SHOP DRAWINGS, PRODUCT DATA AND SAMPLES 4.12.1 Shop Drawings are drawings, diagrams, schedules and other, data specially prepared for the Work by the Contractor or any Subcontractor, manufacturer, supplier or distributor to illustrate some portion of the Work.
4.12.2 Product Data are illustrations, standard schedules, performance charts, instructions, brochures, diagrams and other information furnished by the Contractor to illustrate a material, product or system for some portion of the Work.
4.12.3 Samples are physical examples which illustrate materials, equipment or workmanship and establish standards by which the Work will be judged.
4.12.4 The Contractor shall review, approve and submit, with reasonable promptness and in such sequence as to cause no delay in the Work or in the work of the State or any separate contractor, all Shop Drawings, Product Data and Samples required by the Contract Documents.
4.12.5 By approving and submitting Shop Drawings, Product Data and Samples, the Contractor represents that he / she has determined and verified all materials, field measurements, and field construction criteria related thereto, or will do so, and that he / she has checked and coordinated the information contained within such submittals with the requirements of the Work and of the Contract Documents.
4.12.6 The Contractor shall not be relieved of responsibility for any deviation from the requirements of the Contract Documents by the Architect's approval of Shop Drawings, Product Data or Samples under Subparagraph 2.2.7 of these General Conditions unless the Contractor has specifically informed the Architect and the State in writing of such deviation at the time of sub- mission and the Architect and the State has given written approval to the specific deviation. The Contractor shall not be relieved from responsibility for errors or omissions in the Shop Drawings, Product Data or Samples by the Architect's approval thereof.
4.12.7 The Contractor shall direct specific attention, in writing or on resubmitted Shop Drawings, Product Data or Samples, to revisions other than those requested by the Architect on previous submittals.
4.12.8 No portion of the Work requiring submission of a Shop Drawing, Product Data or Sample shall be commenced until the submittal has been approved by the Architect as provided in Subparagraph 2.2.7 of these General Conditions. All such portions of the Work shall be in accordance with approved submittals.
User Content 13.1 The Site permits the submission and posting of questions and answers in connection with Evaluation Processes and may also permit the submission and posting of other text and/or other content submitted by you and other users (all of the foregoing, collectively, “User Submissions”), and the hosting, sharing, and/or publishing of such User Submissions. You understand that whether or not such User Submissions are published, the Company does not guarantee any confidentiality with respect to any User Submissions. You acknowledge that you shall not be due any remuneration in connection with your User Submissions from the Company or from any other User.
13.2 You shall be solely responsible for your own User Submissions and the consequences of posting or publishing them. In connection with your User Submissions, you affirm, represent, and/or warrant that: (i) your submission of User Submissions and the publication and use thereof by the Company does not violate the copyrights, trade secrets rights or other intellectual property rights of any third party, nor shall it constitute or result in a breach of any duty or obligation of confidentiality owed by you to any third party, and (ii) you have the written consent, release, and/or permission of each and every identifiable individual person in the User Submission to use the name or likeness of each and every such identifiable individual person to enable inclusion and use of the User Submissions in the manner contemplated by the Company and this Agreement.
13.3 By submitting User Submissions to the Site, you hereby grant to the Company a perpetual, irrevocable, worldwide, royalty-free, transferable, sublicensable right and license to use, reproduce, modify, distribute and exploit such User Submission in any manner and in any form of media, whether currently or hereafter existing. You represent and warrant that you have all necessary right, title and interest in and to each such User Submission to validly grant such license to the Company.
13.4 In connection with User Submissions and any other transmission of messages or material facilitated by the Site, you further agree that you will not: (i) submit or transmit material that is not authorized by the copyright owner, protected by trade secret or otherwise subject to third party proprietary rights, including privacy and publicity rights, unless you are the owner of such rights or have permission from their rightful owner to post the material and grant the rights granted to the Company in Section 13.3 above; (ii) publish or transmit falsehoods or misrepresentations that could damage the Company or any third party; (iii) submit or transmit material that is unlawful, defamatory, libelous, threatening, pornographic, harassing, hateful, racially or ethnically offensive or encourages conduct that would be considered a criminal offense, give rise to civil liability, violate any law or is otherwise inappropriate; (iv) post or transmit advertisements or solicitations of business; or (v) impersonate another person. If notified by a user or a content owner of a User Submission that allegedly does not conform to this Agreement, the Company may investigate the allegation and determine in good faith and in its sole discretion whether to remove the User Submission, which it reserves the right to do at any time. Additionally, the Company may, at any time, remove any User Submission that in the sole judgment of the Company violates this Agreement.
13.5 User Submissions may be provided by (without limitation) Users who are members of a Start-Up management team, contacts referred by Start-Ups (including without limitation customers, scientific advisors, background references, suppliers and distributors), external experts referred by the Company. The insights, recommendations, views and other content reflected in a User Submission should be taken as opinion rather than statements of facts. Investors should conduct their own diligence before making an investment. Nothing contained in a User Submission constitutes tax, legal, insurance or investment advice, or the recommendation of or an offer to sell, or the solicitation of an offer to buy or invest in, any investment product, vehicle, service or instrument. Such an offer or solicitation may only be made by delivery to a prospective investor of formal offering materials, including subscription or account documents or form, which should be reviewed carefully by any such investor before making the decision to invest in any particular company issuer listed, reviewed or discussed on the Propel(x) platform. To the maximum extent permitted under applicable law, you hereby release Propel(x) (and our officers, directors, agents, investors, subsidiaries, and employees) and each other User from any and all claims, demands, liabilities, losses or damages (whether direct, indirect, consequential, incidental or otherwise) of every kind and nature, known and unknown, suspected or unsuspected, arising out of or in any way related to User Submissions (including your reliance thereon). You acknowledge that, in connection with the foregoing release, you hereby irrevocably waive all rights granted to you under Section 1542 of the California Civil Code or any analogous applicable state or federal law or regulation. Said Section 1542 of the Civil Code of the State of California reads as follows:
