Hiring Procedures Nothing contained in this Article 4 shall impair any of the rights of the Employer to hire new or additional employees to meet the employment needs of the Employer, in accordance with the terms and provisions of this collective bargaining Agreement or to meet the obligations of the Employer under Article 2, Section H of this Agreement or to take affirmative steps to comply with any requirements under any applicable Federal or State law prohibiting discrimination in employment.
Testing Procedures Testing will be conducted by an outside certified Agency in such a way to ensure maximum accuracy and reliability by using the techniques, chain of custody procedures, equipment and laboratory facilities which have been approved by the U.S. Department of Health and Human Services. All employees notified of a positive controlled substance or alcohol test result may request an independent test of their split sample at the employee’s expense. If the test result is negative the Employer will reimburse the employee for the cost of the split sample test.
Safety Procedures The Contractor shall:
(a) comply with all applicable safety regulations according to Attachment H;
(b) take care for the safety of all persons entitled to be on the Site;
(c) use reasonable efforts to keep the Site and Works clear of unnecessary obstruction so as to avoid danger to these persons;
(d) provide fencing, lighting, guarding and watching of the Works until completion and taking over under clause 10 [Employer's Taking Over]; and
(e) provide any Temporary Works (including roadways, footways, guards and fences) which may be necessary, because of the execution of the Works, for the use and protection of the public and of owners and occupiers of adjacent land.
HIRING PROCEDURE 5.1 At the Pre-job Conference the Employer may request and the Local Union shall clear:
5.1.1 Up to ten percent (10%) of the Principal Operators excluding mechanics, required for the job from other Locals of the Union and each such Principal Operator shall be entitled to perform only the work for which he is cleared. Up to one- half (½) of those Principal Operators cleared under this provision may commence employment at the start of the Right-of-Way operations and the balance of those Principal Operators cleared under this provision may commence employment not prior to the start of the Pipe Gang operations.
5.1.2 Up to fifty percent (50%) of the mechanics, utility welders and lubrication and service unit operators required for the job who are members of another Local of the Union. This ratio shall be maintained on a "one-to-one" basis for the duration of the job. The first employee shall be a member of the Local Union having geographic jurisdiction for the job.
5.1.3 The Employer shall have the right to name request by classification up to fifty percent (50%) of the required employees who are members of the Local Union. Those employees hired under the provisions of Article 5.1.1 and 5.1.2 above shall be included in the fifty percent (50%). This ratio shall be maintained on a one-to-one basis for the duration of the job. Thereafter the Employer shall notify the Local Union of all his employee requirements and shall only hire those who have been cleared for work by the Local Union having jurisdiction.
5.2 The Local Union shall be given forty-eight (48) hours exclusive of Saturdays, Sundays, and holidays to supply the required employees but shall advise the Employer of expected delays in dispatching any employees within forty- eight (48) hours. Employees shall be entitled to Waiting Time or Reporting Time upon arrival at the jobsite on the day designated by the Employer for arrival, if no work is provided.
5.3 All employees shall be in possession of a referral slip from the Local Union for identification purposes unless the Local Union otherwise clears an employee for hire by telegram, telex, facsimile transmission or other means of written communication. All out-of-province employees must provide the Local Union having jurisdiction with a copy of a duly authorized Travel Card issued by his/her home Local prior to being issued a referral slip and cleared to work.
5.4 Subject to the terms and conditions of this Agreement, the Employer shall have the right to refuse any referral provided the cause for such refusal is stated and shall not be unreasonable.
5.5 If the Local Union is unable to supply the required employees in accordance with Article 5.2, the Employer may obtain employees elsewhere, subject to the provisions of Article 3.3.
5.6 In the event the Local Union is unable to supply the required qualified employees, the Employer will provide every opportunity to any employee who has successfully completed a pipeline Operating Engineers training course, and is approved by a joint training committee, and the employee will be admitted to membership in the Local Union in accordance with Article
Closing Procedures Subject to satisfaction or waiver by the relevant Party of the conditions of Closing set forth herein, at the Time of Closing the Vendors shall deliver actual possession of the Purchased Shares and the requisite instruments of conveyance and upon such delivery the Purchaser shall pay or satisfy the Purchase Price in accordance with Section 2.03. The transfer of possession of the Purchased Shares shall be deemed to take effect as at the Time of Closing.
Referral Procedures For Local Unions now having a job referral system as contained in their Collective Bargaining Agreement, the Contractor agrees to utilize such system and it shall be used exclusively by such Contractor, except as it may be modified by this Article. Referrals shall not be affected by obligations of Union membership or the lack thereof. Where airport security clearance requirements apply to work to be performed, the Contractor shall inform the Union’s hiring hall dispatcher of those requirements when requesting workers. For those Local Unions having a Book system as part of their Collective Bargaining Agreement, such system will be honored in regards to lay-off of workers from covered projects.
Section 2. In the event that Local Unions are unable to fill any request for employees within the time specified by the local CBAs the Contractor may employ applicants from any other available source. The Contractor shall inform the Union of the name and social security number of any applicants hired from other sources and shall refer the applicant to the Local Union for dispatch to the Covered Project prior to the commencement of work, and make trust fund contributions for every hour worked.
Section 3. There shall be no discrimination against any employee or applicant for employment because of his/her membership or non-membership in the Union or based upon race, creed, color, sex, age or national origin, or any other legally protected class of such employee or applicant.
Section 4. No employee covered by this PLA shall be required to join any Union as a condition of being employed on the Covered Project; provided, however, that an employee who is a member of the referring Union at the time of the referral shall maintain that membership while employed under the PLA. All employees shall, however, be required to comply with the union security provision of the applicable Collective Bargaining Agreement, for the period during which they are performing on-site work, except as modified by this PLA. The Contractor agrees to deduct union dues or representation fees, whichever is applicable, from the pay of any employee who executes a voluntary authorization for such deductions and to remit the dues to the Union or Council. Initiation fees shall be waived for those employees who are not members of any signatory Union when they begin work on this Covered Project. The dues obligations of such employees shall be confined to that portion of union membership dues directly related to representation of workers in collective bargaining, and in enforcement of the Unions’ collective bargaining agreements. Nothing in this Section is intended to eliminate or affect the right of any employee to join the Union or the right of any union to collect full dues from its member.
Section 5. The Parties agree that where a Contractor is not party to a current Collective Bargaining Agreement with the Union having jurisdiction over the affected work, the Contractor may request by name, and the Local will honor, referral of up to a maximum of five (5) persons per each contractor (“core” employees), provided that the Contractor first demonstrate that those persons possess the following qualifications:
(1) Any license required by state or federal law for the Project work to be performed;
(2) Have worked a total of at least one thousand two hundred (1,200) hours in the construction craft during the prior two (2) years;
(3) Were on the Contractor’s active payroll for at least sixty (60) out of the ninety (90) calendar days prior to the contract award;
(4) Have the ability to perform the work safely. The Contractor may elect to hire its first “core” employee to be a xxxxxxx. After the Contractor hires his first core employee, the Union will refer to such Contractor one journeyman employee from the hiring hall out-of-work list for the affected trade or craft, then refer one of such Contractor’s “core” employees as a journeyman, and shall alternate one core employee and one employee from the out-of-work list, until such Contractor’s crew requirements are met or until such Contractor has hired five (5) “core” employees, whichever occurs first. Thereafter, all additional employees in the affected trade or craft shall be hired exclusively from the hiring hall out-of-work list(s). For the duration of the Contractor’s work the ratio of “core” employees to hiring hall referrals shall be maintained and when the Contractor’s workforce is reduced, employees shall be reduced in the same ratio as was applied in the initial hiring. All employees, core and union, shall be dispatched from the appropriate union. Trust benefits shall be paid on all employees, core and union.
Section 6. Upon referral or dispatch from a Union, “turnaround” or refusal of any worker by the Contractors, requires written explanation from the Contractor that shall be communicated through the Prime Contractor to the Port and affected Union within 48 hours.
Section 7. Individual seniority will not be recognized or applied to employees working on the Project. This provision will not interfere with or supersede the use by individual Contractors of “call lists” maintained by such Contractor pursuant to addenda to the local Collective Bargaining Agreement between such Contractor and a Union signatory to this PLA.
Section 8. The selection of craft foremen and/or general foremen and the number of such foremen and/or general foremen required shall be entirely the responsibility of the Contractor. Craft foremen shall be designated working foremen at the request of the Contractor. Craft workers covered by this PLA will, in the normal day- to-day operations, take their direction and supervision from their xxxxxxx.
Standard Operating Procedures Standard Operating Procedures shall not contravene the Canada Labour Code, the Canadian Human Rights Code, or the Collective Agreement, and an allegation of such contravention is subject to the grievance procedure.
Hearing Procedures The hearing shall be held at the earliest convenient date, taking into consideration the established schedule of the Board or hearing officer and the availability of the CSEA representative, counsel and witnesses. The parties shall be notified of the time and place of the hearing after ensuring availability of all necessary parties. The employee shall be entitled to appear personally, produce evidence, and have CSEA representation. The employee shall be entitled to a public hearing if he/she demands it when the Board is hearing the appeal.
18.12.1 The complainant may also be represented by counsel. The procedure entitled "Administrative Adjudication" commencing with Government Code 11500 shall not apply to any such hearing before the Board or a hearing officer. Neither the Board nor a hearing officer shall be bound by rules of evidence used in California courts. Informality in any such hearing shall not invalidate any order or decision made or approved by the hearing officer or the Board.
18.12.2 All hearings shall be heard by a hearing officer (who shall be an attorney licensed in the State of California) except in those cases where the Board determines to hear the appeal itself. In any case in which the Board hears the appeal, the Board may use the services of its counsel or a hearing officer in ruling upon procedural questions, objections to evidence, and issues of law. However, the Board must employ separate counsel from the one presenting the case for the complainant.
18.12.3 If the appeal is heard by the Board, the Board shall affirm, modify or revoke the recommended personnel action.
18.12.4 If the appeal is heard by a hearing officer, he/she shall prepare a proposed decision in a form that may be adopted by the Board as the decision in the case. A copy of the proposed decision shall be received and filed by the Board and furnished to each party within ten days after the proposed decision is filed by the Board. After furnishing the proposed decision to each party, the Board may:
18.1.4.1 Adopt the proposed decision in its entirety.
18.1.4.2 Reduce the personnel action set forth in the proposed decision and adopt the balance of the proposed decision.
18.1.4.3 Reject a proposed reduction in personnel action, approve the disciplinary action sought by the complainant or any lesser penalty, and adopt the balance of the proposed decision.
18.1.4.4 Reject the proposed decision in its entirety.
18.12.5 If the Board rejects the proposed decision in its entirety, each party shall be notified of such action and the Board may decide the case upon the record including the transcript, with or without the taking of additional evidence, or may refer the case to the same or another hearing officer to take additional evidence. If the case is so assigned to a hearing officer, he/she shall prepare a proposed decision, as provided in item Section 18.12.4 above, upon the additional evidence and the transcript and other papers which are part of the record of the prior hearing. A copy of this proposed decision shall be furnished to each party within 10 days after the proposed decision is filed by the Board.
18.12.6 In arriving at a decision or a proposed decision on the propriety of the proposed disciplinary action, the Board or the hearing officer may consider the records of any prior disciplinary action proceedings against the employee in which a disciplinary action was ultimately sustained and any records that were contained in the employee's personnel files and introduced into evidence at the hearing.
Procedures for Providing NP Through Full NXX Code Migration Where a Party has activated an entire NXX for a single Customer, or activated at least eighty percent (80%) of an NXX for a single Customer, with the remaining numbers in that NXX either reserved for future use by that Customer or otherwise unused, if such Customer chooses to receive Telephone Exchange Service from the other Party, the first Party shall cooperate with the second Party to have the entire NXX reassigned in the LERG (and associated industry databases, routing tables, etc.) to an End Office operated by the second Party. Such transfer will be accomplished with appropriate coordination between the Parties and subject to appropriate industry lead times for movements of NXXs from one switch to another. Neither Party shall charge the other in connection with this coordinated transfer.
Function of Joint Health and Safety Committee All incidents involving aggression or violence shall be brought to the attention of the Joint Health and Safety Committee. The Employer agrees that the Joint Health and Safety Committee shall concern itself with all matters relating to violence to staff.