Effect of Injunctions or Other Court Orders. The Parties recognize the right of the City to withdraw, at its absolute discretion, the utilization of the Agreement as part of any bid specification should a Court of competent jurisdiction issue any order, or any applicable statute which could result, temporarily or permanently in delay of the bidding, awarding and/or construction on the Project. Notwithstanding such an action by the City, or such court order or statutory provision, the Parties agree that the Agreement shall remain in full force and effect on covered Project Work to the maximum extent legally possible.
Effect of Injunctions or Other Court Orders. The Parties recognize the right of Metropolitan to withdraw, at its absolute discretion, the utilization of the PLA as part of any bid specification should a court of competent jurisdiction issue any order or should a government agency take action to enforce any applicable statute or regulation that could result, temporarily or permanently, in delay of the bidding, awarding, and/or construction on the project, or jeopardize project funding.
Effect of Injunctions or Other Court Orders. The Parties recognize the right of the District to withdraw, at its absolute discretion, the utilization of the Agreement as part of any bid specification should a Court of competent jurisdiction issue any order, or any applicable statute which could result, temporarily or permanently in delay of the bidding, awarding and/or construction of Project Work. Notwithstanding such an action by the District, or such court order or statutory provision, the Parties agree that the Agreement shall remain in full force and effect on Project Work to the maximum extent legally possible.
Effect of Injunctions or Other Court Orders. The Parties recognize the right of the College to withdraw, at its absolute discretion, the utilization of the Agreement as part of any bid specification should a Court of competent jurisdiction issue any order, or any applicable statute which could result, temporarily or permanently in delay of the bidding, awarding and/or construction on the Project. Notwithstanding such an action by the College, or such court order or statutory provision, the Parties agree that the Agreement shall remain in full force and the fact on covered Project Work to the maximum extent legally possible.
Effect of Injunctions or Other Court Orders. The parties recognize the right of the District to withdraw, at its absolute discretion, the utilization of the PLA as part of any bid specification should a Court of competent jurisdiction issue any order, or any applicable statue be enacted, which could result temporarily or permanently in delay of the bidding, awarding and/or construction of the Project. Notwithstanding such an action by the District, or such court order or statutory provision, the parties agree that the PLA shall remain in full force and effect on covered Project Work to the maximum extent legally possible.
Effect of Injunctions or Other Court Orders. The Parties recognize the right of the Owner or Prime Contractor to withdraw, at its absolute discretion, the utilization of the Agreement as part of any bid specification should a Court of competent jurisdiction issue any order, or any applicable statute which could result, temporarily or permanently in delay of the bidding, awarding and/or construction on the Project.
Effect of Injunctions or Other Court Orders. The Parties recognize the right of the District to withdraw, at its absolute discretion, the utilization of the CSWPA as part of any bid specification should a Court of competent jurisdiction issue any order, or any applicable statue which results, temporarily or permanently in delay of the bidding, awarding and/or construction on the Project.
Effect of Injunctions or Other Court Orders. The Parties recognize the right of the the Public Agency to withdraw, at its absolute discretion, the utilization of the PLA as part of any bid specification should a court of competent jurisdiction issue any order, or any applicable statute that could result, temporarily or permanently, in delay of the bidding, awarding, and/or construction on the Project. DRAFT
Effect of Injunctions or Other Court Orders. The Parties recognize the right of MTS to withdraw, at its absolute discretion, the utilization of the PLA as part of any bid specification should a court of competent jurisdiction issue any order, or any applicable statute that could result, temporarily or permanently, in delay of the bidding, awarding, and/or construction on the Project.
Effect of Injunctions or Other Court Orders. The Parties recognize the right of SANDAG to withdraw, at its absolute discretion, the utilization of the CBA as part of any bid specification should a court of competent jurisdiction issue any order, or any applicable statute that could result, temporarily or permanently, in delay of the bidding, awarding, and/or construction on the project, or jeopardize project funding.
