Delayed LNTP or NTP Sample Clauses

Delayed LNTP or NTP. In the event Owner fails to: (i) issue LNTP No. 1 in accordance with Section 5.1 on or before March 1, 2022 or (ii) issue NTP in accordance with Section 5.2 on or before July 1, 2022 despite Owner having issued LNTP No. 1 in accordance with Section 5.1 on or before March 1, 2022, then Contractor shall be entitled to an adjustment to the Contract Price and the Guaranteed Substantial Completion Dates if and to the extent caused by such delayed issuance of LNTP No. 1 or NTP, as applicable. Such adjustment shall include cost and schedule impacts caused by, for example, closing of vendor shops, unavailability of or delay in availability of materials (including any delays due to any quotas), labor unavailability, impacts on ability to attract and/or retain qualified labor, as well as escalation and loss of synergies with Contractor’s work under the Stage 2 EPC Agreement. For the avoidance of doubt, any adjustment to the Contract Price or Guaranteed Substantial Completion Dates shall not be based on Contractor’s errors or omissions, a change in technology, or a change in material or Equipment quantities (except where the unavailability of materials, vendors or labor caused by such delayed issuance of LNTP No. 1 or NTP results in necessary changes to Equipment specifications). Contractor shall use commercially reasonable efforts and GECP to mitigate the increase to the Contract Price and the Guaranteed Substantial Completion Dates. Such agreed upon adjustment will be set forth in a Change Order. Contractor shall, at the end of every three (3) Month period thereafter until NTP (if any) is issued by Owner, notify Owner in writing of any impacts such delay has on Contractor’s costs of performance of the Work, including Subcontractor and Sub-subcontractor prices, and Contractor’s ability to perform the Work in accordance with the Agreement, including the Guaranteed Substantial Completion Dates. Contractor shall not be entitled to the relief in this Section 5.2C to the extent the reason for Owner failing to issue NTP is because Contractor failed to provide the Letter of Credit in accordance with Section 9.2A.
Sample 1
AutoNDA by SimpleDocs

Related to Delayed LNTP or NTP

  • Delayed Transfer Employees To the extent that applicable Law or any arrangement with a Governmental Authority prevents the Parties from causing any (a) Honeywell Employee who is intended to be a SpinCo Employee to be employed by a member of the SpinCo Group as of immediately following the Distribution as contemplated by Section 2.01 or (b) SpinCo Employee who is intended to be a Honeywell Employee to be employed by a member of the Honeywell Group as of immediately following the Distribution (each such employee, a “Delayed Transfer Employee” and the SpinCo Group or Honeywell Group entity to which such Delayed Transfer Employee is intended to be transferred, the “Destination Employer”), the Parties shall use commercially reasonable efforts to ensure that (i) such Delayed Transfer Employee becomes employed by the Destination Employer at the earliest time permitted by applicable Law or such agreement with a Governmental Authority and (ii) the Destination Employer receives the benefit of such Delayed Transfer Employee’s services from and after the Distribution, including under the TSA or by entering into an employee leasing or similar arrangement. “Delayed Transfer Employee” shall also include any Honeywell Employee who, following the Distribution, provides services to the SpinCo Group under the TSA and whose employment is intended by Honeywell to transfer to the SpinCo Group following the completion of the applicable TSA service, and with respect to such Delayed Transfer Employees, the Parties shall use commercially reasonable efforts to ensure that any such Delayed Transfer Employee becomes employed by the SpinCo Group as soon as practicable following the completion of the applicable TSA service. From and after the commencement of a Delayed Transfer Employee’s employment with the Destination Employer, such Delayed Transfer Employee shall be treated for all purposes of this Agreement, including Section 4.02, as if such Delayed Transfer Employee commenced employment with the Destination Employer as of the Distribution as contemplated by Section 2.01.

  • Tax Periods Ending on or Before the Closing Date Buyer shall prepare or cause to be prepared and file or cause to be filed all Tax Returns for the Company and the Company Subsidiary for all periods ending on or prior to the Closing Date which are required to be filed (taking into account all extensions properly obtained) after the Closing Date.

  • No Release; Return or Destruction Each Party agrees not to release or disclose, or permit to be released or disclosed, any information addressed in Section 6.9(a) to any other Person, except its Representatives who need to know such information in their capacities as such (who shall be advised of their obligations hereunder with respect to such information), and except in compliance with Section 6.10. Without limiting the foregoing, when any such information is no longer needed for the purposes contemplated by this Agreement or any Ancillary Agreement, and is no longer subject to any legal hold or other document preservation obligation, each Party will promptly after request of the other Party either return to the other Party all such information in a tangible form (including all copies thereof and all notes, extracts or summaries based thereon) or notify the other Party in writing that it has destroyed such information (and such copies thereof and such notes, extracts or summaries based thereon); provided, that the Parties may retain electronic back-up versions of such information maintained on routine computer system backup tapes, disks or other backup storage devices; provided further, that any such information so retained shall remain subject to the confidentiality provisions of this Agreement or any Ancillary Agreement.

  • CONTRIBUTION IN THE EVENT OF JOINT LIABILITY (a) To the fullest extent permissible under applicable law, if the indemnification, hold harmless and/or exoneration rights provided for in this Agreement are unavailable to Indemnitee in whole or in part for any reason whatsoever, the Company, in lieu of indemnifying, holding harmless or exonerating Indemnitee, shall pay, in the first instance, the entire amount incurred by Indemnitee, whether for judgments, liabilities, fines, penalties, amounts paid or to be paid in settlement and/or for Expenses, in connection with any Proceeding without requiring Indemnitee to contribute to such payment, and the Company hereby waives and relinquishes any right of contribution it may have at any time against Indemnitee.

  • Tax Periods Beginning Before and Ending After the Closing Date The Company or the Purchaser shall prepare or cause to be prepared and file or cause to be filed any Returns of the Company for Tax periods that begin before the Closing Date and end after the Closing Date. To the extent such Taxes are not fully reserved for in the Company’s financial statements, the Sellers shall pay to the Company an amount equal to the unreserved portion of such Taxes that relates to the portion of the Tax period ending on the Closing Date. Such payment, if any, shall be paid by the Sellers within fifteen (15) days after receipt of written notice from the Company or the Purchaser that such Taxes were paid by the Company or the Purchaser for a period beginning prior to the Closing Date. For purposes of this Section, in the case of any Taxes that are imposed on a periodic basis and are payable for a Taxable period that includes (but does not end on) the Closing Date, the portion of such Tax that relates to the portion of such Tax period ending on the Closing Date shall (i) in the case of any Taxes other than Taxes based upon or related to income or receipts, be deemed to be the amount of such Tax for the entire Tax period multiplied by a fraction the numerator of which is the number of days in the Tax period ending on the Closing Date and the denominator of which is the number of days in the entire Tax period (the “Pro Rata Amount”), and (ii) in the case of any Tax based upon or related to income or receipts, be deemed equal to the amount that would be payable if the relevant Tax period ended on the Closing Date. The Sellers shall pay to the Company with the payment of any taxes due hereunder, the Sellers’ Pro Rata Amount of the costs and expenses incurred by the Purchaser or the Company in the preparation and filing of the Tax Returns. Any net operating losses or credits relating to a Tax period that begins before and ends after the Closing Date shall be taken into account as though the relevant Tax period ended on the Closing Date. All determinations necessary to give effect to the foregoing allocations shall be made in a reasonable manner as agreed to by the parties.

  • Shareholder Account Maintenance a. Maintain all shareholder records for each account in the Trust.

  • Director Notification Obligation If the Participant is a director of the Corporation’s Malaysian Affiliate, the Participant is subject to certain notification requirements under the Malaysian Companies Act. Among these requirements is an obligation to notify the Malaysian Affiliate in writing when the Participant receives or disposes of an interest (e.g., an Award or shares) in the Corporation or any related company. Such notifications must be made within 14 days of receiving or disposing of any interest in the Corporation or any related company. MEXICO

  • Transition Seller will not take any action that is designed or intended to have the effect of discouraging any lessor, licensor, customer, supplier, or other business associate of the Company from maintaining the same business relationships with the Company after the Closing as it maintained with the Company prior to the Closing. The Seller will refer all customer inquiries relating to the business of the Company to the Purchaser from and after the Closing.

  • Resignation as L/C Issuer after Assignment Notwithstanding anything to the contrary contained herein, if at any time Bank of America assigns all of its Commitment and Loans pursuant to subsection (b) above, Bank of America may, upon 30 days’ notice to the Borrower and the Lenders, resign as L/C Issuer. In the event of any such resignation as L/C Issuer, the Borrower shall be entitled to appoint from among the Lenders a successor L/C Issuer hereunder; provided, however, that no failure by the Borrower to appoint any such successor shall affect the resignation of Bank of America as L/C Issuer. If Bank of America resigns as L/C Issuer, it shall retain all the rights, powers, privileges and duties of the L/C Issuer hereunder with respect to all Letters of Credit outstanding as of the effective date of its resignation as L/C Issuer and all L/C Obligations with respect thereto (including the right to require the Lenders to make Base Rate Loans or fund risk participations in Unreimbursed Amounts pursuant to Section 2.03(c)). Upon the appointment of a successor L/C Issuer, (a) such successor shall succeed to and become vested with all of the rights, powers, privileges and duties of the retiring L/C Issuer, and (b) the successor L/C Issuer shall issue letters of credit in substitution for the Letters of Credit, if any, outstanding at the time of such succession or make other arrangements satisfactory to Bank of America to effectively assume the obligations of Bank of America with respect to such Letters of Credit.

  • AGREEMENT SURVIVES COMPLETION This agreement (other than obligations that have already been fully performed) remains in full force after Completion.

Time is Money Join Law Insider Premium to draft better contracts faster.