Changes in Control For the duration of the Project Term, the Private Party shall procure that there is no Change in Control in the Private Party (or in any company of which the Private Party is a subsidiary) without the prior written approval of SANParks, which approval shall not be unreasonably withheld, provided that no Change in Control may breach the provisions of Schedule 5 in any way.
Termination for Changes in Budget or Law The JBE’s payment obligations under this Agreement are subject to annual appropriation and the availability of funds. Expected or actual funding may be withdrawn, reduced, or limited prior to the expiration or other termination of this Agreement. Funding beyond the current appropriation year is conditioned upon appropriation of sufficient funds to support the activities described in this Agreement. The JBE may terminate this Agreement or limit Contractor’s Services (and reduce proportionately Contractor’s fees) upon Notice to Contractor without prejudice to any right or remedy of the JBE if: (i) expected or actual funding to compensate Contractor is withdrawn, reduced or limited; or (ii) the JBE determines that Contractor’s performance under this Agreement has become infeasible due to changes in applicable laws.
Changes in Benefits The Bank shall not make any changes in such plans, benefits or privileges previously described in Section 3(c), (d) and (e) which would adversely affect the Executive's rights or benefits thereunder, unless such change occurs pursuant to a program applicable to all executive officers of the Bank and does not result in a proportionately greater adverse change in the rights of, or benefits to, the Executive as compared with any other executive officer of the Bank. Nothing paid to Executive under any plan or arrangement presently in effect or made available in the future shall be deemed to be in lieu of the salary payable to Executive pursuant to Section 3(a) hereof.
Changes in Agreement Any changes deemed necessary in this Agreement may be made by mutual agreement at any time during the existence of this Agreement.
Effective Date Term and Termination 1.1 The effective date ("EFFECTIVE DATE") of this Agreement shall be the date first above written.
1.2 The term of this Agreement ("TERM") commences on the Effective Date, and unless the Agreement is terminated pursuant to Section 1.3 or 1.4, it shall continue in force until "Completion Date" (as defined in Section 3.2).
1.3 Each party may terminate this Agreement (effective immediately upon written notice) if the other party materially breaches any provision of this Agreement if such breach continues and is not cured within [***] after written notice thereof by the non-breaching party, including the nature of the breach upon which such notice is based. SVI may terminate this Agreement upon written notice to Customer if Customer fails to pay, within [***] of a Payment Date, any amount payable hereunder. SVI may suspend its performance of services under the terms of this Agreement pending receipt of such payment. Any such termination by SVI shall not affect SVI and Customer's respective rights with respect to any Deliverables and/or Professional Services delivered or performed and fully paid during the Term.
1.4 Customer may terminate this Agreement during the Term (a) upon written notice to SVI after [***] prior written notice, provided that Customer shall remain obligated to pay to SVI all amounts due SVI to such termination date (b) upon [***] written notice to SVI after a change of control (as defined in Section 13.1), or (c) on the occurrence of any of the following: (i) an assignment by SVI for the benefit of creditors; (ii) the appointment of a trustee or receiver for substantially all of SVI's assets; or (iii) to the extent termination is enforceable under the U.S. Bankruptcy Code, a proceeding in bankruptcy is instituted against SVI which is acquiesced in, is not dismissed within [***], or results in an adjudication of bankruptcy.
1.5 After expiration or termination of this Agreement for any reason, other than related to Customer's breach, SVI shall promptly deliver any partially-created Deliverable that exists as of the expiration or termination date; provided that Customer pays SVI all amounts then due SVI. Upon delivery, such Deliverable shall be considered a "Deliverable" for all purposes hereunder.
1.6 Subject to each party's rights, remedies and defenses relating to any breach by the other party, the provisions of Sections 1.5, 1.6, 6 (with respect to Deliverables delivered in the Term, subject to Section 1.5), 9.1 (with respect to fees accrued prior to expiration or termination), 9.3, 12.2(a), 12.3-12.7, 14-33 shall survive expiration or termination of this Agreement (including the Revenue Sharing Term in Section 17.1) for any reason. [***] = Confidential Treatment Requested
Changes in Work A. Work Previously Submitted as Satisfactory. If the Engineer has submitted work in accordance with the terms of this contract but the State requests changes to the completed work or parts thereof which involve changes to the original scope of services or character of work under the contract, the Engineer shall make such revisions as requested and as directed by the State. This will be considered as additional work and paid for as specified under Article 4, Additional Work.
Changes in Corporate Structure The Company shall not have changed its jurisdiction of incorporation or organization, as applicable, or been a party to any merger or consolidation or succeeded to all or any substantial part of the liabilities of any other entity, at any time following the date of the most recent financial statements referred to in Schedule 5.5.
FORCE MAJEURE; OTHER CHANGES IN CONDITIONS 19.1 In the event of and as soon as possible after the occurrence of any cause constituting force majeure, the affected Party shall give notice and full particulars in writing to the other Party, of such occurrence or cause if the affected Party is thereby rendered unable, wholly or in part, to perform its obligations and meet its responsibilities under the Contract. The affected Party shall also notify the other Party of any other changes in condition or the occurrence of any event which interferes or threatens to interfere with its performance of the Contract. Not more than fifteen (15) days following the provision of such notice of force majeure or other changes in condition or occurrence, the affected Party shall also submit a statement to the other Party of estimated expenditures that will likely be incurred for the duration of the change in condition or the event of force majeure. On receipt of the notice or notices required hereunder, the Party not affected by the occurrence of a cause constituting force majeure shall take such action as it reasonably considers to be appropriate or necessary in the circumstances, including the granting to the affected Party of a reasonable extension of time in which to perform any obligations under the Contract.
19.2 If the Contractor is rendered unable, wholly or in part, by reason of force majeure to perform its obligations and meet its responsibilities under the Contract, UNDP shall have the right to suspend or terminate the Contract on the same terms and conditions as are provided for in Article 20, “Termination,” except that the period of notice shall be seven (7) days instead of thirty (30) days. In any case, UNDP shall be entitled to consider the Contractor permanently unable to perform its obligations under the Contract in case the Contractor is unable to perform its obligations, wholly or in part, by reason of force majeure for any period in excess of ninety (90) days.
19.3 Force majeure as used herein means any unforeseeable and irresistible act of nature, any act of war (whether declared or not), invasion, revolution, insurrection, terrorism, or any other acts of a similar nature or force, provided that such acts arise from causes beyond the control and without the fault or negligence of the Contractor. The Contractor acknowledges and agrees that, with respect to any obligations under the Contract that the Contractor must perform in areas in which UNDP is engaged in, preparing to engage in, or disengaging from any peacekeeping, humanitarian or similar operations, any delays or failure to perform such obligations arising from or relating to harsh conditions within such areas, or to any incidents of civil unrest occurring in such areas, shall not, in and of itself, constitute force majeure under the Contract.
Changes in Condition In the event of any advantageous technical changes and/or downward pricing of the Services during the duration of this Agreement, the Contractor shall notify UNDP immediately. UNDP shall consider the impact of any such event and may request an amendment to the Agreement.
Effective Date; Termination; Cancellation and Suspension Section 4.01. This Agreement shall come into force and effect on the date upon which the Development Credit Agreement becomes effective.
Section 4.02. (a) This Agreement and all obligations of the Association and of Republika Srpska thereunder shall terminate on the earlier of the following two dates:
(i) the date on which the Development Credit Agreement shall terminate; or
(ii) a date twenty (20) years after the date of this Agreement.
