CONTRACT CONTROVERSIES Sample Clauses

CONTRACT CONTROVERSIES a. In the event of a controversy or claim arising from this Contract, the Contractor must, within six (6) months after the cause of action occurs, file a written claim with the Contracting Officer for a determination, stating all grounds upon which the Contractor asserts a controversy or claim. The written claim shall state all grounds upon which the Contractor asserts a controversy exists. If the Contractor fails to file a claim or files an untimely claim, the Contractor is deemed to have waived its right to assert a claim in any forum. At the time the claim is filed, or within sixty (60) days thereafter, either party may request mediation through the Commonwealth of Pennsylvania’s Office of General Counsel Mediation Program. b. If the Contractor or the Contracting Officer requests mediation and the other party agrees, the Contracting Officer shall promptly make arrangements for mediation. Mediation shall be scheduled so as to not delay the issuance of the final determination beyond the required 120 days after receipt of the claim if mediation is unsuccessful. c. If mediation is not agreed to or if resolution is not reached through mediation, the Contracting Officer shall review timely filed claims and issue a final determination, in writing, regarding the claim. The final determination shall be issued within 120 days of the receipt of the claim, unless extended by consent of the Contracting Officer and the Contractor. The Contracting Officer shall send his/her written determination to the Contractor. If the Contracting Officer fails to issue a final determination within the 120 days (unless extended by consent of the parties), the claim shall be deemed denied. The Contracting Officer's determination shall be the final order of the purchasing agency. d. Within fifteen (15) days of the mailing date of the determination denying a claim or within 135 days of filing a claim if no extension is agreed to by the parties, whichever occurs first, the Contractor may file a statement of claim with the Commonwealth Board of Claims. Pending a final judicial resolution of a controversy or claim, the Contractor shall proceed diligently with the performance of this Contract in a manner consistent with the determination of the Contracting Officer and the University shall compensate the Contractor pursuant to the terms of this Contract.
Sample 1Sample 2Sample 3See All (30)
AutoNDA by SimpleDocs
CONTRACT CONTROVERSIES a. In the event of a controversy or claim arising from the Contract, the Contractor must, within six months after the cause of action accrues, file a written notice of controversy or claim with the Contracting Officer for a determination. The claim shall state all grounds upon which the Contractor asserts a controversy exists. If the Contractor fails to file a claim or files an untimely claim, the Contractor is deemed to have waived its right to assert a claim in any forum. b. The contracting officer shall review timely filed claims and issue a final determination, in writing, regarding the claim. The final determination shall be issued within 120 days of the receipt of the claim, unless extended by consent of the Contracting Officer and the Contractor. The Contracting Officer shall send his/her written determination to the Contractor. If the Contracting Officer fails to issue a final determination within the 120 days (unless extended by consent of the Parties), the claim shall be deemed denied. The contracting officer’s determination shall be the final order of the Purchasing Agency. c. Within fifteen (15) days of the mailing date of the determination denying a claim or within 135 days of filing a claim if, no extension is agreed to by the parties, whichever occurs first, the Contractor may file a statement of claim with the Commonwealth Board of Claims. Pending a final judicial resolution of a controversy or claim, the Contractor shall proceed diligently with the performance of the Contract in a manner consistent with the determination of the Contracting Officer and the Commonwealth shall compensate the Contractor pursuant to the terms of the Contract.
Sample 1Sample 2Sample 3See All (14)
CONTRACT CONTROVERSIES. In the event of a controversy or claim arising from the Contract, the Contractor must, within six months after the cause of action accrues, file a written claim with the contracting officer for a determination. The claim shall state all grounds upon which the Contractor asserts a controversy exists. If the Contractor fails to file a claim or files an untimely claim, the Contractor is deemed to have waived its right to assert a claim in any forum.
Sample 1Sample 2Sample 3
CONTRACT CONTROVERSIES. Any claim or controversy arising out of this Participating Addendum, State Contract Number 4400019305, or any order issued pursuant to State Contract Number 4400019305, shall be resolved by the provisions of Louisiana Revised Statute 39:1673.
Sample 1
CONTRACT CONTROVERSIES. Any claim or controversy arising out of the Contract shall be resolved by the provisions of Louisiana Revised Statute 39:1524-26.
Sample 1
CONTRACT CONTROVERSIES. In the event of a controversy or claim between the Law Firm and the Board arising from this Contract, the Law Firm must, within six months after the cause of action accrues, file a written notice of the controversy or claim with the Chief Counsel for a determination. The Chief Counsel shall send a written determination to the Law Firm within 60 days of receipt of such written notice. The decision of the Chief Counsel shall be final and conclusive unless, within 15 days after receipt of such written determination, the Law Firm files a claim with the Commonwealth of Pennsylvania Board of Claims ("Board of Claims"). Pending a final judicial resolution of a controversy or claim, the Law Firm shall proceed diligently with the performance of this Contract in a manner consistent with the interpretation of the Board, and the Board shall continue to compensate the Law Firm pursuant to the terms of this Contract.
Sample 1
CONTRACT CONTROVERSIES. All claims, disputes or other matters which cannot be disposed of by mutual agreement, shall be settled in accordance with Alaska Statute 36.30.620 through 36.30.699 of the Procurement Code.
Sample 1
AutoNDA by SimpleDocs
CONTRACT CONTROVERSIES 
Sample 1Sample 2Sample 3

Related to CONTRACT CONTROVERSIES

  • Labor Controversies There are no labor controversies pending or, to the best of the Company’s knowledge, threatened against the Company or any Restricted Subsidiary, that could reasonably be expected to have a Material Adverse Effect.

  • Controversies If any controversy arises between the Parties to this Agreement, or with any other Party, concerning the subject matter of this Agreement, its terms or conditions, the Escrow Agent will not be required to determine the controversy or to take any action regarding it. The Escrow Agent may hold all documents and funds and may wait for settlement of any such controversy by final appropriate legal proceedings or other means as, in the Escrow Agent’s discretion, the Escrow Agent may require, despite what may be set forth elsewhere in this Agreement. In such event, the Escrow Agent will not be liable for interest or damage. Furthermore, the Escrow Agent may at its option file an action of interpleader requiring the Parties to answer and litigate any claims and rights among themselves. The Escrow Agent is authorized to deposit with the clerk of the court all documents and funds held in escrow, except all costs, expenses, charges and reasonable attorney fees incurred by the Escrow Agent due to the interpleader action and which the Company agrees to pay. Upon initiating such action, the Escrow Agent shall be fully released and discharged of and from all obligations and liability imposed by the terms of this Agreement.

  • Tax Controversies Subject to the provisions hereof, the General Partner is designated as the Tax Matters Partner (as defined in the Code) and is authorized and required to represent the Partnership (at the Partnership’s expense) in connection with all examinations of the Partnership’s affairs by tax authorities, including resulting administrative and judicial proceedings, and to expend Partnership funds for professional services and costs associated therewith. Each Partner agrees to cooperate with the General Partner and to do or refrain from doing any or all things reasonably required by the General Partner to conduct such proceedings.

  • Litigation, Labor Controversies, etc There is no pending or, to the knowledge of the Borrower, threatened litigation, action, proceeding, or labor controversy affecting the Borrower or any of its Subsidiaries, or any of their respective properties, businesses, assets or revenues, which could reasonably be expected to have a Material Adverse Effect, except as disclosed in Item 6.7 ("Litigation") of the Disclosure Schedule.

  • Disputes In the case of a dispute as to the determination of the Exercise Price or the arithmetic calculation of the number of Warrant Shares issuable in connection with any exercise, the Company shall promptly deliver to the Holder the number of Warrant Shares that are not disputed.

  • Disputes or Controversies The Executive recognizes that should a dispute or controversy arising from or relating to this Agreement be submitted for adjudication to any court, arbitration panel, or other third party, the preservation of the secrecy of Confidential Information may be jeopardized. All pleadings, documents, testimony, and records relating to any such adjudication will be maintained in secrecy and will be available for inspection by the Employer, the Executive, and their respective attorneys and experts, who will agree, in advance and in writing, to receive and maintain all such information in secrecy, except as may be limited by them in writing.

  • Labor Contracts Except as set forth on Schedule 5.20, as of the Closing Date, none of the Credit Parties is party to any collective bargaining agreement. There are no material grievances, disputes or controversies with any union or other organization of any Credit Party’s employees, or threats of strikes or work stoppages that would reasonably be expected to result in a Material Adverse Effect.

  • Contract Disputes The Parties shall deal in good faith and attempt to resolve potential disputes informally. If the dispute concerning a question of fact arising under the terms of this Contract is not disposed of in a reasonable period of time by the Contractor’s Supervisor and the County‘s project manager as specified in Article 25. Notices by way of the following process, such matter shall be brought to the attention of the County DPA by way of the following process: i. The Contractor shall submit to the County DPA a written demand for a final decision regarding the disposition of any dispute between the Parties arising under, related to, or involving this Contract, unless the County, on its own initiative, has already rendered such a final decision. ii. The Contractor’s written demand shall be fully supported by factual information, and, if such demand involves a cost adjustment to the Contract, the Contractor shall include with the demand a written statement signed by a senior official indicating that the demand is made in good faith, that the supporting data are accurate and complete, and that the amount requested accurately reflects the Contract adjustment for which the Contractor believes the County is liable. iii. Pending the final resolution of any dispute arising under, related to, or involving this Contract, the Contractor agrees to diligently proceed with the performance of this Contract, including the delivery of goods and/or provision of services. The Contractor’s failure to diligently proceed shall be considered a material breach of this Contract. Any final decision of the County shall be expressly identified as such, shall be in writing, and shall be signed by the County DPA or his designee. If the County fails to render a decision within 90 days after receipt of the Contractor’s demand, it shall be deemed a final decision adverse to the Contractor’s contentions. The County’s final decision shall be conclusive and binding regarding the dispute unless the Contractor commences action in a court of competent jurisdiction to contest such decision within 90 days following the date of the County’s final decision or one year following the accrual of the cause of action, whichever is later.

  • Legal Disputes 3.1 Pursuant to New York City Health and Hospitals Corporation Act, Chapter 1016-69, Section 20, all actions against NYC Health + Hospitals shall be brought in the City , in the county in which the cause of action arose, or if it arose outside of the City , in the City , County of New York. The Parties consent to the dismissal or transfer to any claims asserted inconsistent with this section. If Vendor initiates any action in breach of this section, Vendor shall promptly reimburse NYC Health + Hospitals for any attorneys’ fees incurred to remove the action to the contractually agreed upon venue. 3.2 Actions against NYC Health + Hospitals by Vendor arising out of this Agreement must be commenced within six months of the expiration or termination of this Agreement. 3.3 Neither Party shall make a claim for personal liability against any individual, officer, agent or employee of the other, nor of the City, pertaining to anything done or omitted in connection with this Agreement.

  • Labor Disputes No labor disturbance by or dispute with employees of the Company or any of its Subsidiaries exists or, to the knowledge of the Company, is threatened which would reasonably be expected to result in a Material Adverse Effect.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!