Development Phase contractual phase initiated with the approval of ANP for the Development Plan and which is extended during the Production Phase while investments in xxxxx, equipment, and facilities for the Production of Oil and Gas according to the Best Practices of the Oil Industry are required.
Design Development Phase 1.3.1 Based on the approved Schematic Design Documents, model(s) and any adjustments to the Program of Requirements, BIM Execution Plan or Amount Available for the Construction Contract authorized by the Owner, the Architect/Engineer shall prepare, for approval by the Owner and review by the Construction Manager, Design Development Documents derived from the model(s) in accordance with Owner’s written requirements to further define and finalize the size and character of the Project in accordance with the BIM Execution Plan, “Facility Design Guidelines” and any additional requirements set forth in Article 15. The Architect/Engineer shall review the Design Development documents as they are being modeled at intervals appropriate to the progress of the Project with the Owner and Construction Manager at the Project site or other location specified by Owner in the State of Texas. The Architect/Engineer shall utilize the model(s) to support the review process during Design Development. The Architect/Engineer shall allow the Construction Manager to utilize the information uploaded into Owner’s PMIS to assist the Construction Manager in fulfilling its responsibilities to the Owner.
1.3.2 As a part of Design Development Phase, Architect/Engineer shall accomplish model coordination, aggregation and “clash detection” to remove conflicts in design between systems, structures and components. Architect/Engineer shall utilize Owner’s PMIS to accomplish model coordination and collaborate with Construction Manager in the resolution of critical clashes identified by the Construction Manager. Architect/Engineer shall demonstrate and provide written assurance to Owner that conflicts/collisions between models have been resolved.
1.3.3 The Architect/Engineer shall review the Estimated Construction Cost prepared by the Construction Manager, and shall provide written comments.
1.3.4 Before proceeding into the Construction Document Phase, the Architect/Engineer shall obtain Owner’s written acceptance of the Design Development documents and approval of the mutually established Amount Available for the Construction Contract and schedule.
1.3.5 The Architect/Engineer shall prepare presentation materials including an animation derived from the model(s) as defined in “Facility Design Guidelines” at completion of Design Development and if so requested shall present same to the Board of Regents at a regular meeting where scheduled within the state.
1.3.6 The Architect/Engineer shall prepare preliminary recommended furniture layouts for all spaces where it is deemed important to substantiate the fulfillment of program space requirements, or to coordinate with specific architectural, mechanical and electrical elements.
1.3.7 Architect/Engineer shall assist the Owner, if requested, with seeking approval of the Project by the Texas Higher Education Coordinating Board (THECB). Such assistance shall include (i) the preparation of a listing of the rooms and square footages in the Project, and (ii) the preparation of project cost information, in accordance with THECB Guidelines. This information shall be provided at the completion of the Design Development Phase when requested by the Owner. The listing of rooms and square footages shall then be updated to reflect any changes occurring during construction and provided to the Owner at Substantial Completion.
1.3.8 At the completion of the Design Development Phase, or such other time as Owner may specify to Architect/Engineer, at Owner’s sole option and discretion, Owner will furnish Architect/Engineer with a Guaranteed Maximum Price proposal prepared by Construction Manager based upon the Design Development documents prepared by the Architect/Engineer and approved by the Owner. The Architect/Engineer shall assist the Owner and endeavor to further and advocate the Owner’s interests in Owner’s communications with the Construction Manager in an effort to develop a Guaranteed Maximum Price proposal acceptable to Owner, in Owner’s sole option and discretion. If the Owner does not accept the Construction Manager’s Guaranteed Maximum Price proposal, the Architect/Engineer shall participate with the Owner and Construction Manager in constructability reviews and shall revise the documents as necessary in order to reach an agreement. If the Construction Manager’s Guaranteed Maximum Price proposal exceeds the Schematic Design Phase Estimated Construction Cost prepared by, or otherwise accepted by the Construction Manager due to an increase in the scope of the Project caused by further development of the design documents by the Architect/Engineer to the extent that such could not be reasonably inferred by the Construction Manager from the Schematic Design documents, and Owner directs Architect/Engineer to revise the documents, the Architect/Engineer shall revise the documents at its own expense so that the Guaranteed Maximum Price proposal for constructing the Project shall not exceed the Owner’s Amount Available for the Construction Contract and any previously approved Estimated Construction Costs. If it is determined to be in the Owner’s best interest, instead of requiring the Architect/Engineer to revise the Drawings and Specifications, the Owner reserves the right to accept a Guaranteed Maximum Price proposal that exceeds the stipulated Amount Available for the Construction Contract. The Architect/Engineer shall analyze the final Guaranteed Maximum Price proposal document, together with its supporting assumptions, clarifications, and contingencies, and shall submit a detailed written analysis of the document to the Owner. Such analysis shall include, without limitation, reference to and explanation of any inaccurate or improper assumptions and clarifications. The A/E will not be required to make revisions to the documents at its own expense under the provisions of this paragraph if the Owner’s rejection of the Guaranteed Maximum Price proposal is not due to a failure of the A/E to provide the services otherwise required herein.
1.3.9 After the Guaranteed Maximum Price has been accepted, the Architect/Engineer shall incorporate necessary revisions into the Design Development documents. The A/E will not be required to make revisions to the documents at its own expense under the provisions of this paragraph if the revisions are required as the result of inaccurate assumptions and clarifications made in the development of the Guaranteed Maximum Price proposal that are not due to a failure of the A/E to provide the services otherwise required herein.
Development of the Project 4.1 TSP's obligations in development of the Project:
a. for procuring and maintaining in full force and effect all Consents, Clearances and Permits, required in accordance with Law for development of the Project;
b. for financing, constructing, owning and commissioning each of the Element of the Project for the scope of work set out in Schedule 1 of this Agreement in accordance with:
i. the Electricity Act and the Rules made thereof;
ii. the Grid Code;
iii. the CEA Regulations applicable, and as amended from time to time, for Transmission Lines and sub-stations: • the Central Electricity Authority (Technical Standards for Connectivity to the Grid) Regulations, 2007; • Central Electricity Authority (Technical Standards for construction of Electrical Plants and Electric Lines) Regulation, 2010; • Central Electricity Authority (Grid Standard) Regulations, 2010; • Central Electricity Authority (Safety requirements for construction, operation and maintenance of Electrical Plants and Electrical Lines) Regulation, 2011; • Central Electricity Authority (Measures relating to Safety and Electricity Supply) Regulation, 2010; • Central Electricity Authority (Technical Standards for Communication System in Power System Operation) Regulations, 2020.
iv. Safety/ security Guidelines laid down by the Government;
v. Prudent Utility Practices, relevant Indian Standards and the Law; not later than the Scheduled COD as per Schedule 2 of this Agreement;
c. for entering into a Connection Agreement with the concerned parties in accordance with the Grid Code.
d. for owning the Project throughout the term of this Agreement free and clear of any encumbrances except those expressly permitted under Article 15 of this Agreement;
e. to co-ordinate and liaise with concerned agencies and provide on a timely basis relevant information with regard to the specifications of the Project that may be required for interconnecting the Project with the Interconnection Facilities;
f. for providing all assistance to the Arbitrators as they may require for the performance of their duties and responsibilities;
g. to provide to the Nodal Agency and CEA, on a monthly basis, progress reports with regard to the Project and its execution (in accordance with prescribed form) to enable the CEA to monitor and co-ordinate the development of the Project matching with the Interconnection Facilities;
h. to comply with Ministry of Power order no. 25-11/6/2018 – PG dated 02.07.2020 as well as other Guidelines issued by Govt. of India pertaining to this;
i. to procure the products associated with the Transmission System as per provisions of Public Procurement (Preference to Make in India) orders issued by Ministry of Power vide orders No. 11/5/2018 - Coord. dated 28.07.2020 for transmission sector, as amended from time to time read with Department for Promotion of Industry and Internal Trade (DPIIT) orders in this regard (Procuring Entity as defined in above orders shall deemed to have included Selected Bidder and/ or TSP). Also, to comply with Department of Expenditure, Ministry of Finance vide Order (Public Procurement No 1) bearing File No. 6/18/2019- PPD dated 23.07.2020, Order (Public Procurement No 2) bearing File No. 6/18/2019-PPD dated 23.07.2020 and Order (Public Procurement No. 3) bearing File No. 6/18/2019-PPD, dated 24.07.2020, as amended from time to time, regarding public procurement from a bidder of a country, which shares land border with India;
j. to submit to Nodal Agency information in the prescribed format [To be devised by Nodal Agency] for ensuring compliance to Article 4.1 i) above.
k. to comply with all its obligations undertaken in this Agreement.
4.2 Roles of the Nodal Agency in implementation of the Project:
4.2.1 Subject to the terms and conditions of this Agreement, the Nodal Agency shall be the holder and administrator of this Agreement and shall inter alia:
a. appoint an Independent Engineer within 90 days of the Effective Date
b. provide letters of recommendation to the concerned Indian Governmental Instrumentality, as may be requested by the TSP from time to time, for obtaining the Consents, Clearances and Permits required for the Project;
c. coordinate among TSP and upstream/downstream entities in respect of Interconnection Facilities; and
d. monitor the implementation of the Agreement and take appropriate action for breach thereof including revocation of guarantees, cancellation of Agreement, blacklisting etc
e. provide all assistance to the Arbitrators as required for the performance of their duties and responsibilities; and
f. perform any other responsibility (ies) as specified in this Agreement.
DEVELOPMENT OR ASSISTANCE IN DEVELOPMENT OF SPECIFICATIONS REQUIREMENTS/ STATEMENTS OF WORK
Development Program A. Development activities to be undertaken (Please break activities into subunits with the date of completion of major milestones)
B. Estimated total development time
Development Diligence Pfizer will use Commercially Reasonable Efforts to Develop (including to seek Regulatory Approval for) at least one (1) Licensed Product in one (1) Major Market Country for each Research Project Target for which Pfizer exercises its Option. Except as provided in Section 2.2 and this Section 3.2.1, Pfizer will have no other diligence obligations with respect to the Development or Regulatory Approval of Licensed Products under this Agreement. For avoidance of doubt, any actions taken by Pfizer’s Affiliates or Sublicensees under this Agreement shall be treated as actions taken by Pfizer in regard to satisfaction of the requirements of this Section 3.2.1.
Development Plan document specifying the work program, schedule, and relevant investments required for the Development and the Production of a Discovery or set of Discoveries of Oil and Gas in the Concession Area, including its abandonment.
Construction Phase Services 3.1.1 – Basic Construction Services
Development Reports Beginning six months after Effective Date and ending on the date of first commercial sale of a Licensed Product in the United States, LICENSEE shall report to Cornell progress covering LICENSEE's (and Affiliate's and Sublicensee's) activities and efforts in the development of rights granted to LICENSEE under this Agreement for the preceding six months. The report shall include, but not be limited to, activities and efforts to develop and test all Licensed Products and obtain governmental approvals necessary for marketing the same. Such semi-annual reports shall be due within sixty days (60) of the reporting period and shall use the form as provided herein as Appendix C.
Development Plans Customer has provided Provider with a report attached hereto as Exhibit D (the “Current Development Plan”) describing in detail, as of January 1, 2017, the planned development, drilling, production, processing, treating, marketing and other activities to take place with respect to Dedicated Production and Customer Injected NGLs for the applicable Development Period. The information contained in the Current Development Plan is, with respect to the first three Years covered by the Current Development Plan, on a Quarter-by-Quarter basis, and with respect to the remaining Years covered by the Current Development Plan, on a Year-by-Year basis. The Current Development Plan attached hereto has been approved by the Parties.
(a) From time to time during each Year of the Term, the Parties shall meet to discuss the planned development, drilling, production, processing, treating, marketing and other activities that Customer expects to take place with respect to Dedicated Production and Customer Injected NGLs for the then-applicable Development Period. Customer and Provider shall each make their respective representatives available to participate in such meetings and discussions. No later than August 1 of each such Year, Customer shall provide (or cause to be provided) to Provider a proposed update of the then-currently agreed Development Plan, prepared on the same basis as the Current Development Plan and describing in detail the planned development, drilling, production, processing, treating, marketing and other activities to take place with respect to Dedicated Production and Customer Injected NGLs for the then-applicable Development Period (any such update, an “Updated Development Plan” and, together with the Current Development Plan, each, a “Development Plan”).
(b) Each proposed Development Plan shall include information as to the following, in each case, broken out, with respect to the first three Years covered by such Development Plan, on a Quarter-by-Quarter basis, and, with respect to the remaining Years covered by such Development Plan, on a Year-by-Year basis:
(i) forward-looking production estimates for the applicable time period covered by such Development Plan for all Customer Gas and Customer Injected NGLs (A) that Customer reasonably and in good faith believes will become owned or Controlled by Customer during the time period covered by such Development Plan, and/or (B) that will be produced from (I) in the aggregate, all Xxxxx then-existing and (II) in the aggregate, all Xxxxx that are expected to be drilled during the time period covered by such Development Plan (each such Well reflected in such Development Plan, a “Planned Well” and, such collective estimates described in subsections (A) and (B), both with respect to a particular Quarter and an entire Year, the “Dedicated Production Estimates”); TERMS IN THIS EXHIBIT HAVE BEEN REDACTED BECAUSE CONFIDENTIAL TREATMENT FOR THOSE TERMS HAS BEEN REQUESTED. THE REDACTED MATERIAL HAS BEEN FILED SEPARATELY WITH THE SECURITIES AND EXCHANGE COMMISSION, AND THE TERMS HAVE BEEN MARKED AT THE APPROPRIATE PLACE WITH TWO ASTERISKS (**).
(ii) (A) each new receipt point (including the location thereof) proposed by Customer with respect to the Dedicated Production Estimate reflected in such Development Plan (each such receipt point, a “Planned Receipt Point”), (B) each Receipt Point at which Customer expects to Tender Customer Gas or Customer Injected NGLs reflected in such Development Plan into the TGP System, and (C) the estimated portion of the Dedicated Production Estimate contained in such Development Plan that Customer expects to Tender at each such Receipt Point and Planned Receipt Point;
(iii) (A) each new delivery point (including the location thereof) proposed by Customer with respect to the Dedication Production Estimate reflected in such Development Plan (each such delivery point, a “Planned Delivery Point”), (B) each Delivery Point at which Customer expects to Nominate Customer Residue Gas or Customer NGLs produced from the Dedicated Production Estimate reflected in such Development Plan to be redelivered to Customer, and (C) the estimated volumes of Customer Residue Gas and Customer NGLs produced from the Dedication Production Estimate contained in such Development Plan that Customer expects to Nominate to each such Delivery Point;
(iv) the earliest date on which each Planned Receipt Point and Planned Delivery Point included in the Development Plan is required by Customer to be placed into service, which date shall not be earlier than three Months after the January 1st that is immediately subsequent to the date that the Development Plan that initially reflected such Planned Receipt Point or Planned Delivery Point was delivered to Provider hereunder;
(v) the anticipated characteristics of the production from the Xxxxx and Planned Xxxxx reflected in such Development Plan (including liquids content and gas and liquids composition) and the projected production volumes and production pressures applicable thereto; provided that Customer may utilize the existing and historical production information from similarly situated Xxxxx;
(vi) any (A) proposed revision to the then-existing Dedicated Area and/or any then-existing Dedicated Contract and/or (B) any new contract that Customer proposes to be a Dedicated Contract; and
(vii) other information reasonably requested by Provider that is relevant to the design, construction, and operation of the TGP System, including (A) any applicable Plant Expansion or Facilities Modification proposed by Customer, (B) the relevant Receipt Point and Planned Receipt Point facilities applicable to such Development Plan, and (C) the relevant Delivery Point and Planned Delivery Point facilities applicable to such Development Plan. TERMS IN THIS EXHIBIT HAVE BEEN REDACTED BECAUSE CONFIDENTIAL TREATMENT FOR THOSE TERMS HAS BEEN REQUESTED. THE REDACTED MATERIAL HAS BEEN FILED SEPARATELY WITH THE SECURITIES AND EXCHANGE COMMISSION, AND THE TERMS HAVE BEEN MARKED AT THE APPROPRIATE PLACE WITH TWO ASTERISKS (**).
