DETERMINATION AND EXTENSION OF CONTRACT TIME FOR COMPLETION Sample Clauses

DETERMINATION AND EXTENSION OF CONTRACT TIME FOR COMPLETION. Contractor shall perform fully, entirely, and in an acceptable manner, the Work contracted for within the time stated in the Contract. If Contractor finds that it will be impossible to complete the Work on or before the date of completion as set forth in the Contract or as previously extended, Contractor shall, not less than ten (10) days prior to said date, make written request to the City for an extension of time for completion, setting forth fully in its request the reasons which Contractor believes justify the granting of the request. If the City finds that the Work has been delayed on account of unusual conditions beyond the control of Contractor, or that the quantities of the Work done or to be done are in excess of the Contract quantities in sufficient amount to warrant additional time, the City may, in its sole discretion, grant an extension of time for the completion to such date as may seem reasonable and proper. In case such extension is not granted, the right to proceed with the Work may be considered as forfeited as of the Contract Time, including all agreed upon adjustments, and the City, without violating the Contract, may proceed immediately to take over the Work, materials and equipment and make final settlement of costs incurred as provided for in Paragraph 7 below, except that it shall not be necessary to give Contractor written ten (10) days’ notice for such forfeiture.
Sample 1Sample 2
AutoNDA by SimpleDocs
DETERMINATION AND EXTENSION OF CONTRACT TIME FOR COMPLETION. 4.7.1. The Contractor shall perform fully, entirely, and in a satisfactory and acceptable manner the Work, within the number of calendar days stipulated in the Contract. Time will be assessed against the Contractor beginning with the actual date the Work is started in accordance with the Notice to Proceed. If the Contractor does not begin the Work within the limit as designated in the Notice to Proceed, the calendar days shall start on the first calendar day after the expiration of the limit as stated in the Notice to Proceed. 4.7.2. In adjusting the Contract time for the completion of the Project, all strikes, lockouts, unanticipated delays in transportation or any condition over which the Contractor has no control, and any suspensions ordered by the Owner for causes not the fault of the Con- tractor, shall be excluded from the computation of the Contract time for completion of the Work and the Owner may extend the time for completion in such amount as the conditions justify. In order to secure an extension of time for delays beyond his control, the Contractor, shall within ten (10) days from the beginning of any such delay, notify the Owner in writing of the causes of delay, where upon the Owner shall ascertain the facts and the extent of the delay and extend the time for completing the Work when, in his judgment, the findings of fact justify such an extension, and his finding of fact thereon shall be final and conclusive. No allowances will be made for delays or suspensions of the performance of the Work which are in the control of the Contractor. 4.7.3. If the satisfactory execution and completion of the Contract shall require Work or materials in greater amounts or quantities than those set forth in the Contract, then the Contract time shall automatically be increased in the same proportion as the cost of the additional Work bears to the original Work contracted for.
Sample 1

Related to DETERMINATION AND EXTENSION OF CONTRACT TIME FOR COMPLETION

  • Extension of Contract The Director of Procurement Services may, with the consent of the contractor extend the Contract period beyond the indicated expiration date.

  • EXPIRATION DATE AND EXTENSION This Contract expires December 5, 2024, unless it is terminated sooner pursuant to Article XX of the General Terms and Conditions, which are incorporated into this Contract by reference. This Contract allows up to five additional one-year extensions upon the request of Sourcewell and written agreement with Contractor. Sourcewell retains the right to consider additional extensions beyond six years as required under exceptional circumstances.

  • CONDITIONS OF SETTLEMENT, EFFECT OF DISAPPROVAL, CANCELLATION OR TERMINATION 9.1. The Effective Date of this Settlement Agreement shall not occur unless and until each and every one of the following events occurs: (a) This Agreement has been signed by the Parties and Class Counsel, and the individual settlement agreements with Xxxxxxxxx Xxxxx, the heirs of Xxxxx Xxxxx, Xxxxxx Xxxxxxxxx, and Xxxxxx Xxxxxxxx-Xxx have been fully executed; (b) The Court has entered an order granting Preliminary Approval of the Agreement; (c) The Court has entered a Final Approval Order finally approving the Agreement, or a judgment substantially consistent with this Settlement Agreement that has become final and unappealable, following Notice and a Final Approval Hearing, as provided in the Federal Rules of Civil Procedure; and (d) In the event that the Court enters an approval order and final judgment in a form other than that provided above (“Alternative Approval Order”) to which the Parties have consented, that Alternative Approval Order has become final and unappealable. 9.2. If some or all of the conditions specified in Paragraph 9.1 are not met, or in the event that this Settlement Agreement is not approved by the Court, or the settlement set forth in this Agreement is terminated or fails to become effective in accordance with its terms, then this Settlement Agreement shall be canceled and terminated subject to Paragraph 9.3, unless Class Counsel and Defendant’s Counsel mutually agree in writing to proceed with this Agreement. If any Party is in material breach of the terms hereof, any other Party, provided that it is in substantial compliance with the terms of this Agreement, may terminate this Agreement on notice to all other Parties. Notwithstanding anything herein, the Parties agree that the Court’s decision as to the amount of the Illinois Fee Award and Ohio Fee Award to Class Counsel set forth above or the incentive award to the Class Representatives, regardless of the amounts awarded, shall not prevent the Agreement from becoming effective, nor shall it be grounds for termination of the Agreement. 9.3. If this Agreement is terminated or fails to become effective for the reasons set forth in Paragraphs 6.1, 6.2, 9.1, or 9.2 above, the Parties shall be restored to their respective positions in the Action as of the date of the signing of this Agreement. In such event, any Final Approval Order or other order entered by the Court in accordance with the terms of this Agreement shall be treated as vacated, nunc pro tunc, and the Parties shall be returned to the status quo ante with respect to the Actions as if this Agreement had never been entered into, including Defendant’s right to seek to compel arbitration as to the Plaintiffs named in the Second Amended Complaint. 9.4. In the event the Settlement is terminated or fails to become effective for any reason, the Illinois Settlement Fund and Ohio Settlement Fund, together with any earnings thereon at the same rate as earned, less any taxes paid or due, less Settlement Administrative Expenses actually incurred and paid or payable from the Settlement Fund, shall be returned to Defendant or its Insurer within thirty (30) calendar days after written notification of such event in accordance with instructions provided by Defendant’s Counsel to the Settlement Administrator.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!