Construction Documents The architectural and engineering documents setting forth the design for the Project prepared by the Design Professional. Construction Documents include, but are not limited to, the Specifications, the Drawings, the Supplementary Conditions, the General Conditions, and all Addenda.
Formation Documents With respect to the Issuing Entity, the Certificate of Trust and the Trust Agreement, (ii) with respect to the Grantor Trust, the Grantor Trust Certificate of Trust and the Grantor Trust Agreement, and (iii) with respect to the Depositor, the certificate of formation of the Depositor filed in Delaware, dated as of January 4, 2019 and the amended and restated limited liability company agreement of the Depositor, dated as of March 27, 2019, made by the Sponsor, as member.
Construction Document Phase 1.4.1 Based on the approved Design Development Documents, Guaranteed Maximum Price, coordinated models and any further adjustments in the scope or quality of the Project or in the Amount Available for the Construction Contract authorized by the Owner, the Architect/Engineer shall prepare, for approval by the Owner and review by the Construction Manager, Construction Documents consisting of Drawings, Schedules and Specifications derived from the model(s) in accordance with Owner’s written requirements setting forth in detail the requirements for construction of the Project, including, without limitation, the BIM Execution Plan and “Facility Design Guidelines”. The Plans, Drawings and Specifications for the entire Project shall be so prepared that same will call for the construction of the building and related facilities, together with its built-in permanent fixtures and equipment which will cost not more than the Guaranteed Maximum Price accepted by Owner, or the Amount Available for the Construction Contract established by Owner if no Guaranteed Maximum Price proposal has been accepted by Owner. The Architect/Engineer will be responsible for managing the design to stay within such Guaranteed Maximum Price proposal or Amount Available for the Construction Contract. The Architect/Engineer shall review the Construction Documents as they are being prepared at intervals appropriate to the progress of the Project with the Owner and Construction Manager at the Project site or other location specified by Owner in the State of Texas. The Architect/Engineer shall utilize the model(s) to support the review process during Construction Documents. The Architect/Engineer shall allow the Construction Manager to utilize the information uploaded into Owner’s PMIS to assist the Construction Manager in fulfilling its responsibilities to the Owner.
1.4.2 As a part of Construction Documents Phase, Architect/Engineer shall accomplish model coordination, aggregation and “clash detection” to remove conflicts in design between systems, structures and components. Model coordination shall occur at all reviews during the Construction Documents Phase as identified in the BIM Execution Plan. Architect/Engineer shall utilize Owner’s PMIS to accomplish model coordination and collaborate with Construction Manager in the resolution of critical clashes identified by the Construction Manager. Architect/Engineer shall demonstrate and provide written assurance to Owner that conflicts/collisions between models have been resolved.
1.4.3 The Architect/Engineer shall consult with the Owner and Construction Manager on matters such as construction phasing and scheduling, bid or proposal alternates, liquidated damages, the construction contract time period, and other construction issues appropriate for the Project. The Architect/Engineer shall assist the Owner and Construction Manager in the preparation of the necessary bidding information, bidding forms, RFP information, and RFP forms, and the Conditions of the Contract.
1.4.4 The Architect/Engineer shall assist the Owner in connection with the Owner’s responsibility and procedures for obtaining approval of all building and accessibility authorities having jurisdiction over the Project.
1.4.5 The Architect/Engineer shall provide coordination and inclusion of sequence of operations for all operable systems in the facility as defined by Owner during Design Development.
1.4.6 The Architect/Engineer shall review the Estimated Construction Cost prepared by the Construction Manager, and shall provide written comments.
1.4.7 The Architect/Engineer shall participate in a final review of the Construction Documents and model(s) with the Owner and Construction Manager at the Project location or other location specified by Owner in the State of Texas. Prior to the Owner’s approval of the Construction Documents, the Architect/Engineer shall incorporate such changes as are necessary to satisfy the Owner’s review comments.
1.4.8 The Architect/Engineer shall provide a list of all manufacturer warranties and submittals that are required by their specification.
1.4.9 Before proceeding into the Bidding and Proposal Phase, the Architect/Engineer shall obtain Owner’s written acceptance of the Construction Documents and approval of the Final Amount Available for the Construction Contract as approved by the Board of Regents.
Authorization Documents For each Loan Party, such Person’s (a) charter (or similar formation document), certified by the appropriate governmental authority; (b) good standing certificates in its state of incorporation (or formation) and in each other state requested by the Administrative Agent; (c) bylaws (or similar governing document); (d) resolutions of its board of directors (or similar governing body) approving and authorizing such Person’s execution, delivery and performance of the Loan Documents to which it is party and the transactions contemplated thereby; and (e) signature and incumbency certificates of its officers executing any of the Loan Documents (it being understood that the Administrative Agent and each Lender may conclusively rely on each such certificate until formally advised by a like certificate of any changes therein), all certified by its secretary or an assistant secretary (or similar officer) as being in full force and effect without modification.
Construction Documents Phase Services 3.4.1 Based on the Owner’s approval of the Design Development Documents, and on the Owner’s authorization of any adjustments in the Project requirements and the budget for the Cost of the Work, the Architect shall prepare Construction Documents for the Owner’s approval. The Construction Documents shall illustrate and describe the further development of the approved Design Development Documents and shall consist of Drawings and Specifications setting forth in detail the quality levels and performance criteria of materials and systems and other requirements for the construction of the Work. The Owner and Architect acknowledge that, in order to perform the Work, the Contractor will provide additional information, including Shop Drawings, Product Data, Samples and other similar submittals, which the Architect shall review in accordance with Section 3.6.4.
Supporting Documentation Upon request, the HSP will provide the LHIN with proof of the matters referred to in this Article.
Licensed Documentation If commercially available, Licensee shall have the option to require the Contractor to deliver, at Contractor’s expense: (i) one (1) hard copy and one (1) master electronic copy of the Documentation in a mutually agreeable format; (ii) based on hard copy instructions for access by downloading from the Internet
Organization Documents The Administrative Agent shall have received: (i) a copy of the Organization Documents, including all amendments thereto, of each Loan Party, certified as of a recent date by the Secretary of State or other applicable Governmental Authority of its respective jurisdiction of organization to the extent applicable; (ii) a certificate as to the good standing (or comparable status) of each Loan Party from such Secretary of State or other applicable Governmental Authority of its respective jurisdiction of organization, as of a recent date; (iii) a certificate of the Secretary or Assistant Secretary or other applicable Responsible Officer of each Loan Party dated the Closing Date and certifying (A) that, in the case of the Borrower and any Guarantor, the Organization Documents of such Loan Party have not been amended since the date of the last amendment thereto shown on the certificate of good standing or comparable status from its jurisdiction of organization furnished pursuant to clause (ii) above and remains in full force and effect; (B) that attached thereto is a true and complete copy of the Organization Documents as in effect on the Closing Date, (C) that attached thereto is a true and complete copy of resolutions duly adopted by the Board of Directors (or equivalent governing body) of such Loan Party authorizing the execution, delivery and performance of the Loan Documents to which it is to be a party and, in the case of the Borrower, the borrowings hereunder, and that such resolutions have not been modified, rescinded or amended and are in full force and effect and are the only resolutions authorizing the execution, delivery and performance of the Loan Documents; and (D) as to the incumbency and specimen signature of each Responsible Officer executing any Loan Document; and (iv) a certificate of another officer as to the incumbency and specimen signature of the Secretary or Assistant Secretary or other applicable Responsible Officer executing the certificate pursuant to clause (iii) above.
Acquisition Documents Borrower shall fully perform in all material respects all of its obligations under all Acquisition Documents, and shall enforce all of its rights and remedies thereunder as it deems appropriate in its reasonable business judgment; provided, however, that Borrower shall not take any action or fail to take any action which would result in a waiver or other loss of any material right or remedy of Borrower thereunder. Without limiting the generality of the foregoing, Borrower shall take all action necessary or appropriate to permit, and shall not take any action which would have a Material Adverse Effect upon, the full enforcement of all indemnification rights under all the Acquisition Documents. Borrower shall not, without Administrative Agent's prior written consent, modify, amend, supplement, compromise, satisfy, release or discharge any material provision of the Acquisition Documents, any material collateral securing the same, any Person liable directly or indirectly with respect thereto, or any material agreement relating to the Acquisition Documents or the collateral therefor. Borrower shall notify Administrative Agent in writing promptly after Borrower becomes aware thereof, of any event or fact which could give rise to a claim by it for indemnification under any of the Acquisition Documents to the extent such claims in the aggregate exceed $100,000.00, and shall diligently pursue such right and report to Administrative Agent on all further developments with respect thereto. If an Event of Default then exists, Borrower shall remit directly to Administrative Agent, for application to the Loan Obligations in such order as Administrative Agent determines, all amounts received by Borrower as indemnification or otherwise pursuant to the Acquisition Documents. If Borrower fails after Administrative Agent's demand to pursue diligently any right under any of the Acquisition Documents, or if an Event of Default then exists, then Administrative Agent may directly enforce such right in its own or Borrower's name and may enter into such settlements or other agreements with respect thereto as Administrative Agent determines. Notwithstanding the foregoing, Borrower shall at all times remain liable to observe and perform all of its duties and obligations under all the Acquisition Documents, and Administrative Agent's exercise of any of its rights with respect to the Collateral shall not release Borrower from any of such duties or obligations. Administrative Agent shall not be obligated to perform or fulfill any of Borrower's duties or obligations under any of the Acquisition Documents or to make any payment thereunder, or to make any inquiry as to the sufficiency of any payment or property received by it thereunder or the sufficiency of performance by any party thereunder, or to present or file any claim, or to take any action to collect or enforce any performance or payment of any amounts, or any delivery of any property.
Closing Documentation (a) At Closing, Seller shall execute and deliver to Buyer the following documents in the forms attached hereto as Exhibits C through H:
(i) a special warranty deed (the “Deed”) conveying to Buyer fee simple title to the Land and Improvements, free and clear of all liens, charges and encumbrances, except: (A) ad valorem real property taxes for the calendar year of sale, to the extent not yet due and payable (to be prorated as of the Closing Date), (B) the rights of Buyer as tenant under the Lease (which tenancy shall be deemed merged into Buyer’s fee title), and (C) such other matters as are approved by Buyer, or not objected to in a timely manner under Paragraph 7 (collectively, the “Permitted Encumbrances”);
(ii) a xxxx of sale by which Seller transfers to Buyer the FF&E (the “Xxxx of Sale”);
(iii) a general assignment of the Contracts, Licenses and Warranties, to the extent the same may be assignable (the “General Assignment”) (provided that Seller shall cooperate with Buyer to obtain the benefit of any Contracts, Licenses and Warranties which are not assignable);
(iv) a settlement statement (the “Settlement Statement”) reflecting any applicable adjustments to the Purchase Price and the appropriate receipts and disbursements on behalf of the Parties;
(v) an owner’s affidavit in form reasonably acceptable to Buyer and the Title Company (defined in Paragraph 7) affirming that there are no outstanding possessory rights, liens or rights to claim liens against the Property, except for the Permitted Encumbrances, and any other certificates or affidavits reasonably required by the Title Company;
(vi) a certificate confirming that Seller is not a “foreign person” within the meaning of the Foreign Investment in Real Property Tax Act, and containing information necessary to complete an IRS Form 1099;
(vii) a closing certificate from Seller certifying that all of the representations and warranties contained in Paragraph 12(a) of this Agreement are true and correct as of the Closing Date; and
(viii) documents evidencing the due organization and valid existence of Seller and the authority of the designated representative of Seller to execute and deliver the closing documents.
(b) At Closing, Buyer shall execute and deliver to Seller:
(i) the General Assignment;
(ii) the Settlement Statement;
(iii) a statement from Buyer certifying that all of the representations and warranties contained in Paragraph 12(b) of this Agreement are true and correct as of the Closing Date; and
(iv) documents evidencing the due organization and valid existence of Buyer and the authority of the designated representative of Buyer to execute and deliver the closing documents.