Disaster In the event the leased premises are destroyed or injured by fire, earthquake or other casualty so as to render the premises unfit for occupancy, and the Lessor(s) neglects and/or refuses to restore said premises to their former condition, then the Lessee may terminate this Lease and shall be reimbursed for any unearned rent that has been paid. In the event said premises are partially destroyed by any of the aforesaid means, the rent herein agreed to be paid shall be abated from the time of occurrence of such destruction or injury until the premises are again restored to their former condition, and any rent paid by the Lessee during the period of abatement shall be credited upon the next installment(s) of rent to be paid. It is understood that the terms "abated" and "abatement" mean a pro rata reduction of area unsuitable for occupancy due to casualty loss in relation to the total rented area.
Emergency Overtime In the event of an emergency as defined in Section 13.15 notwithstanding the terms of this Article, the Agency Head or designee may assign someone to temporarily meet the emergency requirements, regardless of the overtime distribution.
CONDITIONS FOR EMERGENCY/HURRICANE OR DISASTER - TERM CONTRACTS It is hereby made a part of this Invitation for Bids that before, during and after a public emergency, disaster, hurricane, flood, or other acts of God that Orange County shall require a “first priority” basis for goods and services. It is vital and imperative that the majority of citizens are protected from any emergency situation which threatens public health and safety, as determined by the County. Contractor agrees to rent/sell/lease all goods and services to the County or other governmental entities as opposed to a private citizen, on a first priority basis. The County expects to pay contractual prices for all goods or services required during an emergency situation. Contractor shall furnish a twenty-four (24) hour phone number in the event of such an emergency.
Xxxxx Disaster Protection In accordance with the requirements of the Flood Disaster Protection Act of 1973 (42 U.S.C. 4001), the Subrecipient shall assure that for activities located in an area identified by the Federal Emergency Management Agency (FEMA) as having special flood hazards, flood insurance under the National Flood Insurance Program is obtained and maintained as a condition of financial assistance for acquisition or construction purposes (including rehabilitation).
Emergency Escalation Escalation is strictly for purposes of notifying and investigating possible or potential issues in relation to monitored services. The initiation of any escalation and the subsequent cooperative investigations do not in themselves imply that a monitored service has failed its performance requirements. Escalations shall be carried out between ICANN and Registry Operators, Registrars and Registry Operator, and Registrars and ICANN. Registry Operators and ICANN must provide said emergency operations departments. Current contacts must be maintained between ICANN and Registry Operators and published to Registrars, where relevant to their role in escalations, prior to any processing of an Emergency Escalation by all related parties, and kept current at all times.
Disaster Services In the event of a local, state, or federal emergency, including natural, man-made, criminal, terrorist, and/or bioterrorism events, declared as a state disaster by the Governor, or a federal disaster declared by the appropriate federal official, Grantee may be called upon to assist the System Agency in providing the following services: i. Community evacuation; ii. Health and medical assistance; iii. Assessment of health and medical needs; iv. Health surveillance; v. Medical care personnel; vi. Health and medical equipment and supplies; vii. Patient evacuation; viii. In-hospital care and hospital facility status; ix. Food, drug and medical device safety; x. Worker health and safety; xi. Mental health and substance abuse; xii. Public health information; xiii. Vector control and veterinary services; and xiv. Victim identification and mortuary services.
BUSINESS CONTINUITY/DISASTER RECOVERY In the event of equipment failure, work stoppage, governmental action, communication disruption or other impossibility of performance beyond State Street’s control, State Street shall take reasonable steps to minimize service interruptions. Specifically, State Street shall implement reasonable procedures to prevent the loss of data and to recover from service interruptions caused by equipment failure or other circumstances with resumption of all substantial elements of services in a timeframe sufficient to meet business requirements. State Street shall enter into and shall maintain in effect at all times during the term of this Agreement with appropriate parties one or more agreements making reasonable provision for (i) periodic back-up of the computer files and data with respect to the Trusts; and (ii) emergency use of electronic data processing equipment to provide services under this Agreement. State Street shall test the ability to recover to alternate data processing equipment in accordance with State Street program standards, and provide a high level summary of business continuity test results to the Trusts upon request. State Street will remedy any material deficiencies in accordance with State Street program standards. Upon reasonable advance notice, and at no cost to State Street, the Trusts retain the right to review State Street’s business continuity, crisis management, disaster recovery, and third-party vendor management processes and programs (including discussions with the relevant subject matter experts and an on-site review of the production facilities used) related to delivery of the service no more frequently than an annual basis. Upon reasonable request, the State Street also shall discuss with senior management of the Trusts any business continuity/disaster recovery plan of the State Street and/or provide a high-level presentation summarizing such plan.”
Tenant Delays A "Tenant Delay” shall be defined as any delay in the design, permitting or performance of the Base Building Work to the extent that such delay is actually caused by any act or, where there is a duty to act under this Lease, any failure to act by Tenant or Tenant's contractors, architects, engineers, or anyone else engaged by or on behalf of Tenant in connection with the construction of the Tenant Improvement Work as set forth in this Article III (including, without limitation, any delays resulting from the Approved Tenant Finishes under Section 3.l(C) above) and disclosed to Tenant as hereinafter provided. Notwithstanding the foregoing, in no event shall any delays in the completion of the Base Building Work caused by Tenant’s use of non-union labor constitute a Tenant Delay hereunder. Notwithstanding the foregoing, no event shall be deemed a Tenant Delay unless and until Landlord has given Tenant written notice (the "Tenant Delay Notice") advising Tenant: (x) that a Tenant Delay is occurring and setting forth Landlord's good faith estimate as to the likely length of such Tenant Delay; (y) of the basis on which Landlord has determined that a Tenant Delay is occurring; and (z) the actions which Landlord believes that Tenant must take to eliminate such Tenant Delay. No event shall be deemed to be a Tenant Delay unless and until Tenant has failed to rectify the situation causing the Tenant Delay within forty-eight (48) hours after Tenant's receipt of the Tenant Delay Notice (which for the purposes of determining receipt may be delivered by hand to Tenant's Construction Representative, with copies to follow to Tenant at the notice address set forth in Section 1.2 of this Lease within five (5) days thereafter); provided, however, that if Tenant shall fail to eliminate the delay within the aforesaid 48-hour period, then the 48-hour cure period shall be included in the period of time charged to Tenant pursuant to such Tenant Delay Notice (it being understood and agreed that if Tenant shall in fact eliminate the Tenant Delay within the 48-hour cure period, no Tenant Delay shall be deemed to have occurred for the purposes of this Article III). In addition, any delay to the extent caused by (i) Landlord Delay or (ii) subject to the limitations of subsection (D) below, Tenant's Force Majeure (as defined in said subsection (D)) shall not constitute Tenant Delay. Tenant covenants that no Tenant Delay shall delay commencement of the Term or the obligation to pay Annual Fixed Rent or Additional Rent. The Delivery Dates and/or the date of substantial completion of the Base Building Work, as applicable, shall be deemed to have occurred as of the date when such Delivery Dates and/or date of substantial completion of the Base Building Work, as applicable, would have occurred but for any Tenant Delays, as determined by Landlord in the exercise of its good faith business judgment (it being understood and agreed that the foregoing shall not be construed so as to relieve Landlord of its obligation to actually complete the Base Building Work, notwithstanding the fact that substantial completion may have been deemed to have occurred prior to actual completion as the result of Tenant Delays).
Flood Disaster Protection This contract is subject to the requirements of the Flood Disaster Protection Act of 1973 (P.L.93-234). Nothing included as a part of this contract is approved for acquisition or construction purposes as defined under Section 3(a) of said Act, for use in an area identified by the Secretary of HUD as having special flood hazards which is located in a community not then in compliance with the requirements for participation in the National Flood Insurance Program pursuant to Section 201(d) of said Act; and the use of any assistance provided under this contract for such acquisition for construction in such identified areas in communities then participating in the National Flood Insurance Program shall be subject to the mandatory purchase of flood insurance requirements or Section 102(a) of said Act. Any contract or agreement for the sale, lease, or other transfer of land acquired, cleared or improved with assistance provided under this Contract shall contain, if such land is located in an area identified by the Secretary as having special flood hazards and in which the sale of flood insurance has been made available under the National Flood Insurance Act of 1968, as amended, 42 U.S.C. 4001 et seq., provisions obligating the transferee and its successors or assigns to obtain and maintain, during the ownership of such land, such flood insurance as required with respect to financial assistance for acquisition or construction purposes under Section 102(a) of Flood Disaster Protection Act of 1973.
Noise Abatement Contractor shall operate, conduct, or construct without violating the City’s Noise Abatement Ordinance codified in the SDMC.
