Evidence of Project Costs Sample Clauses

Evidence of Project Costs. (i) Except in relation to an initial borrowing made within one month of the Closing Date, at least fifteen (15) days prior to such Construction Loan, the Administrative Agent and the Independent Engineer shall have received a Construction Progress Report, together with a statement of the payments to be made pursuant to the Backhaul Agreements and/or to the Contractor pursuant to the Construction Contract with the proceeds of such Construction Loans, together with other documentation reasonably requested by and satisfactory to the Administrative Agent and with respect to all other items of Project Costs to be paid or advanced with the proceeds of such Construction Loans.
Sample 1Sample 2Sample 3See All (4)
AutoNDA by SimpleDocs
Evidence of Project Costs. If requested by the Administrative Agent, the Administrative Agent and the Independent Engineer shall have received (i) a copy of all monthly invoices issued under any Construction Contract and invoices and related documentation in connection with any other Project Costs which the Borrower intends to pay with such Term Loan and (ii) projections of invoices expected to be received (A) in respect of all Term Loan Borrowings except the Final Term Loan Borrowing, within forty-five (45) days after the date of the applicable Loan Borrowing Certificate or (B) in respect of the Final Term Loan Borrowing, within the period from the date of the applicable Loan Borrowing Certificate until Final Completion under any Construction Contract and projections, invoices and related documentation in connection with any other Project Costs which the Borrower intends to pay with such Term Loan, in each case not less than five (5) Business Days prior to the date of the Notice of Borrowing, as applicable, as evidence of the Project Costs related to the applicable Loan Borrowing Certificate; provided, that the Borrower shall (x) submit evidence, satisfactory to the Administrative Agent and certified by the Independent Engineer, demonstrating that all amounts borrowed pursuant to the preceding Loan Borrowing Certificate were used to pay Project Costs, (y) certify that Term Loan Borrowings made pursuant to the preceding Loan Borrowing Certificate, as applicable, and all equity not yet expended as previously projected shall be expended during the next forty-five (45) days, as certified by the Independent Engineer or (z) reduce the amount of the Term Loans requested pursuant to the current Notice of Borrowing, as applicable, in an amount equal to the Term Loan proceeds and equity not previously expended and not contemplated to be spent pursuant to clause (y) above; provided, that in no event shall the Borrowing be reduced below $1,000,000.
Sample 1Sample 2See All (4)
Evidence of Project Costs. At least fifteen (15) days prior to such Equity Withdrawal, the Administrative Agent and the Independent Engineer shall have received a Construction Progress Report, together with a statement of the payments to be made pursuant to the Backhaul Agreements and/or to the Contractor pursuant to the Construction Contract with the proceeds of such Equity Withdrawal, together with other documentation reasonably requested by and satisfactory to the Administrative Agent and with respect to all other items of Project Costs to be paid or advanced with the proceeds of such Equity Withdrawal.
Sample 1Sample 2
Evidence of Project Costs. The Administrative Agent and the Independent Engineer shall have received (i) a copy of all invoices and related documentation issued under the EPC Contract (or other invoices and supporting documentation in connection with the payment of any other Project Costs) which the Borrower intends to pay with such Loan, (ii) projections of invoices expected to be received (A) in respect of all Borrowings except the final Borrowing, within forty-five (45) days after the date of the applicable Borrowing Certificate or (B) in respect of the final Borrowing, within the period from the date of the applicable Borrowing Certificate until the Project Completion Date, in connection with Project Costs which the Borrower intends to pay with such Loan, in each case not less than five
Sample 1
Evidence of Project Costs. Furnish to the Administrative Agent and the Technical and Environmental Consultant, within thirty (30) days after the end of each fiscal quarter of the Borrower (for purposes of this Section, “Applicable Quarter”), a certificate dated as of such date certifying and attaching the following:
Sample 1

Related to Evidence of Project Costs

  • Project Costs The Project costs are true and accurate estimates of the costs necessary to complete the Improvements in a good and workmanlike manner according to the Plans and Specifications presented by Borrower to Lender, and Borrower shall take all steps necessary to prevent the actual cost of the Improvements from exceeding the Project costs.

  • Existence; Maintenance of Properties (a) The Borrower will preserve and keep in full force and effect its existence as a Delaware limited partnership. Each Guarantor will preserve and keep in full force and effect its legal existence in the jurisdiction of its incorporation or formation. The Borrower will cause each of its Subsidiaries which is not a Guarantor to preserve and keep in full force and effect their legal existence in the jurisdiction of its incorporation or formation except where such failure has not had and could not reasonably be expected to have a Material Adverse Effect. The Borrower will preserve and keep in full force all of its rights and franchises and those of its Subsidiaries, the preservation of which is necessary to the conduct of their business (except with respect to Subsidiaries of Borrower that are not Guarantors, where such failure has not had and could not reasonably be expected to have a Material Adverse Effect). Parent shall at all times comply with all requirements and applicable laws and regulations necessary to maintain REIT Status and shall continue to receive REIT Status. The common stock of Parent shall at all times be listed for trading and be traded on NASDAQ, the New York Stock Exchange or another nationally recognized exchange unless otherwise consented to by the Required Lenders. The Borrower shall continue to own directly or indirectly one hundred percent (100%) of the Subsidiary Guarantors.

  • Maintenance of Properties; Insurance The Borrower will, and will cause each of its Subsidiaries to, (a) keep and maintain all property material to the conduct of its business in good working order and condition, ordinary wear and tear excepted, and (b) maintain, with financially sound and reputable insurance companies, insurance in such amounts and against such risks as are customarily maintained by companies engaged in the same or similar businesses operating in the same or similar locations.

  • Maintenance of Property; Insurance (a) Keep all property useful and necessary in its business in good working order and condition, ordinary wear and tear excepted and (b) maintain with financially sound and reputable insurance companies insurance on all its property in at least such amounts and against at least such risks (but including in any event public liability, product liability and business interruption) as are usually insured against in the same general area by companies engaged in the same or a similar business.

  • Operation and Maintenance of Properties The Borrower, at its own expense, will, and will cause each Subsidiary to:

  • Maintenance of Properties (a) Maintain, preserve and protect all of its material properties and equipment necessary in the operation of its business in good working order and condition, ordinary wear and tear excepted; (b) make all necessary repairs thereto and renewals and replacements thereof except where the failure to do so could not reasonably be expected to have a Material Adverse Effect; and (c) use the standard of care typical in the industry in the operation and maintenance of its facilities.

  • Amendment costs If (a) the Borrower requests an amendment, waiver or consent or (b) an amendment is required pursuant to Clause 27.9 (Change of currency), the Borrower shall, within three Business Days of demand, reimburse the Agent for the amount of all costs and expenses (including legal fees) reasonably incurred by the Agent in responding to, evaluating, negotiating or complying with that request or requirement.

  • Legal Existence; Maintenance of Properties Each of the Borrowers will do or cause to be done all things necessary to preserve and keep in full force and effect its legal existence, rights and franchises and those of its Subsidiaries and will not, and will not cause or permit any of its Subsidiaries to, convert to a limited liability company or a limited liability partnership. It (a) will cause all of its properties and those of its Subsidiaries used or useful in the conduct of its business or the business of its Subsidiaries to be maintained and kept in good condition, repair and working order and supplied with all necessary equipment, (b) will cause to be made all necessary repairs, renewals, replacements, betterments and improvements thereof, all as in the judgment of such Borrower may be necessary so that the business carried on in connection therewith may be properly and advantageously conducted at all times, (c) will maintain in full force and effect all patents, trademarks, trade names, copyrights, licenses, permits and other authorizations necessary for the ownership and operation of its properties and business, and (d) will, and will cause each of its Subsidiaries to, continue to engage primarily in the businesses now conducted by them and in related businesses; provided that nothing in this Section 8.6 shall prevent any of the Borrowers from discontinuing the operation and maintenance of any of its properties or any of those of its Subsidiaries, including the existence of any Subsidiary of BGI or the conversions of any Subsidiary of BGI to a limited liability company or limited liability partnership, if such discontinuance or conversion is, in the judgment of such Borrower, desirable in the conduct of its or their business and that do not in the aggregate have a Material Adverse Effect and, with respect to the conversions of a Borrower or a Guarantor to a limited liability company or limited liability partnership, simultaneously with such conversion, such Borrower or Guarantor shall have executed and delivered to the Administrative Agent all documentation which the Administrative Agent reasonably determine is necessary to continue such Borrower's or such Guarantor's obligations in respect of this Credit Agreement and the Collateral Agent's Liens in respect of the Collateral.

  • Construction Costs Tenant shall pay for all construction costs, including, but not limited to permits, costs of materials and labor, sales tax, construction management fees and the like except to the extent of the Tenant Improvement Allowance which shall be paid by Landlord. The term “Tenant Improvement Allowance” shall mean the sum of $316,020.00 (or $15.00 per square foot of rentable area times 21,068 square feet of rentable area) which Landlord agrees to pay towards the construction costs. Landlord agrees to pay architectural fees and design services up to $1.25 per rentable square foot. Any services performed by the architect above the $1.25 per rentable square foot shall be the responsibility of the Tenant and may be paid out of the Tenant Improvement Allowance to the extent funds are available. Notwithstanding anything to the contrary, provided there is any unused portion of the Tenant Improvement Allowance, up to 20% of the allowance can be used by the Tenant as a moving allowance or for communications costs for cabling and data. Tenant must submit invoices for such allowances for Landlord to pay. Xxxxxx Development will act as General Contractor for the construction of tenant improvements, competitively bidding each trade to at least three subcontractors, the typical five percent (5%) construction management fee will not be charged to Tenant or deducted from the Tenant Improvement Allowance. Landlord shall obtain bids based on the Approved Pricing Plans and construct the Work as described in the Approved Pricing Plans. If after finalizing the Approved Working Drawings, it is determined that the construction costs will exceed the amount of the Tenant Improvement Allowance (an “Excess”), then Tenant shall pay to Landlord the amount of such Excess within ten (10) days of written request from Landlord. Notwithstanding anything to the contrary, if Tenant fails to pay any Excess timely, Landlord shall not be obligated to commence construction of the Work and such delay shall constitute a Tenant Delay for each day beyond the ten (10) day period until the Excess is paid to Landlord. If Tenant elects not to use Xxxxxx Development as the General Contractor, Tenant understands that Landlord, or its designated agent, shall serve as construction manager for all of Tenant’s refurbishment and renovations in the refurbishment and renovations in the Premises and the fee for such service is 5% of the total cost of all work performed in connection with such refurbishment and renovations. Tenant agrees to cooperate with Landlord in completing any such improvements on a timely basis and Tenant has approved the preliminary space plan and pricing documentation. Additional space on the 3rd floor which Tenant elects to lease pursuant [****] = CERTAIN CONFIDENTIAL INFORMATION CONTAINED IN THIS DOCUMENT, MARKED BY BRACKETS, HAS BEEN OMITTED AND FILED SEPARATELY WITH THE SECURITIES AND EXCHANGE COMMISSION PURSUANT TO RULE 406 OF THE SECURITIES ACT OF 1933, AS AMENDED. to a right hereunder shall be finished out by Landlord pursuant to mutually agreed upon plans and Tenant shall receive an allowance of $15.00 per square foot of rentable area provided, however, Tenant acknowledges that Landlord is improving the entire third (3rd) floor prior to commencement of the Lease and Tenant shall not be entitled to any additional tenant finish when Tenant leases the remainder of the third floor.

  • Maintenance of Properties, Etc Maintain and preserve, and cause each of its Subsidiaries to maintain and preserve, all of its properties that are used or useful in the conduct of its business in good working order and condition, ordinary wear and tear excepted.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!