Owner’s Representative Owner designates the individual listed below as its Owner’s Representative to provide direct interface with Construction Manager with respect to Owner’s responsibilities: Xxxxx Xxxxxx, Owner’s Project Manager.
Contractor’s Representative Contractor hereby designates [***INSERT NAME OR TITLE***], or his or her designee, to act as its representative for the performance of this Agreement (“Contractor’s Representative”). Contractor’s Representative shall have full authority to represent and act on behalf of the Contractor for all purposes under this Agreement. The Contractor’s Representative shall supervise and direct the Services, using his best skill and attention, and shall be responsible for all means, methods, techniques, sequences and procedures and for the satisfactory coordination of all portions of the Services under this Agreement.
Owner’s Representatives 9.1.1 Owner designates the individual listed below as its Senior Representative (“Owner Senior Representative”), which individual has the authority and responsibility for avoiding and resolving disputes under Section 10.2 of the General Conditions: Director Title University of Washington University Facilities Building Box 352205 Xxxxxxx, XX 00000-0000 Phone Email:
Project Representative City shall designate a Project Manager to represent City in coordinating this Project with Consulting Engineer/Architect, with authority to transmit instructions and define policies and decisions of City.
Sellers’ Representative By execution of this Agreement, the Sellers hereby irrevocably and unconditionally appoint Nephron Pharmaceuticals Corporation as the Sellers’ Representative of all Sellers, as the attorney-in-fact for and on behalf of each such Seller, and irrevocably agree that the taking by the Sellers’ Representative of any and all actions and the making of any decisions required or permitted to be taken by it or by a Seller under this Agreement or any Transaction Documents to which the Sellers are a party are hereby authorized and approved in all respects, including without limitation the exercise of the power to (i) receive from Buyer and disburse to Sellers any payments constituting any part of the Purchase Price and receive and disburse from and to any Party or any Third Party which may be contemplated to be made under the Transaction Documents, (ii) agree to, negotiate, enter into settlements and compromises of and comply with orders of courts with respect to any indemnification claims or disputes, (iii) resolve any indemnification claims or disputes, and (iv) take all actions necessary in the judgment of the Sellers’ Representative for the accomplishment of the other terms, conditions and limitations of this Agreement and the Transaction Documents. The Sellers’ Representative has authority and power to act on behalf of the Sellers with respect to this Agreement and the other Transaction Documents and the disposition, settlement or other handling of all indemnification claims, rights or obligations arising from and taken pursuant to this Agreement and the other Transaction Documents. The Sellers irrevocably agree to be bound by all and any such actions taken by the Sellers’ Representative in connection with this Agreement and the other Transaction Documents to which the Sellers are a party, and Sellers and Buyer shall only be required to acknowledge or act upon written communication signed by the Sellers’ Representative. Each Seller agrees that he, she or it has not, and will not, threaten or commence or join any legal action, which term includes, without limitation, any demand for arbitration proceedings and any complaint to any foreign, federal, state or local agency, court or other tribunal, to assert any claim against the Sellers’ Representative or its advisors for acting in such capacity with respect to this Agreement or the other Transaction Documents. If any Seller commences or joins any such prohibited legal action against the Sellers’ Representative, such Seller agrees to promptly indemnify Sellers’ Representative and advisers of Sellers’ THIS EXHIBIT HAS BEEN REDACTED AND IS THE SUBJECT OF A CONFIDENTIAL TREATMENT REQUEST. REDACTED MATERIAL IS MARKED WITH [***] AND HAS BEEN FILED SEPARATELY WITH THE SECURITIES AND EXCHANGE COMMISSION. Representative for all losses, liabilities, reasonable costs or expenses, including without limitation all reasonable fees, disbursements and other charges of attorneys incurred by Sellers’ Representative and/or its advisers in defending such action as well as any monetary judgment obtained against the Sellers’ Representative in such action. The Sellers’ Representative may resign at any time upon 30 days written notice to the Sellers. THIS EXHIBIT HAS BEEN REDACTED AND IS THE SUBJECT OF A CONFIDENTIAL TREATMENT REQUEST. REDACTED MATERIAL IS MARKED WITH [***] AND HAS BEEN FILED SEPARATELY WITH THE SECURITIES AND EXCHANGE COMMISSION.
City’s Representative The City hereby designates Xxx Xxxxx, or his or her designee, to act as its representative for the performance of this Agreement (“City’s Representative”). City’s Representative shall have the power to act on behalf of the City for all purposes under this Contract. Consultant shall not accept direction or orders from any person other than the City’s Representative or his or her designee.
Business Representative You and your Representative individually affirm to Stripe that (a) your Representative is authorised to provide User Information on your behalf and to bind you to this Agreement; and (b) your Representative is an executive officer, director, senior manager or otherwise has significant responsibility for the control, management or direction of your business. Stripe may require you or your Representative to provide additional information or documentation demonstrating your Representative’s authority.
Contractor Representative Contractor designates *** as the Contractor Representative. Notification of a change in Contractor Representative shall be provided in advance, in writing, to Owner. The Contractor Representative is a Key Person.
Project Representatives The Contractor designates the following individual as project representative for all matters concerning this Agreement: Xxxxxxx Xxxxxxx Vice President of Development 000 Xxxxx Xxxxxxxxx, Suite 231 Troy, MI 48084 Phone: 000-000-0000 Email: xxxxxxxx@xxxxxx.xxx The Authority designates the following individual as Contract Administrator/project representative to be the initial point of contact for all matters concerning this Agreement: Xxxx Xxxxxxxxxxxxx Authority Buyer 000 Xxxx Xxxxxxxx Xxxxxx Xxxxxxx, XX 00000 Email: XxxxxxxxxxxxxX0@xxxxxxxx.xxx The Contractor shall contact only the designated Contract Administrator with any Authority-related questions, work requests, etc., as described in this Agreement, as well as any Authority-related questions, work requests, etc., falling outside the scope of this Agreement. Except for changes to the performance schedule (not including the project’s completion date), the designated project representatives shall have no authority to make promises or binding obligations on behalf of the Authority, as such authority rests with the duly authorized persons executing this Agreement.
Parties’ Representatives Both Parties shall ensure that throughout the term of this Agreement, a duly appointed Representative is available for communications between the Parties. The Representatives shall have full authority to deal with all day-to-day matters arising under this Agreement. If a Party’s Representative becomes unavailable, the Party shall promptly appoint another Representative. Acts and omissions of Representatives shall be deemed to be acts and omissions of the Party. Owner and CAISO shall be entitled to assume that the Representative of the other Party is at all times acting within the limits of the authority given by the Representative’s Party. Owner’s Representatives and CAISO’s Representatives shall be identified on Schedule J.
