Tenant Delay Except as otherwise provided in the Lease, Delivery of the Premises shall occur when Landlord’s Work has been Substantially Completed, except to the extent that completion of Landlord’s Work shall have been actually delayed by any one or more of the following causes (“Tenant Delay”):
(i) Tenant’s Representative was not available to give or receive any Communication or to take any other action required to be taken by Tenant hereunder within a reasonable period of time (not to exceed 2 business days) after written request from Landlord;
(ii) Tenant’s request for changes to the Building Shell, whether or not such changes are actually performed;
(iii) The construction of any changes to the Building Shell requested by Tenant and agreed upon by Landlord;
(iv) Tenant’s request for Change Requests (as defined in Section 4(a) below) whether or not any such Change Requests are actually performed;
(v) Construction of any Change Requests;
(vi) Tenant’s request for materials, finishes or installations requiring unusually long lead times (provided Landlord will request that the General Contractor inform Tenant of any long lead time items and identify substitutes for such items as soon as reasonably possible);
(vii) Tenant’s delay in reviewing, revising or approving plans and specifications beyond the periods set forth herein;
(viii) Tenant’s delay in providing any information that is reasonably required to come from Tenant which is critical to the normal progression of the Project within a reasonable period of time after request. Tenant shall provide such information as soon as reasonably possible, but in no event longer than one week after receipt of any request for such information from Landlord;
(ix) Tenant’s delay in making payments to Landlord for Excess TI Costs (as defined in Section 5(d) below) for more than 10 business days after such Excess TI Costs are required to be paid to Landlord; or
(x) Any other act or omission by Tenant or any Tenant Party (as defined in the Lease), or persons employed by any of such persons that continues for more than 1 business day after Landlord’s notice thereof to Tenant. If Delivery is delayed for any of the foregoing reasons, then Landlord shall cause the TI Architect to certify the date on which the Tenant Improvements would have been Substantially Completed but for such Tenant Delay and such certified date shall be deemed to be the Commencement Date for purposes of Tenant’s obligation to pay Base Rent, Operating Expenses, Excess TI Costs and TI Rent; however, Tenant will not have any obligation to pay any amounts to third parties pursuant to the Lease (and will not occupy the Premises) until the date upon which the Premises is Delivered to Tenant with the Landlord’s Work Substantially Complete. Upon request, Landlord shall advise Tenant of any materials, finishes or installations which are required as part of any Change Request that will result in unusually long lead times.
Tenant Delays A "Tenant Delay” shall be defined as any delay in the design, permitting or performance of the Base Building Work to the extent that such delay is actually caused by any act or, where there is a duty to act under this Lease, any failure to act by Tenant or Tenant's contractors, architects, engineers, or anyone else engaged by or on behalf of Tenant in connection with the construction of the Tenant Improvement Work as set forth in this Article III (including, without limitation, any delays resulting from the Approved Tenant Finishes under Section 3.l(C) above) and disclosed to Tenant as hereinafter provided. Notwithstanding the foregoing, in no event shall any delays in the completion of the Base Building Work caused by Tenant’s use of non-union labor constitute a Tenant Delay hereunder. Notwithstanding the foregoing, no event shall be deemed a Tenant Delay unless and until Landlord has given Tenant written notice (the "Tenant Delay Notice") advising Tenant: (x) that a Tenant Delay is occurring and setting forth Landlord's good faith estimate as to the likely length of such Tenant Delay; (y) of the basis on which Landlord has determined that a Tenant Delay is occurring; and (z) the actions which Landlord believes that Tenant must take to eliminate such Tenant Delay. No event shall be deemed to be a Tenant Delay unless and until Tenant has failed to rectify the situation causing the Tenant Delay within forty-eight (48) hours after Tenant's receipt of the Tenant Delay Notice (which for the purposes of determining receipt may be delivered by hand to Tenant's Construction Representative, with copies to follow to Tenant at the notice address set forth in Section 1.2 of this Lease within five (5) days thereafter); provided, however, that if Tenant shall fail to eliminate the delay within the aforesaid 48-hour period, then the 48-hour cure period shall be included in the period of time charged to Tenant pursuant to such Tenant Delay Notice (it being understood and agreed that if Tenant shall in fact eliminate the Tenant Delay within the 48-hour cure period, no Tenant Delay shall be deemed to have occurred for the purposes of this Article III). In addition, any delay to the extent caused by (i) Landlord Delay or (ii) subject to the limitations of subsection (D) below, Tenant's Force Majeure (as defined in said subsection (D)) shall not constitute Tenant Delay. Tenant covenants that no Tenant Delay shall delay commencement of the Term or the obligation to pay Annual Fixed Rent or Additional Rent. The Delivery Dates and/or the date of substantial completion of the Base Building Work, as applicable, shall be deemed to have occurred as of the date when such Delivery Dates and/or date of substantial completion of the Base Building Work, as applicable, would have occurred but for any Tenant Delays, as determined by Landlord in the exercise of its good faith business judgment (it being understood and agreed that the foregoing shall not be construed so as to relieve Landlord of its obligation to actually complete the Base Building Work, notwithstanding the fact that substantial completion may have been deemed to have occurred prior to actual completion as the result of Tenant Delays).
Base Rental (a) Lessee hereby agrees to pay to Lessor, without setoff or deduction whatsoever, in accordance with the Schedule of Base Rent attached hereto as EXHIBIT D ("Base Rental). Lessee shall also pay, as additional rent [or Forecast Additional Rent ], all such other sums of money as shall become due from and payable by Lessee to Lessor under this Lease (Base Rental, any adjustment thereto pursuant to Section 4 hereof, and all such other sums of money due from and payable by Lessee pursuant to this Lease are sometimes hereinafter collectively called "rent"), for the nonpayment of which Lessor shall be entitled to exercise all such rights and remedies as are herein provided in the case of the nonpayment of Base Rental. The annual Base Rental, together with any adjustment or increase thereto then in effect, shall be due and payable in advance in twelve (12) equal installments on the first 1st day of each calendar month during the term of this Lease, and Lessee hereby agrees so to pay such Base Rental and any adjustment or increase thereto to Lessor at Lessor's address provided herein (or such other address as may be designated by Lessor in writing from time to time) monthly, in advance, and without demand. If the term of this Lease commences on a day other than first (1st) day of a month or terminates on a day other than the last day of a month, then the installments of Base Rental and any adjustments thereto for such month or months shall be prorated, and the installment or installments so prorated shall be paid in advance.
(b) In the event any installment of the Base Rental, or any other sums which may become owing by Lessee to Lessor under the provisions hereof are not received within Five (5) days after the due date thereof (without in any way implying Lessor's consent to such late payment), Lessee, to the extent permitted by law, agrees to pay, in addition to said installment of the Base Rental or such other sums owed, a late payment charge equal to ten percent (10%) (Late Fee) of the installment of the Base Rental or such other sums owed. Notwithstanding the foregoing, the foregoing late charges shall not apply to any sums which have been advanced by Lessor to or for the benefit of Lessee pursuant to the provisions of this Lease, it being understood that such sums shall bear interest, which Lessee hereby agrees to pay to Lessor, at the lesser of fifteen percent (15%) per annum or the maximum rate of interest permitted by law to be charged Lessee for the use or forbearance of such money.
Base Rent Lessee shall pay Base Rent and other rent or charges, as the same may be adjusted from time to time, to Lessor in lawful money of the United States, without offset or deduction, on or before the day on which it is due under the terms of this Lease. Base Rent and all other rent and charges for any period during the term hereof which is for less than one full month shall be prorated based upon the actual number of days of the month involved. Payment of Base Rent and other charges shall be made to Lessor at its address stated herein or to such other persons or at such other addresses as Lessor may from time to time designate in writing to Lessee.
Expansion Premises In addition to the Original Premises, commencing on the Expansion Premises Commencement Date (as defined below), Landlord leases to Tenant, and Tenant leases from Landlord, the Expansion Premises.
Basic Rental Tenant agrees to pay to Landlord during the Term hereof, at Landlord's office or to such other person or at such other place as directed from time to time by written notice to Tenant from Landlord, the monthly and annual sums as set forth in Article 1.C. of the Basic Lease Provisions, payable in advance on the first (1st) day of each calendar month, without demand, setoff or deduction, and in the event this Lease commences or the date of expiration of this Lease occurs other than on the first (1st) day or last day of a calendar month, the rent for such month shall be prorated. Notwithstanding anything to the contrary contained herein and provided that Tenant faithfully performs all of the terms and conditions of this Lease, Landlord hereby agrees to xxxxx Tenant's obligation to pay monthly Basic Rental for the second (2nd) and third (3rd) full calendar months of the initial Lease Term. During such abatement periods, Tenant shall still be responsible for the payment of all of its other monetary obligations under this Lease. In the event of a default by Tenant under the terms of this Lease that results in early termination pursuant to the provisions of Section 20(a) of this Lease, then as a part of the recovery set forth in Article 20 of this Lease, Landlord shall be entitled to the recovery of the monthly Basic Rental that was abated under the provisions of this Section 3(a). The amount of Basic Rental to be abated pursuant to this Section 3(a) above may be referred herein as "Abated Rent Amount." Notwithstanding the foregoing or anything to contrary contained herein, upon written notice to Tenant, Landlord shall have the option to purchase all or any portion of Tenant's Abated Rent Amount by paying such amount to Tenant, in which case the amount so paid to Tenant shall nullify an equivalent amount of abatement of Tenant's Basic Rental as to the period so designated by Landlord in Landlord's written notice to Tenant. In addition, notwithstanding the foregoing, the first full month's Basic Rental shall be paid to Landlord in accordance with Article 1.J. of the Basic Lease Provisions and, if the Commencement Date is not the first day of a month, Basic Rental for the partial month commencing as of the Commencement Date shall be prorated based upon the actual number of days in such month and shall be due and payable upon the Commencement Date.
Basic Rent The periodic rent payable for the Aircraft throughout the Basic Term pursuant to Section 3.02 of the Lease, adjusted pursuant to Article 3 of the Lease. Basic Term. The period commencing at the beginning of the day on the Delivery Date and ending at the end of the day on July 15, 2023, or such earlier date on which the Lease shall be terminated as provided therein.
Monthly Rent a. Commencing as of the Commencement Date, and continuing thereafter on or before the first day of each calendar month during the term hereof, Tenant shall pay to Landlord, as monthly rent for the Premises, the Monthly Rent specified in Paragraph 2 above. If Tenant’s obligation to pay Monthly Rent hereunder commences on a day other than the first day of a calendar month, or if the term of this Lease terminates on a day other than the last day of a calendar month, then the Monthly Rent payable for such partial month shall be appropriately prorated on the basis of a thirty (30)-day month. Monthly Rent and the Additional Rent specified in Paragraph 7 shall he paid by Tenant to Landlord, in advance, without deduction, offset, prior notice or demand, in immediately available funds of lawful money of the United States of America, or by good check as described below, to the lockbox location designated by Landlord, or to such other person or at such other place as Landlord may from time to time designate in writing. Payments made by check must be drawn either on a California financial institution or on a financial institution that is a member of the federal reserve system. Notwithstanding the foregoing, Tenant shall pay to Landlord together with Tenant’s execution of this Lease an amount equal to the Monthly Rent payable for the first full calendar month of the Lease term after Tenant’s obligation to pay Monthly Rent shall have commenced hereunder, which amount shall be applied to the Monthly Rent first due and payable hereunder.
b. All amounts payable by Tenant to Landlord under this Lease, or otherwise payable in connection with Tenant’s occupancy of the Premises, in addition to the Monthly Rent hereunder and Additional Rent under Paragraph 7, shall constitute rent owed by Tenant to Landlord hereunder.
c. Any rent not paid by Tenant to Landlord when due shall bear interest from the date due to the date of payment by Tenant at an annual rate of interest (the “Interest Rate”) equal to the lesser of (i) twelve percent (12%) per annum or (ii) the maximum annual interest rate allowed by law on such due date for business loans (not primarily for personal, family or household purposes) not exempt from the usury law. Notwithstanding the foregoing, Landlord shall give Tenant notice of non-payment of rent when due and five (5) days after delivery of such notice to cure such non-payment once in each calendar year before assessing interest in such calendar year pursuant to this Paragraph 5.c. Failure by Tenant to pay rent when due, including any interest accrued under this subparagraph, shall constitute an Event of Default (as defined in Paragraph 25 below) giving rise to all the remedies afforded Landlord under this Lease and at law for nonpayment of rent.
d. No security or guaranty which may now or hereafter be furnished to Landlord for the payment of rent due hereunder or for the performance by Tenant of the other terms of this Lease shall in any way be a bar or defense to any of Landlord’s remedies under this Lease or at law.
e. Notwithstanding anything to the contrary in this Lease: (i) in no event may any rent under this Lease be based in whole or in part on the income or profits derived from the Premises, except for percentage rent based on gross (not net) receipts or sales; (ii) if the holder of a Superior Interest (as defined in Paragraph 21 below) succeeds to Landlord’s interest in the Lease (“Successor Landlord”) and the Successor Landlord is advised by its counsel that all or any portion of the rent payable under this Lease is or may be deemed to be “unrelated business income” within the meaning of the Internal Revenue Code or regulations issued thereunder, such Successor Landlord may, at its option, unilaterally amend the calculation of rent so that none of the rent payable to Landlord under the Lease will constitute “unrelated business income,” but the amendment will not increase Tenant’s payment obligations or other liability under this Lease or reduce the Landlord’s obligations under this Lease and (iii) upon the Successor Landlord’s request, Tenant shall execute any document such holder deems necessary to effect the foregoing amendment to this Lease.
Expansion Space As used in this paragraph, the term “Expansion Space” means any space in the Building which, at any time during the Lease Term, is occupied by a Person other than Landlord under a written lease with Landlord, and the term “Tenant’s Expansion Space” means Expansion Space which Tenant has elected to lease as provided in this paragraph. Landlord agrees to notify Tenant promptly after Landlord learns that any Expansion Space is or will become available. Subject to the prior rights of other tenants to whom Landlord has granted substantially similar rights, Tenant has the option to lease any Expansion Space which Landlord notifies Tenant is or will become available. If Tenant gives Landlord notice of its exercise of this option within thirty (30) days after notification from Landlord of the availability of the Expansion Space and if no Event of Default exists when Tenant’s notice is given, this Lease will be deemed to be amended to include Tenant’s Expansion Space as part of the Premises for the remainder of the Lease Term upon all of the same terms contained in this Lease except that (i) the Rentable Area of the Premises will be amended to include Tenant’s Expansion Space; (ii) Tenant’s Share will be increased to include the rentable area of Tenant’s Expansion Space; (iii) the Term Commencement Date with respect to Tenant’s Expansion Space will be the earlier of sixty (60) days after the date on which Tenant’s Expansion Space becomes vacant and ready for occupancy (provided that date is at least sixty (60) days after Tenant exercises its option to lease the Expansion Space), or the date on which the Expansion Space is first occupied by Tenant; (iv) if Tenant’s Expansion Space contains a rentable area of 10,000 square feet or more, and if there are less than three (3) Lease Years remaining in the Lease Term, the Lease Term will be extended to include three (3) full years from the Term Commencement Date with respect to Tenant’s Expansion Space; and (v) subject to adjustment during each Fixed Rental Period as provided in Exhibit E, Basic Rent for each year of the remaining Lease Term (as it may be extended) will be the greater of (a) the Basic Rent last paid by the Person most recently occupying Tenant’s Expansion Space or (b) Market Rent determined as provided in the Rent Rider attached as Exhibit E. If Tenant exercises this option, Tenant’s Expansion Space will be leased to Tenant in its “as is” condition and Tenant will, at its expense and in compliance with the provisions of Section 7.06, design and construct all Improvements desired by Tenant for its use and occupancy. Landlord and Tenant agree to execute such amendments to this Lease and other instruments as either of them considers necessary or desirable to reflect Tenant’s exercise of this option.
Additional Premises Landlord shall use commercially reasonable efforts to expand the Premises to include an additional fifteen thousand four hundred ten (15,410) square feet of Rentable Area located on the first (1st) floor, as shown on Exhibit A attached hereto (the “Additional Premises”) on July 1, 2012 (the “Additional Premises Delivery Date”). In the event Landlord determines the Additional Premises will be ready for delivery to Tenant in the Required Condition on the Additional Premises Delivery Date, within ten (10) business days prior to the Additional Premises Delivery Date, Landlord and Tenant shall enter into a written amendment to the Lease, which amendment shall provide, unless otherwise agreed in writing, (a) that the commencement date of the Additional Premises shall be the Additional Premises Delivery Date (the “Additional Premises Commencement Date”), (b) that, as of the Additional Premises Commencement Date, the Premises under the Lease shall be increased to include the Additional Premises for a total of sixty-one thousand four hundred forty-four (61,444) square feet of Rentable Area (together, the Premises and the Additional Premises shall be referred to hereinafter as the “Total Premises”), (c) the new Basic Annual Rent applicable to the Total Premises, which shall commence on the Additional Premises Commencement Date and shall be as further described in Section 4.2 of this Amendment, (d) Tenant’s new Pro Rata Share of Operating Expenses as of the Additional Premises Commencement Date, which Pro Rata Share shall equal one hundred percent (100%) of the Building and thirty-three and 51/100 percent (33.51%) of the Project and (e) that, in addition to the parking which Tenant is entitled to under the terms of the Lease with respect to the original Premises, Tenant, for so long as Tenant leases the Additional Premises, shall have a non-exclusive license to use the parking facilities serving the Building in common on an unreserved basis with other tenants of the Building and the Project at a ratio of 3.3 parking spaces per 1,000 rentable square feet of Additional Premises, which amounts to fifty-one (51) additional parking spaces, which number shall include three (3) additional Reserved Spaces. In the event the Additional Premises is not ready for delivery to Tenant in the Required Condition on the Additional Premises Delivery Date, then (x) this Amendment and the Lease shall not be void or voidable, (y) Landlord shall not be liable to Tenant for any loss or damage resulting therefrom and (z) the new Basic Annual Rent applicable to the Premises shall be as further described in Section 4.3 of this Amendment.
