Construction Safety Prior to contract award, the successful bidder must provide a Certificate of Recognition or Letter of Good Standing issued by an occupational health and safety organization approved by the Workers’ Compensation Board of Nova Scotia.
Construction Schedules 10.1 Within seven (7) days of the University’s issuance of a purchase order, the Contractor shall submit to the Project Coordinator three (3) copies of a Construction Schedule for this Project. The Schedule shall be in bar chart form and shall include all aspects of the work, the interrelationship of the various trades and the critical path of the job. The schedule shall include a timeline for the submission, review and approval of shop drawings for critical path items and delivery and installation dates for those same critical path, or long lead time items, (such as electrical transformers and elevator). The Schedule shall coincide with the Contractor’s approved Schedule of Values. The Schedule shall indicate a completion date in advance of the date established for Substantial Completion. The Schedule shall be acceptable to the Architect/Engineer and the Project Coordinator. It shall be revised and reissued at the beginning of every month for the duration of the project. This monthly update progress Schedule shall include a summary comparison of the original schedule and the latest updated schedule (previous month) showing all activity description and dates. These comparison schedules shall be in the form of a summary bar chart, an activity listing report and actual to target comparisons. The reports may include critical activities, float time, duration of each activity, dates of each activity and the network logic (including successors and predecessors of each activity). Included with the written report and electronic copy of the schedule submission noting the above referenced requirements. Failure to provide the Architect/Engineer, or the Project Coordinator with an acceptable, revised Schedule, within seven (7) days of the receipt of a written request, may result in the withholding of the Contractor’s monthly progress payments until such a Schedule is received.
Construction of Public Improvements a. Upon satisfaction of the conditions set forth in Paragraph 2.1 and the notice requirement set forth below, Developer shall construct the Public Improvements at its own expense in accordance with this Agreement, the Final Plat, the Resolution, the Civil Engineering Construction Plans, the Town’s ordinances, resolutions and regulations and all other applicable laws and regulations. All Public Improvements shall be installed and constructed within the rights- of-way or easements dedicated to the Town. Unless otherwise approved by the Town in writing, all materials used for constructing the Public Improvements shall be materials set forth on the Town’s approved material list. Workmanship and materials shall be of good quality.
Construction Sequencing In general, the sequence of the proposed dates of Initial Operation of Interconnection Customers seeking interconnection to the Transmission System will determine the sequence of construction of Network Upgrades.
Construction of the Agreement The Agreement sets forth the entire understanding between two sophisticated business entities with legal counsel as to its subject and supersedes all prior agreements, conditions, warranties, representations, arrangements and communications, including purchase orders issued by Client, whether oral or written, and whether with or by Accenture, any of its affiliates, or any of their employees, officers, directors, agents or shareholders. Each party acknowledges that it entered into the Agreement solely based on the agreements and representations contained herein, and has not relied upon any representations, warranties, promises, or inducements of any kind, whether oral or written, and from any source. If a court of competent jurisdiction finds any term of the Agreement to be invalid, illegal or otherwise unenforceable, such term or provision will not affect the other terms of this Agreement and will be deemed modified to the extent necessary, in the court’s opinion, to render such term enforceable while preserving to the fullest extent permissible the intent and agreements of the parties set forth in this Agreement. No waiver or modification of any provision of the Agreement will be effective unless it is in writing and signed by the party against which it is sought to be enforced. The delay or failure by either party to exercise or enforce any of its rights under this Agreement is not a waiver of that party’s right to later enforce those rights, nor will any single or partial exercise of any such right preclude any other or further exercise of these rights or any other right. There are no third-party beneficiaries to the Agreement. In the event of a conflict between these GTC and an Order Form, the Order Form controls for purposes of that Order Form only.
Construction The parties agree that each of them and/or their respective counsel have reviewed and had an opportunity to revise the Transaction Documents and, therefore, the normal rule of construction to the effect that any ambiguities are to be resolved against the drafting party shall not be employed in the interpretation of the Transaction Documents or any amendments thereto. In addition, each and every reference to share prices and shares of Common Stock in any Transaction Document shall be subject to adjustment for reverse and forward stock splits, stock dividends, stock combinations and other similar transactions of the Common Stock that occur after the date of this Agreement.
Construction and Scope of Agreement The language of all parts of this Agreement shall in all cases be construed as a whole, according to its fair meaning, and not strictly for or against any party. This Agreement is the only, sole, entire, and complete agreement of the parties relating in any way to the subject matter hereof. No statements, promises, or representations have been made by any party to any other, or relied upon, and no consideration has been offered or promised, other than as may be expressly provided herein. This Assumption of Risk, Release of Claims, Indemnification, and Hold Harmless and Agreement supersedes any earlier written or oral understandings or agreements between the parties. Participant acknowledges that he/she has read this Assumption of Risk, Release of Claims, Indemnification and Hold Harmless Agreement, understands its meaning and effect, and agrees to be bound by it. Date:
Construction; Severability In the event that any provision of this Agreement conflicts with the law under which this Agreement is to be construed or if any such provision is held invalid by a court with jurisdiction over the Parties to this Agreement, (i) such provision will be deemed to be restated to reflect as nearly as possible the original intentions of the Parties in accordance with applicable law, and (ii) the remaining terms, provisions, covenants and restrictions of this Agreement will remain in full force and effect.
Construction Schedule The progress schedule of construction of the Project as provided by Developer and approved by District.
Special Construction If, after an order is placed, Xxxxxxx finds that third-party special construction services are needed to build, configure or install any additional facilities and/or equipment necessary for Verizon to provide Access service, Verizon will notify the Customer of any such special construction charges. If Customer does not accept the special construction charges, Customer may terminate the order(s) affected by the special construction charges, with no cancellation fee(s).
