Design Standards Most recent edition of the “Owner’s Design Standards,” including any partial updates as may be directed by the Owner.
Maintenance and Support Services If this Agreement is for IT goods or services, this section applies: Unless otherwise specified in this Agreement: The Contractor shall promptly provide the Court with all Upgrades, including without limitation: (i) all Upgrades generally made available by Contractor to its other customers; (ii) Upgrades as necessary so that the Work complies with the Specifications and Applicable Law (including changes in Applicable Law); (iii) Upgrades as necessary so that the Work operates under new versions or releases of the Court’s operating system or database platform; and (iv) all on-site services necessary for installation of Upgrades. Without limiting any other obligation of Contractor under this Agreement, Contractor represents and warrants that it will maintain services, equipment, software or any other part of the Work so that they operate in accordance with their Specifications and Documentation; and The Contractor shall respond to the Court within four (4) hours after the Court reports a Technical Support Incident (such hours all occurring during Standard M&S Hours) to Contractor. DELIVERY, ACCEPTANCE, AND PAYMENT Delivery. Contractor shall deliver to the Court the Deliverables in accordance with this Agreement, including the Statement of Work. Unless otherwise specified by this Agreement, Contractor will deliver all goods purchased by the Court “Free on Board Destination Freight Prepaid” to the Court at the address and location specified by the Court. Title to all goods purchased by the Court vests in the Court upon payment of the applicable purchase price. Contractor will bear the risk of loss for any Work being delivered until received by the Court at the proper location. All shipments by Contractor or its Subcontractors must include packing sheets identifying: this Agreement number, the Court’s purchase order number, item number, quantity and unit of measure, part number and description of the goods shipped, and appropriate evidence of inspection, if required. Goods for different Agreements shall be listed on separate packing sheets.
Uncovering and Correction of Work 12.1 The Contractor shall promptly correct Work rejected by the Owner or failing to conform to the requirements of the Contract Documents, whether observed before or after Substantial Completion and whether or not fabricated, installed or completed, and shall correct any Work found to be not in accordance with the requirements of the Contract Documents within a period of two years from the date of Substantial Completion, or by terms of an applicable special warranty required by the Contract Documents. The provisions of this Article apply to work done by Subcontractors as well as to Work done by direct employees of the Contractor. 12.2 At any time during the progress of the work, or in any case where the nature of the defects shall be such that it is not expedient to have them corrected, the Owner, at their option, shall have the right to deduct such sum, or sums, of money from the amount of the contract as they consider justified to adjust the difference in value between the defective work and that required under contract including any damage to the structure.
Construction Phase Services 3.1.1 – Basic Construction Services
Design Services The Engineer shall perform services during the schematic design phase, the design development phase, the contract documents phase, and the bidding period as hereinafter specified.
Compliance Services (a) If Schedule I contains a requirement for the BNY to provide the Fund with compliance services, such services shall be provided pursuant to the terms of this Section 6 (the “Compliance Services”). The precise compliance review and testing services to be provided shall be as mutually agreed between the BNY and each Fund, and the results of the BNY’s Compliance Services shall be detailed in a compliance summary report (the “Compliance Summary Report”) prepared on a periodic basis as mutually agreed. Each Compliance Summary Report shall be subject to review and approval by the Fund. The BNY shall have no responsibility or obligation to provide Compliance Services other that those services specifically listed in Schedule I. (b) The Fund will examine each Compliance Summary Report delivered to it by the BNY and notify the BNY of any error, omission or discrepancy within ten (10) days of its receipt. The Fund agrees to notify the BNY promptly if it fails to receive any such Compliance Summary Report. The Fund further acknowledges that unless it notifies the BNY of any error, omission or discrepancy within 10 days, such Compliance Summary Report shall be deemed to be correct and conclusive in all respects. In addition, if the Fund learns of any out-of-compliance condition before receiving a Compliance Summary Report reflecting such condition, the Fund will notify the BNY of such condition within one business day after discovery thereof. (c) While the BNY will endeavor to identify out-of-compliance conditions, the BNY does not and could not for the fees charged, make any guarantees, representations or warranties with respect to its ability to identify all such conditions. In the event of any errors or omissions in the performance of Compliance Services, the Fund’s sole and exclusive remedy and the BNY’s sole liability shall be limited to re-performance by the BNY of the Compliance Services affected and in connection therewith the correction of any error or omission, if practicable and the preparation of a corrected report, at no cost to the Fund.
GENERAL SERVICE DESCRIPTION Service Provider currently provides active medical, pharmacy(Rx) and dental administration for coverages provided through Empire and Anthem (medical), Medco(Rx), MetLife(dental) and SHPS (FSA) (Empire, Anthem, Medco, MetLife and SHPS collectively, the “Vendors”) for its U.S. Active, Salaried, Eligible Employees (“Covered Employees”). Service Provider shall keep the current contracts with the Vendors and the ITT CORPORATION SALARIED MEDICAL AND DENTAL PLAN (PLAN NUMBER 502 EIN 00-0000000) and the ITT Salaried Medical Plan and Salaried Dental Plan General Plan Terms (collectively, the “Plans”) and all coverage thereunder in full force through December 31, 2011 for Service Recipient’s Covered Employees. All claims of Service Recipient’s Covered Employees made under the Plans and incurred on or prior to December 31, 2011 the (“2011 Plan Year”) will be adjudicated in accordance with the current contract and Service Provider will continue to take such actions on behalf of Service Recipient’s Covered Employees as if such employees are employees of Service Provider. All medical, dental, pharmacy and FSA claims of Service Recipient’s Covered Employees made under the Plans (the “Claims”) will be paid by the Vendors on behalf of the Service Provider. Service Recipient will pay Service Provider for coverage based on 2011 budget premium rates previously set for the calendar year 2011 and described in the “Pricing” section below. Service Recipient will pay Service Provider monthly premium payments for this service, for any full or partial months, based on actual enrollment for the months covered post-spin using enrollments as of the first (1st) calendar day of the month, commencing on the day after the Distribution Date. Service Recipient will prepare and deliver to Service Provider a monthly self xxxx containing cost breakdown by business unit and plan tier as set forth on Attachment A, within five (5) Business Days after the beginning of each calendar month. The Service Recipient will be required to pay the Service Provider the monthly premium payments within ten (10) Business Days after the beginning of each calendar month. A detailed listing of Service Recipient’s employees covered, including the Plans and enrollment tier in which they are enrolled, will be made available to Service Provider upon its reasonable request. Service Provider will retain responsibility for executing funding of Claim payments and eligibility management with Vendors through December 31, 2013. Service Provider will conduct a Headcount True-Up (as defined below) of the monthly premiums and establish an Incurred But Not Reported (“IBNR”) claims reserve for Claims incurred prior to December 31, 2011 date, but paid after that date, and conduct a reconciliation of such reserve. See “Headcount True-Up” and “IBNR Reconciliation” sections under Additional Pricing for details.
Developer Attachment Facilities Developer shall design, procure, construct, install, own and/or control the Developer Attachment Facilities described in Appendix A hereto, at its sole expense.
Quality Improvement VRC shall develop programs designed to improve the quality of care provided by the Radiologists and encourage identification and adoption of best demonstrated processes. Practice and VRC acknowledge that, in connection with such quality improvement activities, it may be necessary to provide VRC with Protected Health Information and Practice and VRC agree to treat such information in accordance with Article 9;
XXX Hosting 10.1 XXX Hosting is not required for resale in the BellSouth region.