Contract Documents This Contract consists of these Terms and Conditions and the documents ("Exhibits") listed below in descending order of precedence. A conflict in these documents shall be resolved in the priority listed below with these Terms and Conditions taking precedence over all other documents. The Exhibits to this Contract include the following documents:
THE CONTRACT DOCUMENTS The Contract Documents consist of the State-Contractor Agreement, the Conditions of the Contract (General, Supplementary and other Conditions), the Drawings, the Specifications, and all Addenda issued prior to bid opening and any Change Orders after execution of the Contract.
Copies of Contract Documents to Contractor Without charge to the Contractor the Design Professional shall furnish to the Contractor up to five sets of completed Contract Documents in hardcopy, one set of reproducible and electronic background floor and reflected ceiling plan drawings and, if requested, one copy in read-only electronic format. The Contractor may obtain such additional sets of Contract Documents, as the Contractor deems necessary and shall pay the cost of reproduction of such additional sets to the Design Professional.
REVIEW OF CONTRACT DOCUMENTS 4.2.1 The Contractor shall carefully study and compare the Contract Documents and shall immediately report in writing to the Architect and the State any error, inconsistency or omission he may discover. The Contractor shall not be liable to the State or the Architect for any damage resulting from any such errors, inconsistencies or omissions in the Contract Documents. The
Project Contracts Prior to the delivery of this Lease, the Company may have entered into a contract or contracts with respect to the acquisition and/or construction of the Improvements. Those contracts, and any such contracts entered into by the Company after delivery of this Lease are hereinafter referred to as the “Project Contracts.” Prior to the delivery hereof, certain work has been or may have been performed on the Improvements pursuant to said Project Contracts or otherwise. Subject to the Lender’s rights in the Project Contracts, the Company hereby conveys, transfers and assigns to the Issuer all of the Company’s rights in, but not its obligations under the Project Contracts and the Issuer hereby designates the Company as Issuer’s agent for the purpose of executing and performing the Project Contracts. After the execution hereof, the Company shall cause the Project Contracts to be fully performed by the contractor(s), subcontractor(s) and supplier(s) thereunder in accordance with the terms thereof, and the Company covenants to cause the Improvements to be acquired, constructed and/or completed in accordance with the Project Contracts. Any and all amounts received by the Issuer, the Trustee or the Company from any of the contractors or other suppliers by way of breach of contract, refunds or adjustments shall become a part of and be deposited in the Project Fund.
Contractor’s Documents Any licensing and maintenance agreement, or any order-specific agreement or document, including any pre-installation, linked or “click through” agreement that is allowed by, referenced within or incorporated within the Contract whenever the Contract is used for a State procurement, whether directly by the Contractor or through a Contractor’s agent, subcontractor or reseller, is agreed to only to the extent the terms within any such agreement or document do not conflict with the Contract or applicable Minnesota or Federal law, and only to the extent that the terms do not modify, diminish or derogate the terms of the Contract or create an additional financial obligation to the State. Any such agreement or document must not be construed to deprive the State of its sovereign immunity, or of any legal requirements, prohibitions, protections, exclusions or limitations of liability applicable to this Contract or afforded to the State by Minnesota law. A State employee’s decision to choose “accept” or an equivalent option associated with a “click- through” agreement does not constitute the State’s concurrence or acceptance of terms, if such terms are in conflict with this section.
HHSC and Contractor Agreements HHSC and Contractor hereby agree:
A. That in the event any provision of this Contract becomes unenforceable or void all other provisions of this Contract will remain ineffect.
B. That the Contractor may not transfer or assign this Contract without the express prior written approval of HHSC.
C. That this Contract may be assigned to a state agency or agencies.
D. That HHSC may amend this Contract by written notice to the Contractor. HHSC reserves the right to amend this Contract through execution of a unilateral amendment signed by an HHSC person with delegated signature authority and provided to the Contractor under the following circumstances:
1. to correct an obvious clerical error in the Contract;
2. to incorporate new or revised federal or state statutes, rules or policies;
3. to comply with a court order or judgment; and
4. to change the name of the Contractor to reflect the Contractor's name as recorded by the Texas Secretary of State.
E. That nothing in this Contract or any conduct by a representative of HHSC relating to this Contract shall be construed as a waiver of the state's sovereign immunity to suit.
F. That neither party to this Contract waives its right to enforce a right under this Contract by failing to enforce or delaying the enforcement of any other right under this Contract.
G. That the Contractor is an independent contractor and not an employee of HHSC for any purpose. The Contractor and HHSC agreethat:
1. HHSC will not withhold or pay on behalf of the Contractor any sums for income tax, unemployment insurance, Social Security or any other withholding, or make available to the Contractor any of the benefits, including workers' compensation insurance coverage and health and retirement benefits, afforded to HHSC employees; and
2. the Contractor must indemnify HHSC from any liability, including attorneys' fees and legal expenses, incurred by HHSC with respect to claims that HHSC should have been withholding or making payments on behalf of the Contractor or providing benefits to the Contractor's employees.
H. That nothing in this Contract is intended to create a joint venture, a partnership or a principal-agent relationship.
I. That the Contractor assigns to HHSC all claims for overcharges associated with this Contract arising under the anti-trust laws of the United States, 15 U.S.C. §§ 1-38, or the anti-trust laws of the state of Texas, Tex. Bus. & Com. Code, §§ 15.01-.40.
J. That HHSC has authority to monitor and conduct fiscal and program compliance reviews of the Contractor and its subcontractor(s) to the extent of services provided under the terms of this Contract. The Contractor will grant on-site access at reasonable times to all records relating to services provided and payments received under the terms of this Contract to state and federal auditing agencies and personnel and representatives of HHSC and HHS when it is deemed necessary by such agencies for purposes of inspection, monitoring, auditing or evaluating Contractor's performance under this Contract and compliance with applicable state and federal laws, rules and regulations; the applicable HHSC provider handbook or manual; and this Contract. That for Title XX programs, HHSC shall, by Form 2029, Information Worksheet – POS Contract, set the rate or maximum amount of funds or both available to be paid to Contractor by HHSC. Form 2029 is incorporated into and made a part of this Contract and is effective for the time stated on the form. Form 2029 may be amended by HHSC as necessary to comply with state and federal laws and regulations or renewed by HHSC by a new Form 2029 and incorporated into and made part of this Contract.
K. That in compliance with §2262.003, Texas Government Code:
1. the state auditor may conduct an audit or investigation of any entity receiving funds from the state directly under the Contract or indirectly through a subcontract under the Contract;
2. acceptance of funds directly under the Contract or indirectly through a subcontract under the Contract acts as acceptance of the authority of the state auditor, under the direction of the legislative audit committee, to conduct an audit or investigation in connection with those funds; and
3. under the direction of the legislative audit committee, an entity that is the subject of an audit or investigation by the state auditor must provide the state auditor with access to any information the state auditor considers relevant to the investigation or audit.
L. That this Contract shall continue subject to the availability of appropriated funds or until the federal or state governments or both cease to participate in the program.
M. That any breach or violation of any of the provisions of this Contract or state or federal regulations shall make this entire Contract, at HHSC's option, subject to termination.
N. That if HHSC does not renew the Contractor's contract due to the Contractor's noncompliance with applicable federal or Texas statutes or rules, the Contractor cannot enter into another contract for a Community Services program until the application denial period established by HHSC expires.
O. That the venue for any lawsuit between HHSC and the Contractor shall be Travis County, Texas.
P. That this Contract may be terminated by:
Construction Contracts Item A: Enter the total dollar amount of all contacts awarded on the project/ program. Item B: Enter the total dollar amount of contracts connected with this project/program that were awarded to Section 3 businesses.
General Contractor A building, construction, or contracting firm with whom Borrower has contracted or may in the future contract with for the construction of the Improvements pursuant to a certain construction contract between them (the "Construction Contract").
Assignment and Subcontractors Provider shall not assign, sublet, or transfer this Agreement or any rights under or interest in this Agreement without the prior written consent of the DISTRICT, which may be withheld by the DISTRICT in its sole and absolute discretion for any reason. Nothing contained herein shall prevent Provider from employing independent associates, subcontractors, and sub consultants as Provider may deem appropriate to assist in the performance of services herein, subject to the prior written approval of the DISTRICT. Any attempted assignment, sublease, or transfer in violation of this Agreement shall be null and void, and of no force and affect. Any attempted assignment, sublet, or transfer in violation of this Agreement shall be grounds for the DISTRICT, in its sole discretion, to terminate the Agreement.
