Consultant’s Activities at Construction Site Sample Clauses

Consultant’s Activities at Construction Site. The presence of Consultant's personnel at a construction site, whether as on-site representative, resident engineer, construction manager, or otherwise, does not make Consultant responsible for those duties that belong to Client and/or construction contractors or others, and does not relieve construction contractors or others of their obligations, duties, and responsibilities, including, but not limited to, construction methods, means, techniques, sequences, and procedures necessary for completing all portions of the construction work in accordance with the contract documents, any health or safety programs and precautions required by such construction work, and any compliance with applicable laws and regulations. Any inspection or observation of the contractor's work is solely for the purpose of determining that the work is generally proceeding in conformance with the intent of the project specifications and contract documents. Consultant makes no warranty or guarantee with respect to the performance of a contractor. Consultant has no authority to exercise control over any construction contractor in connection with their work or health or safety programs and precautions. Except to protect Consultant's own personnel and except as may be expressly required elsewhere in the scope of services, Consultant has no duty to inspect, observe, correct, or report on health or safety deficiencies of the construction contractor.
Sample 1Sample 2Sample 3See All (5)
AutoNDA by SimpleDocs
Consultant’s Activities at Construction Site. The presence of CONSULTANT's personnel at a construction site, whether as on-site representative, resident engineer, construction manager, or otherwise, does not make CONSULTANT responsible for those duties that belong to CITY and/or construction contractors or others, and does not relieve construction contractors or others of their obligations, duties, and responsibilities, including, but not limited to, construction methods, means, techniques, sequences, and procedures necessary for completing all portions of the construction work in accordance with the contract documents, any health or safety programs and precautions required by such construction work, and any compliance with applicable laws and regulations. Any inspection or observation of the contractor's work is solely for the purpose of determining that the work is generally proceeding in conformance with the intent of the project specifications and contract documents. CONSULTANT makes no warranty or guarantee with respect to the performance of a contractor. CONSULTANT has no authority to exercise control over any construction contractor in connection with their work or health or safety programs and precautions. Except to protect CONSULTANT's own personnel and except as may be expressly required elsewhere in the scope of services, CONSULTANT has no duty to inspect, observe, correct, or report on health or safety deficiencies of the construction contractor.
Sample 1Sample 2Sample 3

Related to Consultant’s Activities at Construction Site

  • Construction Activities Please list all major construction activities, both planned and completed, to be performed by Seller or the EPC Contractor. Activity EPC Contractor / Subcontractor Completion Date __/__/____ (expected / actual) __/__/____ (expected / actual)

  • Suspension of unsafe Construction Works (i) Upon recommendation of the Authority’s Engineer to this effect, the Authority may by notice require the Contractor to suspend forthwith the whole or any part of the Works if, in the reasonable opinion of the Authority’s Engineer, such work threatens the safety of the Users and pedestrians. (ii) The Contractor shall, pursuant to the notice under Clause 11.17 (i), suspend the Works or any part thereof for such time and in such manner as may be specified by the Authority and thereupon carry out remedial measures to secure the safety of suspended works, the Users and pedestrians. The Contractor may by notice require the Authority’s Engineer to inspect such remedial measures forthwith and make a report to the Authority recommending whether or not the suspension hereunder may be revoked. Upon receiving the recommendations of the Authority’s Engineer, the Authority shall either revoke such suspension or instruct the Contractor to carry out such other and further remedial measures as may be necessary in the reasonable opinion of the Authority, and the procedure set forth in this Clause 11.17 shall be repeated until the suspension hereunder is revoked. (iii) Subject to the provisions of Clause 21.6, all reasonable costs incurred for maintaining and protecting the Works or part thereof during the period of suspension (the “Preservation Costs”), shall be borne by the Contractor; provided that if the suspension has occurred as a result of any breach of this Agreement by the Authority, the Preservation Costs shall be borne by the Authority. (iv) If suspension of Works is for reasons not attributable to the Contractor, the Authority’s Engineer shall determine any Time Extension to which the Contractor is reasonably entitled.

  • PRE-CONSTRUCTION PHASE SERVICES The Pre-Construction Phase shall be deemed to commence upon the date specified in a written Notice to Proceed with Pre-Construction Phase Services issued by Owner and shall continue through completion of the Construction Documents and procurement of all major Subcontractor agreements. Contractor is not entitled to reimbursement for any costs incurred for Pre-Construction Phase Services performed before issuance of the written Notice to Proceed. Pre-Construction Phase Services may overlap Construction Phase Services. Contractor shall perform the following Pre-Construction Phase Services:

  • Project Construction The Contractor agrees to provide continuous on-site supervision on each Job Order, while progress on the project is being accomplished. The Contractor’s Project Manager will ensure: 1. Coordination and providing supervision to all Subcontractor and workers; 2. Posting of the prevailing wage scale; 3. Maintaining a copy of the Contractors safety program manual made available to all construction personnel; 4. Conducting weekly on-site safety meetings; 5. Completing the daily labor and construction progress log on a daily basis and submit copies to the County on a daily basis. Copies of the previous day’s reports must be submitted by 9:00AM of the following day. a. Daily labor log is to include a listing of Subcontractor(s) and a count of workers by trade providing services for the day. b. Construction progress log is to include a narrative of the Work provided by trade(s). Narrative agrees to include the various areas of the jobsite where Work was performed and any problems or conditions that were encountered. c. In the event the Contractor fails to provide a daily log and/or construction progress log, the County may impose damages against the Contractor in the amount of fifty dollars ($50.00) for each log and deduct from the Contractor’s payment request, for each day the Contractor does not provide the documentation. 6. County may suspend Contractor operations if no Contractor Superintendent is observed. All delays caused by the suspension will be the responsibility of the Contractor. No time extension or claims for cost(s) associated with the suspension will be granted by the County.

  • Working Facilities and Expenses It is understood by the parties that the Executive’s principal place of employment shall be at the Bank’s principal executive office located in New Haven, Connecticut, or at such other Bank Board approved location within 50 miles of the address of such principal executive office, or at such other location as the Employer and the Executive may mutually agree upon. The Employer shall provide the Executive at his principal place of employment with a private office, secretarial services and other support services and facilities suitable to his position with the Employer and necessary or appropriate in connection with the performance of his assigned duties under this Agreement. The Employer shall reimburse the Executive for his ordinary and necessary business expenses attributable to the Employer’s business, including, without limitation, the Executive’s travel and entertainment expenses incurred in connection with the performance of his duties for the Employer under this Agreement, in each case upon presentation to the Employer of an itemized account of such expenses in such form as the Employer may reasonably require, and such reimbursement shall be paid promptly by the Employer and in any event no later than March 15 of the year immediately following the year in which the expenses were incurred.

  • Contract Construction 6.27.1 The parties acknowledge that each party and its counsel have reviewed this CONTRACT and that the normal rule of construction to the effect that any ambiguities are to be resolved against the drafting party shall not be employed in the interpretation of this CONTRACT or any amendment or exhibits hereto.

  • Other Activities/Renovations A. The Contractor acknowledges its responsibility to assure the Judicial Council’s quiet enjoyment of the Program and to provide the full service level of the Property for the Program, free from outside distractions, disturbances, and/or interruptions. The Contractor shall avoid assigning any rooms to the Judicial Council or the Attendees during the Program which are adjacent to or across from any group or activity that may generate noise or other distractions, such as construction or other conduct, sufficient to detract from quiet enjoyment of the Program on the Property. B. Additionally, the Contractor shall notify the Judicial Council of any actual or contemplated renovations or other construction that will or may occur on or adjacent to the Property during the Program, no later than fourteen (14) Days from the time the Contractor learns of such renovation or construction activity. C. For any disturbance, renovation, or construction activity that is potentially or actually inconvenient or disruptive to the Program, upon the Judicial Council’s request, the Contractor shall: i. Immediately cause such disturbance to cease, if possible, or suspend or minimize construction or renovation on the Property, if necessary, in order to maintain a proper environment for the Program; and/or ii. Immediately provide equivalent alternate space on the Property, satisfactory to the Program Manager, conducive to conducting the Program in a proper environment. D. If the Contractor is unable to comply with the conditions set forth in this provision, the Judicial Council may terminate the Agreement pursuant to the termination for cause provision set forth herein.

  • Interconnection Facilities Engineering Procurement and Construction Interconnection Facilities, Network Upgrades, and Distribution Upgrades shall be studied, designed, and constructed pursuant to Good Utility Practice. Such studies, design and construction shall be based on the assumed accuracy and completeness of all technical information received by the Participating TO and the CAISO from the Interconnection Customer associated with interconnecting the Large Generating Facility.

  • ARCHITECT’S RESPONSIBILITIES § 2.1 The Architect shall provide professional services as set forth in this Agreement. The Architect represents that it is properly licensed in the jurisdiction where the Project is located to provide the services required by this Agreement, or shall cause such services to be performed by appropriately licensed design professionals. § 2.2 The Architect shall perform its services consistent with the professional skill and care ordinarily provided by architects practicing in the same or similar locality under the same or similar circumstances. The Architect shall perform its services as expeditiously as is consistent with such professional skill and care and the orderly progress of the Project. § 2.3 The Architect shall identify a representative authorized to act on behalf of the Architect with respect to the Project. § 2.4 Except with the Owner’s knowledge and consent, the Architect shall not engage in any activity, or accept any employment, interest or contribution that would reasonably appear to compromise the Architect’s professional judgment with respect to this Project. § 2.5 The Architect shall maintain the following insurance until termination of this Agreement. If any of the requirements set forth below are in addition to the types and limits the Architect normally maintains, the Owner shall pay the Architect as set forth in Section 11.9. § 2.5.1 Commercial General Liability with policy limits of not less than « » ($ « » ) for each occurrence and « » ($ « » ) in the aggregate for bodily injury and property damage. § 2.5.2 Automobile Liability covering vehicles owned, and non-owned vehicles used, by the Architect with policy limits of not less than « » ($ « » ) per accident for bodily injury, death of any person, and property damage arising out of the ownership, maintenance and use of those motor vehicles, along with any other statutorily required automobile coverage. § 2.5.3 The Architect may achieve the required limits and coverage for Commercial General Liability and Automobile Liability through a combination of primary and excess or umbrella liability insurance, provided such primary and excess or umbrella liability insurance policies result in the same or greater coverage as the coverages

  • CONSULTANT’S RESPONSIBILITIES In addition to all other obligations contained herein, the Consultant agrees, warrants, and represents that: 6.1 The Consultant will furnish all material, equipment, labor and supplies in such quantities and of the proper quality to professionally and timely perform the Services, except as otherwise mutually agreed by the Parties; 6.2 The Consultant shall perform the Services with the professional skill and care ordinarily provided by competent consultants practicing in the same or similar locality and under the same or similar circumstances and professional license; 6.3 The Consultant will comply with the provisions of all federal, state, and local laws, regulations, ordinances, requirements and codes which are applicable to its performance of Services; 6.4 The Consultant is not and will not be bound by any agreement and has not assumed nor will assume any obligation which would, in any way, restrict its ability to perform the Services or be inconsistent with the Services; 6.5 In performing the Services, the Consultant will not use any third party’s confidential or propriety information, or infringe the rights of another party, nor will the Consultant disclose to the Authority, or bring onto the Authority’s premises, or induce the Authority to use any third party’s confidential or proprietary information; 6.6 The Consultant does not have the authority to act for the Authority, bind the Authority in any respect, or incur any debts or liabilities in the name of or on behalf of the Authority, except as otherwise expressly authorized in writing by the Authority; 6.7 Consultant is an independent contractor for the performance of his duties under this Contract. Accordingly, the Consultant shall be responsible for payment of all taxes including federal, state and local taxes arising out of the Consultant’s activities in accordance with this Contract. Consultant is responsible for payment of the compensation, including any withholding, Social Security, or other taxes on such compensation, of any subcontractors retained by Consultant, or Consultant's employees performing Services consistent with its status as an independent contractor and in compliance with all applicable laws and regulations; 6.8 Consultant has and hereby retains full control of any supervision over the Consultant’s obligations hereunder and over any persons employed or subcontracted by the Consultant for performing Services hereunder; 6.9 Consultant will in no way be considered an agent, partner, joint venturer, or employee of Authority at any time during the Term. Consultant will not undertake to commit Authority to any course of action in relation to a third party unless expressly requested and authorized to do so by the Authority in writing. 6.10 As of the Effective Date and at all times while providing Services hereunder, the Consultant shall possess and maintain in good standing any and all licenses or other authorizations and approvals necessary to perform the Services.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!