Infringement and Defense of Licensee SAP shall defend Licensee against claims brought against Licensee in the Territory by any third party alleging that Licensee's Use of the Software, in accordance with the terms and conditions of this Agreement, constitutes a direct infringement or misappropriation of such third party’s patent claim(s), copyright or trade secret rights, and SAP will pay damages finally awarded against Licensee (or the amount of any settlement SAP enters into) with respect to such claims. This obligation of SAP shall not apply if the alleged infringement or misappropriation results from (i) Use of the Software in conjunction with any other software; (ii) Use of the Software with an apparatus other than a Designated Unit; (iii) failure to promptly use an update provided by SAP if such infringement or misappropriation could have been avoided by use of the update; or (iv) any Use not permitted by this Agreement. This obligation of SAP also shall not apply if Licensee fails to timely notify SAP in writing of any such claim; however Licensee’s failure to provide or delay in providing such notice shall not relieve SAP of its obligations under this Section except to the extent SAP is prejudiced by Licensee’s failure to provide or delay in providing such notice. SAP is permitted to control fully the defense and any settlement of any such claim as long as such settlement shall not include a financial obligation on or admission of liability by Licensee. In the event Licensee declines SAP’s proffered defense, or otherwise fails to give full control of the defense to SAP’s designated counsel, then Licensee waives SAP’s obligations under this Section 8.1. Licensee shall reasonably cooperate in the defense of such claim and may appear, at its own expense, through counsel reasonably acceptable to SAP. SAP expressly reserves the right to cease such defense of any claim(s) in the event the Software is no longer alleged to infringe or misappropriate, or is held not to infringe or misappropriate, the third party’s rights. SAP may settle or mitigate damages from any claim or potential claim by substituting alternative substantially equivalent non-infringing programs and supporting documentation for the Software. Licensee shall not undertake any action in response to any infringement or misappropriation, or alleged infringement or misappropriation of the Software that is prejudicial to SAP’s rights.
Indemnification and Defense 16.1 To the fullest extent permitted by California law, Developer shall indemnify, keep and hold harmless the District, the Architect(s) and Construction Manager(s), their respective consultants, separate contractors, board members, officers, representatives, agents, and employees, in both individual and official capacities (“Indemnitees”), against all suits, claims, injury, damages, losses, and expenses (“Claims”), including but not limited to attorney’s fees and costs, caused by, arising out of, resulting from, or incidental to, in whole or in part, the performance of the Work under this Contract by Developer or its Subcontractors, vendors and/or suppliers. However, Developer’s indemnification and hold harmless obligation shall be reduced by the proportion of the Indemnitees’ and/or Architect’s liability to the extent the Claim(s) is/are caused wholly by the active negligence or willful misconduct of the Indemnitees, and/or defects in design furnished by the Architect, as found by a court or arbitrator of competent jurisdiction. This indemnification and hold harmless obligation of Developer shall not be construed to negate, abridge, or otherwise reduce any right or obligation of indemnity that would otherwise exist or arise as to any Indemnitee or other person described herein. This indemnification and hold harmless obligation includes, but is not limited to, any failure or alleged failure by Developer to comply with any law and/or provision of the Contract Documents in strict accordance with their terms, and without limitation, any failure or alleged failure of Developers obligations regarding any stop payment notice actions or liens, including Civil Wage and Penalty Assessments and/or Orders by the DIR.
Litigation and Claims No litigation, claim, investigation, administrative proceeding or similar action (including those for unpaid taxes) against Borrower is pending or threatened, and no other event has occurred which may materially adversely affect Borrower’s financial condition or properties, other than litigation, claims, or other events, if any, that have been disclosed to and acknowledged by Lender in writing.
Cooperation with Investigations You agree to cooperate with us in the investigation of unusual transactions, poor quality transmissions, and resolution of customer claims, including by providing, upon request and without further cost, any originals or copies of items deposited through the Service in your possession and your records relating to such items and transmissions.
Cooperation of the Parties Each Party agrees to cooperate fully in the preparation, filing, and prosecution of any Patent Rights under this Agreement. Such cooperation includes, but is not limited to:
Mediation and jurisdiction 1. The data importer agrees that if the data subject invokes against it third-party beneficiary rights and/or claims compensation for damages under the Clauses, the data importer will accept the decision of the data subject:
Extent of Cooperation (1) Prior to December 31, 2017, Counsel for the Settling Defendants met with Class Counsel in Canada or the United States, to provide an oral evidentiary proffer which included information originating with the Settling Defendants that was not covered by privilege relating to the allegations in the Proceedings. Notwithstanding any other provision of this Settlement Agreement, and for greater certainty, it is agreed that all statements made and information provided by Counsel for the Settling Defendants are privileged, will be kept strictly confidential, may not be directly or indirectly disclosed to any other Person, unless disclosure is ordered by a Court. Further, absent a Court order, Class Counsel will not attribute any factual information obtained from the proffer to the Settling Defendants and/or Counsel for the Settling Defendants. Notwithstanding the foregoing, Class Counsel may: (i) use information obtained from the proffer in the prosecution of the Proceedings, including for the purpose of developing an allocation plan relating to any settlement or judgment proceeds, except the prosecution of any claims against Releasees; and (ii) may rely on such information to certify that, to the best of Class Counsel’s knowledge, information and belief, such information has evidentiary support or will likely have evidentiary support after reasonable opportunity for further investigation or discovery, but, absent a Court Order, the Plaintiffs shall not introduce any information from a proffer into the record or subpoena any Counsel for the Settling Defendants related to a proffer.
Defense of Third Party Claims Upon receipt by the Indemnifying Party of a notice from the Indemnified Party with respect to any claim of a third party against the Indemnified Party, for which the Indemnified Party seeks indemnification hereunder, the Indemnifying Party shall have the right to assume the defense of such claim, and the Indemnified Party shall cooperate to the extent reasonably requested by the Indemnifying Party in defense or prosecution thereof and shall furnish such records, information and testimony and attend all such conferences, discovery proceedings, hearings, trials and appeals as may be reasonably requested by the Indemnifying Party in connection therewith. If the Indemnifying Party shall elect to assume the defense of such claim, the Indemnified Party shall have the right to employ its own counsel in any such case, but the fees and expenses of such counsel shall be at the expense of the Indemnified Party. If the Indemnifying Party has assumed the defense of any claim against the Indemnified Party, the Indemnifying Party shall have the right to settle any claim for which indemnification has been sought and is available hereunder; provided that, to the extent that such settlement requires the Indemnified Party to take, or prohibits the Indemnified Party from taking, any action or purports to obligate the Indemnified Party, then the Indemnifying Party shall not settle such claim without the prior written consent of the Indemnified Party, such consent not to be unreasonably withheld, conditioned or delayed. If the Indemnifying Party does not assume the defense of a third party claim and disputes the Indemnified Party’s right to indemnification, the Indemnified Party shall have the right to assume control of the defense of such claim through counsel of its choice, the reasonable costs of which shall be at the Indemnifying Party’s expense in the event that the Indemnified Party’s right of indemnification is ultimately established through settlement, compromise or other legal proceeding. In no circumstance may the Indemnified Party compromise or settle a claim with a third party for which it seeks indemnification from the Indemnifying Party without first obtaining the prior written consent of the Indemnifying Party, such consent not to be unreasonably withheld, conditioned or delayed.
Defense of Claims Subject to the provisions of applicable policies of directors’ and officers’ liability insurance, if any, the Company shall be entitled to participate in the defense of any Indemnifiable Claim or to assume or lead the defense thereof with counsel reasonably satisfactory to the Indemnitee; provided that if Indemnitee determines, after consultation with counsel selected by Indemnitee, that (a) the use of counsel chosen by the Company to represent Indemnitee would present such counsel with an actual or potential conflict, (b) the named parties in any such Indemnifiable Claim (including any impleaded parties) include both the Company and Indemnitee and Indemnitee shall conclude that there may be one or more legal defenses available to him or her that are different from or in addition to those available to the Company, (c) any such representation by such counsel would be precluded under the applicable standards of professional conduct then prevailing, or (d) Indemnitee has interests in the claim or underlying subject matter that are different from or in addition to those of other Persons against whom the Claim has been made or might reasonably be expected to be made, then Indemnitee shall be entitled to retain separate counsel (but not more than one law firm plus, if applicable, local counsel in respect of any particular Indemnifiable Claim for all indemnitees in Indemnitee’s circumstances) at the Company’s expense. The Company shall not be liable to Indemnitee under this Agreement for any amounts paid in settlement of any threatened or pending Indemnifiable Claim effected without the Company’s prior written consent. The Company shall not, without the prior written consent of the Indemnitee, effect any settlement of any threatened or pending Indemnifiable Claim which the Indemnitee is or could have been a party unless such settlement solely involves the payment of money and includes a complete and unconditional release of the Indemnitee from all liability on any claims that are the subject matter of such Indemnifiable Claim. Neither the Company nor Indemnitee shall unreasonably withhold its consent to any proposed settlement; provided that Indemnitee may withhold consent to any settlement that does not provide a complete and unconditional release of Indemnitee.
Civil Actions Except when the Joint Committee established under Article 28 considers that there has been flagrant or wilful negligence on the part of an employee, the Employer agrees not to seek indemnity against an employee whose actions result in a judgement against the Employer. The Employer agrees to pay any judgement against an employee arising out of the performance of their duties. The Employer also agrees to pay any legal costs incurred in the proceedings including those of the employee.
