Continued Design-to-Budget Obligations Sample Clauses

Continued Design-to-Budget Obligations. In general, the A/E shall use its best efforts to develop the Construction Documents in a manner that is consistent with the Design-to- Budget that was established in this Agreement. The A/E understands and agrees that any redesign required due to the design exceeding the Design-to-Budget may need to be completed on an expedited basis or in multiple packages in order to keep the Project on schedule and the A/E shall use its best efforts to meet the Project’s schedule requirements in performing such redesign. It is understood and agreed by both Parties to this Agreement that the A/E’s redesign obligations under this Section 3.3 shall be the limit of the A/E’s liability for the failure to meet its design-to-budget obligations.
Sample 1Sample 2
AutoNDA by SimpleDocs
Continued Design-to-Budget Obligations. In general, the A/E shall use its best efforts to develop the Construction Documents in a manner that is consistent with the Design- to-Budget that was established at the end of the Schematic Design phase. In furtherance of the A/E’s design to budget obligations, the A/E hereby agrees as follows: a. With regard to any bid package that was purchased at the GMP on a design-assist basis or with a mini-GMP, the A/E shall work with the XXXX and the relevant trade subcontractor to develop a design that can be accommodated by such mini-GMP or other subcontract structure. The A/E understands and agrees that this may require redesign and that any such redesign is included within its base fee. b. With regard to work that will be purchased subsequent to the formation of the GMP, the A/E shall be required to work with the Department and the XXXX should the trade bids for any such package exceed the design-to-budget figure established at the time the GMP was agreed upon for such package at no additional cost to either the Department or the XXXX. The A/E understands and agrees that any such redesign may need to be completed on an expedited basis or in multiple packages in order to keep the Project on schedule and the A/E shall use its best efforts to meet the Project’s schedule requirements in performing such redesign. It is understood and agreed by both parties to this Agreement that the A/E’s redesign obligations under this Section 3.4 shall be the limit of the A/E’s liability for the failure to meet its design-to-budget obligations.
Sample 1Sample 2
Continued Design-to-Budget Obligations. In general, the A/E shall use its best efforts to develop the Construction Documents in a manner that is consistent with the Design- to-Budget that was established at the end of the Schematic Design phase. In furtherance of the A/E’s design to budget obligations, the A/E hereby agrees as follows: a. With regard to any bid package that was purchased at the GMP on a design-assist basis or with a mini-GMP, the A/E shall work with the XXXX and the relevant trade subcontractor to develop a design that can be accommodated by such mini-GMP or other subcontract structure. The A/E understands and agrees that this may require redesign and that any such redesign is included within its base fee. b. With regard to work that will be purchased subsequent to the formation of the GMP, the A/E shall be required to work with the Department and the XXXX should the trade bids for any such package exceed the design-to-budget figure established at the time the GMP was agreed upon for such package at no additional cost to either the Department or the XXXX.
Sample 1
Continued Design-to-Budget Obligations. In general, the A/E shall use its best efforts to develop the Construction Documents in a manner that is consistent with the Design-to- Budget that was established in this Agreement. The A/E understands and agrees that any redesign required due to the design exceeding the Design-to-Budget may need to be completed on an expedited basis or in multiple packages in order to keep the Project on schedule and the A/E shall use its best efforts to meet the Project’s schedule requirements in performing such redesign. It is understood and
Sample 1
Continued Design-to-Budget Obligations. In general, the Architect shall use its best efforts to develop the Construction Documents in a manner that is consistent with the Design-to-Budget that was established at the GMP. In furtherance of the Architect’s design to budget obligations, the Architect hereby agrees as follows: .1 With regard to any bid package that was purchased at the GMP on a design-assist basis or with a mini-GMP, the Architect shall work with the Design-Builder and the relevant trade subcontractor to develop a design that can be accommodated by such mini-GMP or other subcontract structure. The Architect understands and agrees that this may require redesign and that any such redesign is included within its base fee. .2 With regard to work that will be purchased subsequent to the formation of the GMP, the Architect shall be required to work with the Department and the Design-Builder should the trade bids for any such package exceed the design to budget figure established at the time the GMP was agreed upon for such package at no additional cost to either the Department or the Design-Builder.
Sample 1

Related to Continued Design-to-Budget Obligations

  • ADDITIONAL SPECIAL CONTRACT CONDITIONS Special Contract Conditions revisions: the corresponding subsections of the Special Contract Conditions referenced below are replaced in their entirety with the following:

  • Initial Contract Term The Initial Contract Term shall be for two years. The Initial Contract Term shall begin on October 1, 2021, or on the last date the Contract is signed by all Parties, whichever is later. The Contract shall expire on October 1, 2023, unless terminated earlier in accordance with the Special Contract Conditions or Additional Special Contract Conditions.

  • Existing Improvements All improvements located on the Site as of the date of execution of the Construction Contract, whether above or below the surface of the ground, including but not limited to existing buildings, utilities, infrastructure improvements and other facilities.

  • Disbursement of the Tenant Improvement Allowance Except as otherwise set forth in this Work Letter, the Tenant Improvement Allowance shall be disbursed by Landlord (each of which disbursements shall be made pursuant to Landlord’s disbursement process, which disbursement process shall require the Architect to make field verifications and written certifications as required by Landlord in connection with Landlord’s disbursements to Contractor (as defined below)) only for the following items and costs (collectively the “Tenant Improvement Allowance Items”): (a) Payment of (i) the fees of the Architect and the Engineers (as defined below), (ii) charges for Landlord’s construction consultant and Building engineer, and (iii) the fees incurred by, and the cost of documents and materials supplied by, Landlord and Landlord’s consultants in connection with the preparation and review of the Construction Drawings (as defined below); (b) The payment of plan check, permit and license fees relating to construction of the Tenant Improvements; (c) The cost of construction of the Tenant Improvements, including, without limitation, any cost of after-hours freight elevator usage; (d) The cost of any changes in the Base, Shell, and Core when such changes are required by the Construction Drawings, such cost to include all direct architectural and/or engineering fees and expenses incurred in connection therewith; (e) The cost of any changes to the Construction Drawings or Tenant Improvements required by applicable laws and building codes (collectively, “Code”); (f) Sales and use taxes; and (g) All other costs to be expended by Landlord in connection with the construction of the Tenant Improvements. In no event shall the Tenant Improvement Allowance Items include any costs of procuring or installing in the Premises any trade fixtures, equipment, furniture, furniture partitions or systems, furnishings, telephone, telecommunications, data and security wiring, cabling and equipment, or other personal property (“Personal Property”) to be used in the Premises by Tenant, and the cost of such Personal Property shall be paid by Tenant.

  • Notice to Proceed - Site Improvements The Recipient shall not commence, or cause to be commenced, any site improvements or other work on the Land until the Director has issued a Notice to Proceed to the Recipient. Such Notice to Proceed will not be issued until the Director is assured that the Recipient has complied with all requirements for the approval of a grant under Revised Code Sections 164.20 through 164.27 and has completed any land acquisition required by the Project. A Notice to Proceed shall be required for all Project prime contractors or direct procurement initiated by the Recipient following execution of this Agreement.

  • Disbursement of Tenant Improvement Allowance During the construction of the Tenant Improvements, Landlord shall make monthly disbursements of the Tenant Improvement Allowance for Tenant Improvement Allowance Items for the benefit of Tenant and shall authorize the release of monies for the benefit of Tenant as follows.

  • Tenant Improvement Allowance Items Except as otherwise set forth in this Tenant Work Letter, the Tenant Improvement Allowance shall be disbursed by Landlord only for the following items and costs (collectively, the “Tenant Improvement Allowance Items”): 2.2.1.1 Payment of the fees of the “Architect” and the “Engineers,” as those terms are defined in Section 3.1 of this Tenant Work Letter, the costs of Tenant’s project manager (if any) and payment of the fees incurred by, and the cost of documents and materials supplied by, Landlord and Landlord’s consultants in connection with the preparation and review of the “Construction Drawings,” as that term is defined in Section 3.1 of this Tenant Work Letter; 2.2.1.2 The payment of plan check, permit and license fees relating to construction of the Tenant Improvements; 2.2.1.3 The cost of construction of the Tenant Improvements, including, without limitation, contractors’ fees and general conditions, testing and inspection costs, costs of utilities, trash removal, parking and hoists, and the costs of after-hours freight elevator usage. 2.2.1.4 The cost of any changes in the Base, Shell and Core work when such changes are required by the Construction Drawings (including if such changes are due to the fact that such work is prepared on an unoccupied basis), such cost to include all direct architectural and/or engineering fees and expenses incurred in connection therewith; 2.2.1.5 The cost of any changes to the Construction Drawings or Tenant Improvements required by applicable laws and building codes (collectively, “Code”); 2.2.1.6 Sales and use taxes; 2.2.1.7 The “Coordination Fee,” as that term is defined in Section 4.2.2.2 of this Tenant Work Letter; and 2.2.1.8 All other costs to be expended by Landlord in connection with the construction of the Tenant Improvements.

  • Extension of Initial Contract Period 31.1 Subject to clause 13 (Price Adjustment on Extension of the Initial Contract Period), the Authority may, by giving written notice to the Contractor not less than three (3) Month(s) prior to the last day of the Initial Contract Period, extend the Contract for such further period as may be specified in the notice. The provisions of the Contract will apply (subject to any Variation or adjustment to the Contract Price pursuant to clause 13) throughout any such extended period.

  • Issuing Bank’s Duties Regarding Letters of Credit; Unconditional Nature of Reimbursement Obligations In examining documents presented in connection with drawings under Letters of Credit and making payments under such Letters of Credit against such documents, the Issuing Bank shall only be required to use the same standard of care as it uses in connection with examining documents presented in connection with drawings under letters of credit in which it has not sold participations and making payments under such letters of credit. The Borrower assumes all risks of the acts and omissions of, or misuse of the Letters of Credit by, the respective beneficiaries of such Letters of Credit. In furtherance and not in limitation of the foregoing, none of the Issuing Bank, Administrative Agent or any of the Lenders shall be responsible for, and the Borrower’s obligations in respect of Letters of Credit shall not be affected in any manner by, (i) the form, validity, sufficiency, accuracy, genuineness or legal effects of any document submitted by any party in connection with the application for and issuance of or any drawing honored under any Letter of Credit even if such document should in fact prove to be in any or all respects invalid, insufficient, inaccurate, fraudulent or forged; (ii) the validity or sufficiency of any instrument transferring or assigning or purporting to transfer or assign any Letter of Credit, or the rights or benefits thereunder or proceeds thereof, in whole or in part, which may prove to be invalid or ineffective for any reason; (iii) failure of the beneficiary of any Letter of Credit to comply fully with conditions required in order to draw upon such Letter of Credit; (iv) errors, omissions, interruptions or delays in transmission or delivery of any messages, by mail, cable, facsimile, electronic mail, telecopy or otherwise, whether or not they be in cipher; (v) errors in interpretation of technical terms; (vi) any loss or delay in the transmission or otherwise of any document required in order to make a drawing under any Letter of Credit, or of the proceeds thereof; (vii) the misapplication by the beneficiary of any Letter of Credit, or of the proceeds of any drawing under any Letter of Credit; or (viii) any consequences arising from causes beyond the control of the Issuing Bank, Administrative Agent or the Lenders. None of the above shall affect, impair or prevent the vesting of any of the Issuing Bank’s or Administrative Agent’s rights or powers hereunder. Any action taken or omitted to be taken by the Issuing Bank under or in connection with any Letter of Credit, if taken or omitted in the absence of gross negligence or willful misconduct (as determined by a court of competent jurisdiction in a final, non-appealable judgment), shall not create against the Issuing Bank any liability to the Borrower, the Administrative Agent or any Lender. In this connection, the obligation of the Borrower to reimburse the Issuing Bank for any drawing made under any Letter of Credit, and to repay any Revolving Loan made pursuant to the second sentence of the immediately preceding subsection (e), shall be absolute, unconditional and irrevocable and shall be paid strictly in accordance with the terms of this Agreement and any other applicable Letter of Credit Document under all circumstances whatsoever, including without limitation, the following circumstances: (A) any lack of validity or enforceability of any Letter of Credit Document or any term or provisions therein; (B) any amendment or waiver of or any consent to departure from all or any of the Letter of Credit Documents; (C) the existence of any claim, setoff, defense or other right which the Borrower may have at any time against the Issuing Bank, the Administrative Agent or any Lender, any beneficiary of a Letter of Credit or any other Person, whether in connection with this Agreement, the transactions contemplated hereby or in the Letter of Credit Documents or any unrelated transaction; (D) any breach of contract or dispute between the Borrower, the Issuing Bank, the Administrative Agent, any Lender or any other Person; (E) any demand, statement or any other document presented under a Letter of Credit proving to be forged, fraudulent, invalid or insufficient in any respect or any statement therein or made in connection therewith being untrue or inaccurate in any respect whatsoever; (F) any non-application or misapplication by the beneficiary of a Letter of Credit or of the proceeds of any drawing under such Letter of Credit; (G) payment by the Issuing Bank under any Letter of Credit against presentation of a draft or certificate which does not strictly comply with the terms of such Letter of Credit; and (H) any other act, omission to act, delay or circumstance whatsoever that might, but for the provisions of this Section, constitute a legal or equitable defense to or discharge of the Borrower’s Reimbursement Obligations. Notwithstanding anything to the contrary contained in this Section or Section 12.10., but not in limitation of the Borrower’s unconditional obligation to reimburse the Issuing Bank for any drawing made under a Letter of Credit as provided in this Section and to repay any Revolving Loan made pursuant to the second sentence of the immediately preceding subsection (e), the Borrower shall have no obligation to indemnify the Administrative Agent, the Issuing Bank or any Lender in respect of any liability incurred by the Administrative Agent, the Issuing Bank or such Lender arising solely out of the gross negligence or willful misconduct of the Administrative Agent, the Issuing Bank or such Lender in respect of a Letter of Credit as determined by a court of competent jurisdiction in a final, non-appealable judgment. Except as otherwise provided in this Section, nothing in this Section shall affect any rights the Borrower may have with respect to the gross negligence or willful misconduct of the Administrative Agent, the Issuing Bank or any Lender with respect to any Letter of Credit.

  • Interest Subsidy and Special Allowance Payments and Rebate Fees The Seller shall be entitled to all Interest Subsidy Payments and Special Allowance Payments on each Additional Loan or Substituted Loan accruing up to but not including the related Subsequent Cutoff Date and shall be responsible for the payment of any rebate fees applicable to such Purchased Loans subject to the related Xxxx of Sale accruing up to but not including the related Subsequent Cutoff Date. The Purchaser and the Eligible Lender Trustee on behalf of the Purchaser shall be entitled to all Special Allowance Payments and Interest Subsidy Payments accruing from the related Subsequent Cutoff Date with respect to the Additional Loans or Substituted Loans, and shall be responsible for the payment of any rebate fees applicable to the Additional Loans accruing from the date of the related Subsequent Cutoff Date.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!