Compensation to NCPS (a) Issuer Party shall pay or cause to be paid to NCPS for its services as the facilitator of escrow as outlined in Exhibit B, which may be updated from time to time by NCPS by providing written notice to Issuer Party. Issuer Party’s obligation to pay such fees to NCPS and reimburse NCPS for such expenses is not conditioned upon a successful closing. Upon Issuer Party’s request, NCPS will provide Issuer Party with copies of all relevant invoices, receipts or other evidence of such expenses. The obligations of Issuer Party under this Section 10 shall survive any termination of this Agreement and the resignation or removal of NCPS.
(b) All of the compensation and reimbursement obligations shall be payable by Issuer Party upon demand by NCPS and will be charged automatically by NCPS to the credit card or other payment method separately provided or as otherwise agreed by the Parties. Issuer Party consents to NCPS retaining and using Issuer Party’s payment information for future invoices and as provided in this Agreement. Issuer Party agrees and acknowledges that NCPS and its third party vendors may retain and use Issuer Party’s payment information to facilitate the payments provided for in this Agreement. Issuer Party agrees to provide NCPS written notice (which may be via email) of any update or changes to Issuer Party’s payment information. Absent current payment information, Issuer Party shall make, or cause to be made, all payments to NCPS within 10 days of receiving an invoice therefor. All payments made to NCPS shall be in US dollars in immediately available funds.
(c) If Issuer Party fails to make any payment when due then, in addition to all other remedies that may be available: (a) NCPS may charge interest on the past due amount at the rate of 1.5% per month, calculated daily and compounded monthly, or if lower, the highest rate permitted under Law, which Issuer Party shall pay; such interest may accrue after as well as before any judgment relating to collection of the amount due; and (b) Issuer Party shall reimburse, or cause to be reimbursed, NCPS for all costs incurred by NCPS in collecting any late payments or interest, including attorneys’ fees, court costs and collection agency fees; provided that cumulative late payments are subject to the overall limits as may be required by Law as set forth in Exhibit B.
(d) Only upon the fulfillment of the Minimum Offering, and only when Escrowed Funds are eligible to be released to Issuer in accordance with Section 4(a), and otherwise in compliance with Law, NCPS is authorized to and may disburse from time to time, to itself or to any NCPS Party from the Escrow Funds (but only to the extent of Issuer’s rights thereto), the amount of any compensation and reimbursement of out-of-pocket expenses due and payable hereunder (including any amount to which NCPS or any NCPS Party is entitled to seek indemnification pursuant to Section 9 hereof). NCPS shall notify Issuer Party of any disbursement from the Escrow Funds to itself or to any NCPS Party in respect of any compensation or reimbursement hereunder and shall furnish to Issuer copies of all related invoices and other statements.
(e) Only upon the fulfillment of the Minimum Offering, and only when Escrowed Funds are eligible to be released to Issuer in accordance with Section 4(a), and otherwise in compliance with Law, Issuer shall grant to NCPS and the NCPS Parties a security interest in and lien upon such Escrow Funds (but only to the extent of Issuer’s rights thereto) to secure all obligations hereunder, and NCPS and the NCPS Parties shall have the right to offset the amount of any compensation or reimbursement due any of them hereunder (including any claim for indemnification pursuant to Section 9 hereof) against the Escrow Funds (but only to the extent of Issuer’s rights thereto). If for any reason the Escrow Funds available to NCPS and the NCPS Parties pursuant to such security interest or right of offset are insufficient to cover such compensation and reimbursement, Issuer Party shall promptly pay such amounts to NCPS and the NCPS Parties upon receipt of an itemized invoice.
Compensation for Damages or Losses When investments by investors of either Contracting Party suffer damages or losses owing to war, armed conflict, a state of national emergency, revolt, insurrection, riot or other similar events in the territory of the other Contracting Party, they shall be accorded by the latter Contracting Party a treatment, as regards compensation or other settlement, not less favourable than that accorded to its own investors or to investors of any Third State.
Compensation for Losses Upon demand of any Lender (with a copy to the Administrative Agent) from time to time, the Borrower shall promptly compensate such Lender for and hold such Lender harmless from any loss, cost or expense incurred by it as a result of:
(a) any continuation, conversion, payment or prepayment of any Loan other than a Base Rate Loan on a day other than the last day of the Interest Period for such Loan (whether voluntary, mandatory, automatic, by reason of acceleration, or otherwise);
(b) any failure by the Borrower (for a reason other than the failure of such Lender to make a Loan) to prepay, borrow, continue or convert any Loan other than a Base Rate Loan on the date or in the amount notified by the Borrower; or
(c) any assignment of a Eurodollar Rate Loan on a day other than the last day of the Interest Period therefor as a result of a request by the Borrower pursuant to Section 10.13; including any loss of anticipated profits and any loss or expense arising from the liquidation or reemployment of funds obtained by it to maintain such Loan or from fees payable to terminate the deposits from which such funds were obtained. The Borrower shall also pay any customary administrative fees charged by such Lender in connection with the foregoing. For purposes of calculating amounts payable by the Borrower to the Lenders under this Section 3.05, each Lender shall be deemed to have funded each Eurodollar Rate Loan made by it at the Eurodollar Rate for such Loan by a matching deposit or other borrowing in the London interbank eurodollar market for a comparable amount and for a comparable period, whether or not such Eurodollar Rate Loan was in fact so funded.
Compensation for Damages 4.1 If the Principal has disqualified the Bidder from the tender process prior to the award according to Section 3, the Principal is entitled to demand and recover the damages equivalent Xxxxxxx Money Deposit/Bid Security.
4.2 If the Principal has terminated the contract according to Section 3, or if the Principal is entitled to terminate the contract according to section 3, the Principal shall be entitled to demand and recover from the Contractor liquidated damages equivalent to 5% of the contract value or the amount equivalent to Security Deposit/Performance Bank Guarantee, whichever is higher.
COMPENSATION TO CONSULTANT The Consultant's compensation for the Consulting Services shall be as set forth in Exhibit B attached hereto and incorporated herein by this reference.
Damages for delay Subject to the provisions of Clause 12.4, if COD does not occur prior to the 91st day after the Scheduled Completion Date, unless the delay is on account of reasons solely attributable to the Authority or due to Force Majeure, the Concessionaire shall pay Damages to the Authority in a sum calculated at the rate of 0.1% (zero point one per cent) of the amount of Performance Security for delay of each day until COD is achieved.
Effect of Failure or Delay in Requesting Compensation Failure or delay on the part of any Lender or the Issuing Bank to demand compensation pursuant to this Section 5.01 shall not constitute a waiver of such Lender’s or the Issuing Bank’s right to demand such compensation; provided that the Borrower shall not be required to compensate a Lender or the Issuing Bank pursuant to this Section 5.01 for any increased costs or reductions incurred more than 180 days prior to the date that such Lender or the Issuing Bank, as the case may be, notifies the Borrower of the Change in Law giving rise to such increased costs or reductions and of such Lender’s or the Issuing Bank’s intention to claim compensation therefor; provided further that, if the Change in Law giving rise to such increased costs or reductions is retroactive, then the 180-day period referred to above shall be extended to include the period of retroactive effect thereof.
Compensation to Contractor The terms related to the price of the goods and/or services to be provided under this Agreement and the terms of payment to the Contractor are described in more detail in Attachment “B” to this Agreement: Price and Payment Information.
COMPENSATION OF ULTIMUS The Trust, on behalf of each Fund, shall pay for the services to be provided by Ultimus under this Agreement in accordance with, and in the manner set forth in, Schedule B attached hereto, as such Schedule may be amended from time to time. If this Agreement becomes effective subsequent to the first day of a month or terminates before the last day of a month, Ultimus’ compensation for that part of the month in which the Agreement is in effect shall be prorated in a manner consistent with the calculation of the fees as set forth above. Payment of Ultimus’ compensation for the preceding month shall be made promptly.
Compensation on Termination An Employee whose services have been terminated for any cause and who within three (3) months of separation is diagnosed by a physician as having tuberculosis, shall be entitled to the above compensation and the salary rate shall be based on the salary he was receiving at the time his services were terminated. The benefits of this provision may be extended for an additional three (3) months, provided that the former Employee concerned submits a x-ray plate taken within three (3) months after the termination of employment.
