Contractor Requested Change Sample Clauses

Contractor Requested Change. If the Change Request is submitted by Contractor to State, the Change Request shall, to the extent known at the time of the request, indicate schedule changes and any other items Contractor believes the Change Request is likely to impact (each an “Impact Analysis”). If a complete and final Impact Analysis cannot be specified, or if aspects of the Impact Analysis cannot be determined at the time of the request, Contractor shall so indicate on the applicable Change Control Form, including a detailed explanation of the basis of such inability of Contractor to so determine. State shall indicate its acceptance or rejection of the Change Request and/or provide a counter-proposal to the Impact Analysis stated thereon via a Change Response. In no event shall any Contractor-submitted Change Request include any additional charges or purport to increase any of the fees set forth on the Fee Schedule payable by a State Entity hereunder. A Contractor submitted Change Request shall not become a Change Order unless such Change Request (and its related Impact Analysis) are expressly accepted by State as evidenced by its signature on the applicable Change Control Form.
Sample 1Sample 2Sample 3See All (5)
AutoNDA by SimpleDocs

Related to Contractor Requested Change

  • Owner-Requested Changes If the Owner requests changes in the Contract Documents that would materially affect the completion of the Work by lengthening the critical path of the Overall Project Schedule, the Design Professional shall determine the appropriate number of days and thereby extend the Material Completion and Occupancy Date. The Contractor expressly agrees that the Contractor’s sole monetary remedy for such extensions of Contract Time shall be calculated at the daily rate established for Time Dependent Overhead Costs in the Contract.

  • CLEC Requested Changes 58.9.1 CLEC may submit a request to negotiate and pay for changes in the content and format of the usage data transmitted by CenturyLink.

  • Contractor Changes The Contractor shall notify DAS in writing no later than ten (10) Days from the effective date of any change in:

  • CONTRACT ITEM CHANGES A. If a manufacturer discontinues a contracted item, that item will automatically be considered deleted from the contract with no penalty to Contractor. However, H-GAC may at its sole discretion elect to make a contract award to the next lowest Respondent for the item, or take any other action deemed by H-GAC, at its sole discretion, to be in the best interests of its Customers.

  • Contract Changes Changes may not be made in the terms and conditions of this contract without the agreement and written permission of the Director of Housing.

  • Contract Task Order A-E shall be assigned work via a task order by COUNTY which shall subsequently be referred to as the “Contract Task Order” (hereinafter “CTO”). A CTO for each project shall be developed by A-E in conjunction with COUNTY Project Management staff. The COUNTY Project Manager shall manage all A-E’s work including monitoring the CTO work schedule, quality of deliverables, review of invoiced amounts, adherence to set budget, and internal review of submittal packages. A-E shall follow all requirements as outlined in the CTO; this general Scope of Work, the project specific Scope Statement, and the Architect-Engineer Guide (Rev July 2018). The CTO shall include a detailed Scope Statement, describing tasks to be performed with a specific list of deliverables for each task, schedule of work and cost to complete the work. The schedule of work shall allow enough time for meetings with COUNTY Management staff to review the work progress, provide technical and policy direction, resolve problems and ensure adherence to the work completion schedule. The CTO shall include a cover sheet provided by COUNTY Project Management staff with the appropriate signature blocks and contract information. Once both Parties agree, and all Parties have signed the CTO, COUNTY Management staff shall provide A-E with a Notice to Proceed (NTP) to begin work. A-E shall submit all plans, reports and other documents produced under the CTO to the assigned COUNTY Project Manager within the timeframe indicated in the CTO or as directed by COUNTY Project Management staff.

  • CONTRACT DIRECTION (a) Only the LOCKHEED XXXXXX Procurement Representative has authority on behalf of LOCKHEED XXXXXX to make changes to this Contract. All amendments must be identified as such in writing and executed by the parties.

  • Construction Change Directive A written order prepared and issued by the District, the Construction Manager, and/or the Architect and signed by the District and the Architect, directing a change in the Work.

  • Change Order (5) The Change Order is then submitted to the Project Manager who immediately processes the CO with OPC as required by Bulletin 3.5 and BGS’ Contracting Plan.

  • Approval Process Tenant shall notify Landlord whether it approves of the submitted working drawings within three business days after Landlord’s submission thereof. If Tenant disapproves of such working drawings, then Tenant shall notify Landlord thereof specifying in reasonable detail the reasons for such disapproval, in which case Landlord shall, within five business days after such notice, revise such working drawings in accordance with Tenant’s objections and submit the revised working drawings to Tenant for its review and approval. Tenant shall notify Landlord in writing whether it approves of the resubmitted working drawings within one business day after its receipt thereof. This process shall be repeated until the working drawings have been finally approved by Landlord and Tenant. If Tenant fails to notify Landlord that it disapproves of the initial working drawings within three business days (or, in the case of resubmitted working drawings, within one business day) after the submission thereof, then Tenant shall be deemed to have approved the working drawings in question. Any delay caused by Tenant’s unreasonable withholding of its consent or delay in giving its written approval as to such working drawings shall constitute a Tenant Delay Day (defined below). If the working drawings are not fully approved (or deemed approved) by both Landlord and Tenant by the 15th business day after the delivery of the initial draft thereof to Tenant, then each day after such time period that such working drawings are not fully approved (or deemed approved) by both Landlord and Tenant shall constitute a Tenant Delay Day.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!