DELAYS / DISRUPTIONS Sample Clauses

DELAYS / DISRUPTIONS. The contractor shall coordinate the work effort with the NSA Project Manager on a daily basis to prevent changing situations from causing delays and disruptions. Disruption due to minor delays in obtaining access to spaces and operation of equipment are to be expected. A minor delay is defined as eight (8) hours or less. These disruptions are considered normal rather than unusual occurrences during the performance of tasks ordered under this contract. If, during contract performance, delays greater than those indicated above are encountered, the Contractor shall immediately verbally notify the Project Manager and Contracting Officer, followed by a written statement within 24 hours after occurrence of delay, stating time of impact, reason for delay, duration of impact, number of people affected, action taken to properly schedule the work, action taken to minimize impact, and the names of the Government person(s) contacted.
AutoNDA by SimpleDocs
DELAYS / DISRUPTIONS. The Contractor shall coordinate the work effort with the NSA Project Manager on a daily basis to prevent changing situations from causing delays and disruptions. Disruption due to minor delays in obtaining access to spaces and operation of equipment are to be expected. A minor delay is defined as eight clock (8) hours or less in duration (and is not the cumulative effect of labor hour impact). Minor delays and/or disruptions are considered normal rather than unusual occurrences during the performance of tasks ordered under these resulting contracts. The Government will not provide any schedule relief for minor delays/disruptions. The burden is on the Contractor to establish a delay/disruption is not minor in nature, by immediate verbal notification to the Project Manager and Contracting Officer, followed by a written statement within 24 hours after occurrence of delay, stating time of impact, reason for delay, duration of impact, number of people affected, action taken to properly schedule the work, action taken to minimize impact, and the names of the Government person(s) contacted, and impact to the critical path and/or controlling work items.
DELAYS / DISRUPTIONS. The contractor shall coordinate the work effort with the SWRMC LCAC Project Manager on a daily basis to prevent changing situations from causing delays and disruptions. Disruption due to minor delays in obtaining access to spaces and operation of equipment are to be expected. A minor delay is defined as eight (8) hours or less. These disruptions are considered normal rather than unusual occurrences during the performance of tasks ordered under this contract. If, during contract performance, delays greater than those indicated above are encountered, the Contractor shall immediately verbally notify the Project Manager and Contracting Officer, followed by a written statement within twenty-four (24) hours after occurrence of delay, stating time of impact, reason for delay, duration of impact, number of people affected, action taken to properly schedule the work, action taken to minimize impact, and the names of the Government person(s) contacted.

Related to DELAYS / DISRUPTIONS

  • H5 Disruption The Contractor shall take reasonable care to ensure that in the performance of its obligations under the Contract it does not disrupt the operations of the Authority, its employees or any other contractor employed by the Authority.

  • Disruption 41.1 The Contractor shall take reasonable care to ensure that in the performance of its obligations under the Framework Agreement it does not disrupt the operations of the Authority, its employees or any other Contractor employed by the Authority. 41.2 The Contractor shall immediately inform the Authority of any actual or potential industrial action, whether such action be by their own employees or others, which affects or might affect its ability at any time to perform its obligations under the Framework Agreement. 41.3 In the event of industrial action by the Staff, the Contractor shall seek Approval to its proposals to continue to perform its obligations under the Framework Agreement. 41.4 If the Contractor’s proposals referred to in clause 41.3 are considered insufficient or unacceptable by the Authority acting reasonably, then the Authority may by notice terminate the Framework Agreement with immediate effect.

  • Delays If no event of Force Majeure shall have occurred and be continuing and in the event that a delay shall have been caused by the negligence or willful misconduct of the Custodian in carrying out an Instruction to credit or transfer cash, the Custodian shall be liable to the Fund: (a) with respect to Principal Accounts, for interest to be calculated at the rate customarily paid on such deposit and currency by the Custodian on overnight deposits at the time the delay occurs for the period from the day when the transfer should have been effected until the day it is in fact effected; and, (b) with respect to Agency Accounts, for interest to be calculated at the rate customarily paid on such deposit and currency by the Subcustodian on overnight deposits at the time the delay occurs for the period from the day when the transfer should have been effected until the day it is in fact effected. The Custodian shall not be liable for delays in carrying out Instructions to transfer cash which are not due to the Custodian's own negligence or willful misconduct.

  • Additional Disruption Events Change in Law: Applicable; provided that Section 12.9(a)(ii) of the Equity Definitions is hereby amended by adding the words “(including, for the avoidance of doubt and without limitation, adoption or promulgation of new regulations authorized or mandated by existing statute)” after the word “regulation” in the second line thereof.

  • Market Disruption (a) If a Market Disruption Event occurs in relation to a Loan for any Interest Period, then the rate of interest on each Lender’s share of that Loan for the Interest Period shall be the percentage rate per annum which is the sum of: (i) the Margin; (ii) the rate notified to the Agent by that Lender as soon as practicable and in any event before interest is due to be paid in respect of that Interest Period, to be that which expresses as a percentage rate per annum the cost to that Lender of funding its participation in that Loan from whatever source it may reasonably select; and (iii) the Mandatory Cost, if any, applicable to that Lender’s participation in the Loan. (b) In this Agreement “Market Disruption Event” means:

  • Force Majeure Delays In any case where either party hereto is required to do any act (other than the payment of money), delays caused by or resulting from Acts of God or Nature, war, civil commotion, fire, flood or other casualty, labor difficulties, shortages of labor or materials or equipment, government regulations, delay by government or regulatory agencies with respect to approval or permit process, unusually severe weather, or other causes beyond such party’s reasonable control the time during which act shall be completed, shall be deemed to be extended by the period of such delay, whether such time be designated by a fixed date, a fixed time or “a reasonable time.”

  • Notification of market disruption The Agent shall promptly notify the Borrowers and each of the Lenders stating the circumstances falling within Clause 5.7 which have caused its notice to be given.

  • Force Majeure Events a) Neither Party shall be responsible or liable for or deemed in breach hereof because of any delay or failure in the performance of its obligations hereunder (except for obligations to pay money due prior to occurrence of Force Majeure events under this Agreement) or failure to meet milestone dates due to any event or circumstance (a "Force Majeure Event") beyond the reasonable control of the Party experiencing such delay or failure, including the occurrence of any of the following: i) acts of God; ii) typhoons, floods, lightning, cyclone, hurricane, drought, famine, epidemic, plague or other natural calamities; iii) acts of war (whether declared or undeclared), invasion or civil unrest; iv) any requirement, action or omission to act pursuant to any judgment or order of any court or judicial authority in India (provided such requirement, action or omission to act is not due to the breach by the SPG or of any Law or any of their respective obligations under this Agreement); v) inability despite complying with all legal requirements to obtain, renew or maintain required licenses or Legal Approvals; vi) earthquakes, explosions, accidents, landslides; fire; vii) expropriation and/or compulsory acquisition of the Project in whole or in part by Government Instrumentality; viii) chemical or radioactive contamination or ionizing radiation; or ix) damage to or breakdown of transmission facilities of GETCO/ DISCOMs; x) Exceptionally adverse weather condition which are in excess of the statistical measure of the last hundred (100) years.

  • Market Disruption Event Section 6.3(a) of the Equity Definitions is hereby replaced in its entirety by the following:

  • FORCE MAJEURE; OTHER CHANGES IN CONDITIONS 19.1 In the event of and as soon as possible after the occurrence of any cause constituting force majeure, the affected Party shall give notice and full particulars in writing to the other Party, of such occurrence or cause if the affected Party is thereby rendered unable, wholly or in part, to perform its obligations and meet its responsibilities under the Contract. The affected Party shall also notify the other Party of any other changes in condition or the occurrence of any event which interferes or threatens to interfere with its performance of the Contract. Not more than fifteen (15) days following the provision of such notice of force majeure or other changes in condition or occurrence, the affected Party shall also submit a statement to the other Party of estimated expenditures that will likely be incurred for the duration of the change in condition or the event of force majeure. On receipt of the notice or notices required hereunder, the Party not affected by the occurrence of a cause constituting force majeure shall take such action as it reasonably considers to be appropriate or necessary in the circumstances, including the granting to the affected Party of a reasonable extension of time in which to perform any obligations under the Contract. 19.2 If the Contractor is rendered unable, wholly or in part, by reason of force majeure to perform its obligations and meet its responsibilities under the Contract, UNDP shall have the right to suspend or terminate the Contract on the same terms and conditions as are provided for in Article 20, “Termination,” except that the period of notice shall be seven (7) days instead of thirty (30) days. In any case, UNDP shall be entitled to consider the Contractor permanently unable to perform its obligations under the Contract in case the Contractor is unable to perform its obligations, wholly or in part, by reason of force majeure for any period in excess of ninety (90) days. 19.3 Force majeure as used herein means any unforeseeable and irresistible act of nature, any act of war (whether declared or not), invasion, revolution, insurrection, terrorism, or any other acts of a similar nature or force, provided that such acts arise from causes beyond the control and without the fault or negligence of the Contractor. The Contractor acknowledges and agrees that, with respect to any obligations under the Contract that the Contractor must perform in areas in which UNDP is engaged in, preparing to engage in, or disengaging from any peacekeeping, humanitarian or similar operations, any delays or failure to perform such obligations arising from or relating to harsh conditions within such areas, or to any incidents of civil unrest occurring in such areas, shall not, in and of itself, constitute force majeure under the Contract.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!