Minimum Site Requirements for TIPS Sales (when applicable to TIPS Sale). Cleanup: When performing work on site at a TIPS Member’s property, Vendor shall clean up and remove all debris and rubbish resulting from their work as required or directed by the TIPS Member or as agreed by the parties. Upon completion of work, the premises shall be left in good repair and an orderly, neat, clean and unobstructed condition. Preparation: Vendor shall not begin a project for which a TIPS Member has not prepared the site, unless Vendor does the preparation work at no cost, or until TIPS Member includes the cost of site preparation in the TIPS Sale Site preparation includes, but is not limited to: moving furniture, installing wiring for networks or power, and similar pre‐installation requirements. Registered Sex Offender Restrictions: For work to be performed at schools, Vendor agrees that no employee of Vendor or a subcontractor who has been adjudicated to be a registered sex offender will perform work at any time when students are, or reasonably expected to be, present unless otherwise agreed by the TIPS Member. Vendor agrees that a violation of this condition shall be considered a material breach and may result in the cancellation of the TIPS Sale at the TIPS Member’s discretion. Vendor must identify any additional costs associated with compliance of this term. If no costs are specified, compliance with this term will be provided at no additional charge. Safety Measures: Vendor shall take all reasonable precautions for the safety of employees on the worksite, and shall erect and properly maintain all necessary safeguards for protection of workers and the public. Vendor shall post warning signs against all hazards created by the operation and work in progress. Proper precautions shall be taken pursuant to state law and standard practices to protect workers, general public and existing structures from injury or damage. Smoking: Persons working under Agreement shall adhere to the TIPS Member’s or local smoking statutes, codes, ordinances, and policies.
FALSE STATEMENTS CONCERNING HIGHWAY PROJECTS T h i s p r o v i s i o n i s applicable to all Federal-aid construction contracts and to all related subcontracts. In order to assure high quality and durable construction in conformity with approved plans and specifications and a high degree of reliability on statements and representations made by engineers, contractors, suppliers, and workers on Federal- aid highway projects, it is essential that all persons concerned with the project perform their functions as carefully, thoroughly, and honestly as possible. Willful falsification, distortion, or misrepresentation with respect to any facts related to the project is a violation of Federal law. To prevent any misunderstanding regarding the seriousness of these and similar acts, Form FHWA-1022 shall be posted on each Federal-aid highway project (23 CFR 635) in one or more places where it is readily available to all persons concerned with the project: 18 U.S.C. 1020 reads as follows: "Whoever, being an officer, agent, or employee of the United States, or of any State or Territory, or whoever, whether a person, association, firm, or corporation, knowingly makes any false statement, false representation, or false report as to the character, quality, quantity, or cost of the material used or to be used, or the quantity or quality of the work performed or to be performed, or the cost thereof in connection with the submission of plans, maps, specifications, contracts, or costs of construction on any highway or related project submitted for approval to the Secretary of Transportation; or Whoever knowingly makes any false statement, false representation, false report or false claim with respect to the character, quality, quantity, or cost of any work performed or to be performed, or materials furnished or to be furnished, in connection with the construction of any highway or related project approved by the Secretary of Transportation; or Whoever knowingly makes any false statement or false representation as to material fact in any statement, certificate, or report submitted pursuant to provisions of the Federal-aid Roads Act approved July 1, 1916, (39 Stat. 355), as amended and supplemented; Shall be fined under this title or imprisoned not more than 5 years or both."
Technical Accuracy Owner shall not be responsible for discovering deficiencies in the technical accuracy of Engineer’s services. Engineer shall correct deficiencies in technical accuracy without additional compensation, unless such corrective action is directly attributable to deficiencies in Owner-furnished information.
Position Descriptions Individual position descriptions shall be reduced to writing and delineate the duties currently assigned to an employee’s position. A dated copy of the position description shall be given to the employee upon assuming the position and when the position description is amended. The individual position description shall be subject to at least an annual review with the employee. Nothing contained herein shall compromise the right or the responsibility of the Agency to assign work consistent with the classification specification.
Minimum Shipping Requirements for TIPS Sales Vendor shall ship, deliver, or provide ordered goods and services within a commercially reasonable time after acceptance of the order. If a delay in delivery is anticipated, Vendor shall notify the TIPS Member as to why delivery is delayed and provide an updated estimated time for completion. The TIPS Member may cancel the order if the delay is not commercially acceptable or not consistent with the Supplemental Agreement applicable to the order.
Corrections to Factual Inaccuracies In the event that the LEA determines that the Provider is maintaining Student Data that contains a factual inaccuracy, and Provider cooperation is required in order to make a correction, the LEA shall notify the Provider of the factual inaccuracy and the correction to be made. No later than 90 calendar days after receiving the notice of the factual inaccuracy, the Provider shall correct the factual inaccuracy and shall provide written confirmation of the correction to the LEA.
Background and Narrative of Budget Reductions 2. Assumptions Used in the Deficit Reduction Plan: - EBF and Estimated New Tier Funding: - Equal Assessed Valuation and Tax Rates: - Employee Salaries and Benefits: - Short and Long Term Borrowing: - Educational Impact: - Other Assumptions: - Has the district considered shared services or outsourcing (Ex: Transportation, Insurance) If yes please explain: ESTIMATED LIMITATION OF ADMINISTRATIVE COSTS (School Districts Only) (For Local Use Only)
Xxxxxxx to Meet Timelines Failure by the Union to comply with the timelines will result in the automatic withdrawal of the grievance. Failure by the Employer to comply with the timelines will entitle the Union to move the grievance to the next step of the procedure.
COMPLETE STATEMENTS 1 THROUGH 5 BELOW 1. This request is for an: Update Amendment See Contract Modification Procedure for an explanation of these terms. 2. The intent of this submittal is to request: Addition of new products or services Deletion of products or services Change in pricing level Other Update Other Amendment
Offense Level Calculations i. The base offense level is 7, pursuant to Guideline § 2B1.1(a)(1).
