Excusable Delays Except with respect to defaults of subproviders, the Engineer shall not be in default by reason of any failure in performance of this contract in accordance with its terms (including any failure to progress in the performance of the work) if such failure arises out of causes beyond the control and without the default or negligence of the Engineer. Such causes may include, but are not restricted to, acts of God or the public enemy, acts of the Government in either its sovereign or contractual capacity, fires, floods, epidemics, quarantine restrictions, strikes, freight embargoes, and unusually severe weather.
Excusable Delay The parties shall not be obligated to perform and shall not be deemed to be in default hereunder, if the performance of a non-monetary obligation required hereunder is prevented by the occurrence of any of the following, other than as the result of the financial inability of the party obligated to perform: acts of God, strikes, lock-outs, other industrial disturbances, acts of a public enemy, war or war-like action (whether actual, impending or expected and whether de jure or de facto), acts of terrorists, arrest or other restraint of government (civil or military), blockades, insurrections, riots, epidemics, landslides, lightning, earthquakes, fires, hurricanes, storms, floods, washouts, sink holes, civil disturbances, explosions, breakage or accident to equipment or machinery, confiscation or seizure by any government or public authority, nuclear reaction or radiation, radioactive contamination or other causes, whether of the kind herein enumerated or otherwise, that are not reasonably within the control of the party claiming the right to delay performance on account of such occurrence.
Requests for Exclusion (Opt-Outs) 8.5.1 Class Members who wish to exclude themselves (opt-out of) the Class Settlement must send the Administrator, by fax, email, or mail, a signed written Request for Exclusion not later than 60 days after the Administrator mails the Class Notice (plus an additional 14 days for Class Members whose Class Notice is re-mailed). A Request for Exclusion is a letter from a Class Member or his/her representative that reasonably communicates the Class Member’s election to be excluded from the Settlement and includes the Class Member’s name, address and email address or telephone number. To be valid, a Request for Exclusion must be timely faxed, emailed, or postmarked by the Response Deadline. 8.5.2 The Administrator may not reject a Request for Exclusion as invalid because it fails to contain all the information specified in the Class Notice. The Administrator shall accept any Request for Exclusion as valid if the Administrator can reasonably ascertain the identity of the person as a Class Member and the Class Member’s desire to be excluded. The Administrator’s determination shall be final and not appealable or otherwise susceptible to challenge. If the Administrator has reason to question the authenticity of a Request for Exclusion, the Administrator may demand additional proof of the Class Member’s identity. The Administrator’s determination of authenticity shall be final and not appealable or otherwise susceptible to challenge. 8.5.3 Every Class Member who does not submit a timely and valid Request for Exclusion is deemed to be a Participating Class Member under this Agreement, entitled to all benefits and bound by all terms and conditions of the Settlement, including the Participating Class Members’ Releases under Paragraphs 6.2 and
Requests for Extension The Borrower may, by notice to the Administrative Agent (who shall promptly notify the Lenders) not earlier than 90 days and not later than 35 days prior to an anniversary of the Closing Date (each, an “Applicable Anniversary Date”), request that each Lender extend such Lender’s Maturity Date for an additional year from the Maturity Date then in effect for such Lender hereunder (such Lender’s “Existing Maturity Date”). The Borrower may request such an extension no more than two times.
Indemnification for Expenses as a Witness Notwithstanding any other provision of this Agreement except for Section 26 hereof, to the extent that Indemnitee is, by reason of his Corporate Status, a witness in any Proceeding, he shall be indemnified against all Expenses actually and reasonably incurred by him or on his behalf in connection therewith.
Force Majeure Delays In any case where either party hereto is required to do any act (other than the payment of money), delays caused by or resulting from Acts of God or Nature, war, civil commotion, fire, flood or other casualty, labor difficulties, shortages of labor or materials or equipment, government regulations, delay by government or regulatory agencies with respect to approval or permit process, unusually severe weather, or other causes beyond such party’s reasonable control the time during which act shall be completed, shall be deemed to be extended by the period of such delay, whether such time be designated by a fixed date, a fixed time or “a reasonable time.”
Requests for Exclusion 9.1 The provisions of this section shall apply to any request by a Class Member for exclusion from the Class. 9.2 Any Class Member may make a request for exclusion by submitting such request in writing as set forth in the Notice. 9.3 Any request for exclusion must be submitted no later than the date specified in the Court’s preliminary approval order. 9.4 Any request for exclusion shall (i) state the Class Member’s full name and current address, (ii) provide the model year and Vehicle Identification Number (“VIN”) of his/her/its Class Vehicle(s) and the approximate date(s) of purchase or lease, and (iii) specifically and clearly state his/her/its desire to be excluded from the Settlement and from the Class. 9.5 Failure to comply with these requirements and to timely submit the request for exclusion will result in the Class Member being bound by the terms of the Settlement Agreement. 9.6 Any Class Member who submits a timely request for exclusion may not file an objection to the Settlement and shall be deemed to have waived any rights or benefits under this Settlement Agreement. 9.7 The Settlement Administrator shall report the names of all Class Members who have submitted a request for exclusion to the Parties on a weekly basis, beginning 30 days after the Notice Date. 9.8 Co-Lead Class Counsel represent and warrant that they have no other agreements with other counsel respecting Class Members, including any agreements with respect to referring, soliciting, or encouraging any Class Members to request to be excluded (or “opt out”) from this agreement. 9.9 Upon certification of the Class in connection with the Preliminary Approval of this agreement, Co-Lead Class Counsel agree to seek in the Preliminary Approval Order from the Court a provision encouraging all written communications to multiple Class Members with respect to this Agreement to be reviewed and approved by Co-Lead Class Counsel and the Court, and Co- Lead Class Counsel agree to abide by that provision as may be required by the Court.
INDEMNIFICATION FOR EXPENSES OF A WITNESS Notwithstanding any other provision of this Agreement except for Section 27, to the extent that Indemnitee is, by reason of Indemnitee’s Corporate Status, a witness or deponent in any Proceeding to which Indemnitee was or is not a party or threatened to be made a party, Indemnitee shall, to the fullest extent permitted by applicable law, be indemnified, held harmless and exonerated against all Expenses actually and reasonably incurred by Indemnitee or on Indemnitee’s behalf in connection therewith.
Force Majeure, Notice of Delay, and No Damages for Delay The Contractor will not be responsible for delay resulting from its failure to perform if neither the fault nor the negligence of the Contractor or its employees or agents contributed to the delay and the delay is due directly to acts of God, wars, acts of public enemies, strikes, fires, floods, or other similar cause wholly beyond the Contractor’s control, or for any of the foregoing that affect subcontractors or suppliers if no alternate source of supply is available to the Contractor. In case of any delay the Contractor believes is excusable, the Contractor will notify the Department or Customer in writing of the delay or potential delay and describe the cause of the delay either (1) within 10 days after the cause that creates or will create the delay first arose, if the Contractor could reasonably foresee that a delay could occur as a result, or (2) if delay is not reasonably foreseeable, within five days after the date the Contractor first had reason to believe that a delay could result. The foregoing will constitute the Contractor’s sole remedy or excuse with respect to delay. Providing notice in strict accordance with this paragraph is a condition precedent to such remedy. No claim for damages will be asserted by the Contractor. The Contractor will not be entitled to an increase in the Contract price or payment of any kind from the Department or Customer for direct, indirect, consequential, impact or other costs, expenses or damages, including but not limited to costs of acceleration or inefficiency, arising because of delay, disruption, interference, or hindrance from any cause whatsoever. If performance is suspended or delayed, in whole or in part, due to any of the causes described in this paragraph, after the causes have ceased to exist the Contractor will perform at no increased cost, unless the Department or Customer determines, in its sole discretion, that the delay will significantly impair the value of the Contract to the State of Florida or to Customers, in which case the Department or Customer may (1) accept allocated performance or deliveries from the Contractor, provided that the Contractor grants preferential treatment to Customers with respect to commodities or contractual services subjected to allocation, or (2) purchase from other sources (without recourse to and by the Contractor for the related costs and expenses) to replace all or part of the commodity or contractual services that are the subject of the delay, which purchases may be deducted from the Contract quantity, or (3) terminate the Contract in whole or in part.
Unit Price Work Work to be paid for on the basis of unit prices as defined and described in the Contract Documents. A percentage markup for overhead or profit shall be included in all unit prices.
