Construction Personnel Security Sample Clauses

Construction Personnel Security. After award of the contract, the Contractor has ten calendar days to submit to the Contracting Officer a list of workers and supervisors assigned to this project for the Government to conduct all necessary security checks. It is anticipated that security checks will take 14 days to perform. For each individual the list shall include: Full Name Place and Date of Birth Current Address Identification number Failure to provide any of the above information may be considered grounds for rejections and/or resubmittal of the application. Once the Government has completed the security screening and approved the applicants a badge will be provided to the individual for access to the site. This badge may be revoked at any time due to the falsification of data, or misconduct on site. These passes must be displayed visibly by all Contractor personnel working on site. The Contractor shall inform its employees to be used under this contract that they may be subject to search by the Government when entering or leaving work. The Contractor shall return all passes upon conclusion of the contract.
Sample 1
AutoNDA by SimpleDocs
Construction Personnel Security. After award of the contract, the Contractor shall have ten days to submit to the Contracting Officer a list of workers and supervisors assigned to this project (Biographic Data on Personnel) for the Government to conduct all necessary security checks. It is anticipated that security checks will take between 30 and 50 calendar days to perform. For each individual the list shall include: Full Name Other name (Xxxxxxx, maiden, married, patronymic, tribal names) Gender and Nationality Place and Date of Birth Marital Status Occupation (Title of position) Employment (Workplace) Current and / or past citizenships Passport Number Telephone number Naturalization number / or Alien Certification Current Address National identification number Failure to provide any of the above information may be considered grounds for rejection and/or re- submittal of the application. Once the Government has completed the security screening and approved the applicants, the Government will provide a badge to the individual for access to the site. The Government may revoke this badge at any time due to the falsification of data, or misconduct on site.
Sample 1

Related to Construction Personnel Security

  • Personnel Security 6.1 Staff recruitment in accordance with government requirements for pre- employment checks; 6.2 Staff training and awareness of Departmental security and any specific contract requirements.

  • Supervision of Contractor Personnel The Contractor must supply all necessary and sufficient supervision over the work that is being performed and will be held solely responsible for the conduct and performance of his employees or agents involved in work under the Agreement.

  • Information Systems Acquisition Development and Maintenance a. Client Data – Client Data will only be used by State Street for the purposes specified in this Agreement.

  • Contractor Personnel Contractor's staff is expected to present a professional appearance. All personnel of the Contractor will be neat, well groomed, properly uniformed in industry standard uniforms and are expected to conduct themselves at all times in a responsible and courteous manner while performing any work under this Agreement and/or whenever they are on District property. The following code of conduct will be adhered to by the Contractor, his agent(s) and/or his employees. If Contractor fails to ensure that its employees or other agents comply with these requirements, then Contractor may be terminated for cause under this Agreement: A. All employees of the Contractor shall wear a recognizable uniform. No hats will be worn inside the building. All of Contractor’s employees and agents performing work must carry a government-issued photo ID. Contractor’s employees and agents will present ID to District Staff upon request. This provision will be strictly enforced. B. The use of tobacco or tobacco products on Board property is prohibited by State law. C. The Contractor will not be permitted to utilize Day Labor or Temporary Workers to provide any services at any District facility. This includes any employees or agents that are hired prior to contract award. Failure to comply with this requirement could result in immediate termination of contract with the Contractor liable for any breach, including liquidated damages for delay damages and/or forfeiture of Performance Bond. D. The Contractor or employees or agents of the Contractor are not permitted to play loud music, to make unnecessary noises, or to use vulgar or inappropriate language that causes offense to others. E. The employment of unauthorized or illegal aliens by the Contractor is considered a violation of Section 247A (e) of the Immigration and Naturalization Act. If the Contractor knowingly employs unauthorized aliens, such a violation shall also be cause for termination of this Agreement. F. Possession of firearms will not be tolerated on Board property. No person who has a firearm in their vehicle will be permitted to park on District property. Any employee of the Contractor found in violation of this policy will be immediately asked to leave, and will not be allowed to return to perform further work without the consent of the District. G. The Contractor certifies that he/she will not engage in the unlawful manufacture, sale distribution, dispensation, possession, or use of a controlled substance or drug during the performance of the contract and that a drug-free workplace will be provided for the Contractor’s employees or agents during the performance of the contract. The Contractor also certifies that he will secure from any subcontractor who works on the contract, written certification of the same drug free workplace requirements. False certification or violation by failing to carry out requirements of O.C.G.A. § 50-24-3 may cause suspension, termination of contract, or debarment of such bidder Please Note: If any employee or agent of the Contractor or Sub-contractor is found to have brought a firearm on District property, the Contractor or Sub-contractor shall prohibit them from continuing to perform any work on District property. If the Contractor or Sub-contractor fails to do so, then the District may terminate this Agreement for cause as set forth below.

  • Review Systems; Personnel It will maintain business process management and/or other systems necessary to ensure that it can perform each Test and, on execution of this Agreement, will load each Test into these systems. The Asset Representations Reviewer will ensure that these systems allow for each Review Receivable and the related Review Materials to be individually tracked and stored as contemplated by this Agreement. The Asset Representations Reviewer will maintain adequate staff that is properly trained to conduct Reviews as required by this Agreement.

  • PREVAILING WAGE RATES - PUBLIC WORKS AND BUILDING SERVICES CONTRACTS If any portion of work being Bid is subject to the prevailing wage rate provisions of the Labor Law, the following shall apply:

  • Contractor’s Project Manager and Key Personnel Contractor shall appoint a Project Manager to direct the Contractor’s efforts in fulfilling Contractor’s obligations under this Contract. This Project Manager shall be subject to approval by the County and shall not be changed without the written consent of the County’s Project Manager, which consent shall not be unreasonably withheld. The Contractor’s Project Manager shall be assigned to this project for the duration of the Contract and shall diligently pursue all work and services to meet the project time lines. The County’s Project Manager shall have the right to require the removal and replacement of the Contractor’s Project Manager from providing services to the County under this Contract. The County’s Project manager shall notify the Contractor in writing of such action. The Contractor shall accomplish the removal within five (5) business days after written notice by the County’s Project Manager. The County’s Project Manager shall review and approve the appointment of the replacement for the Contractor’s Project Manager. The County is not required to provide any additional information, reason or rationale in the event it The County is not required to provide any additional information, reason or rationale in the event it requires the removal of Contractor’s Project Manager from providing further services under the Contract.

  • Technical Security Controls 35 a. Workstation/Laptop encryption. All workstations and laptops that store PHI COUNTY 36 discloses to CONTRACTOR or CONTRACTOR creates, receives, maintains, or transmits on behalf of 37 COUNTY either directly or temporarily must be encrypted using a FIPS 140-2 certified algorithm which 1 is 128bit or higher, such as AES. The encryption solution must be full disk unless approved by the 2 COUNTY.

  • Interconnection Facilities Engineering Procurement and Construction Interconnection Facilities, Network Upgrades, and Distribution Upgrades shall be studied, designed, and constructed pursuant to Good Utility Practice. Such studies, design and construction shall be based on the assumed accuracy and completeness of all technical information received by the Participating TO and the CAISO from the Interconnection Customer associated with interconnecting the Large Generating Facility.

  • Personnel Equipment and Material Engineer shall furnish and maintain, at its own expense, quarters for the performance of all Engineering Services, and adequate and sufficient personnel and equipment to perform the Engineering Services as required. All employees of Engineer shall have such knowledge and experience as will enable them to perform the duties assigned to them. Any employee of Engineer who, in the reasonable opinion of County, is incompetent or whose conduct becomes detrimental to the Engineering Services shall immediately be removed from association with the Project when so instructed by County. Engineer certifies that it presently has adequate qualified personnel in its employment for performance of the Engineering Services required under this Contract, or will obtain such personnel from sources other than County. Engineer may not change the Project Manager without prior written consent of County.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!