Shifting of obstructing utilities The Contractor shall, in accordance with Applicable Laws and with assistance of the Authority, undertake the work of shifting of any utility (including electric lines, water pipes, gas pipelines and telephone cables) to an appropriate location or alignment, if such utility or obstruction adversely affects the execution of Works or Maintenance of the Project Highway in accordance with this Agreement. The cost of such shifting, as per estimates prepared by the entity owning the utility and approved by the Authority, shall be reimbursed by the Authority to the Contractor. The scope of work of such shifting of Utilities shall be as indicated in Schedule-B-1. In the event of any delay of such shifting on the part of the contractor, no extension of time for completion of the project and no claims, in any manner, shall be admissible on this account against the Authority. The work of shifting of Utilities can be taken up by the Contractor any time after signing of the Agreement.
CLEANING UP 4.15.1 Before commencement of any on-site activities, Contractor is required to prepare and submit to the Project Manager a Construction Site Waste Reduction Plan. A sample plan is available at: xxxx://xxx.xxx.xxxxx.xx.xx/dec/wastediv/recycling/CandD.htm . Failure to comply with this provision or a failure to comply with the plan itself will result in withholding of general conditions’ money from the contractor’s monthly requisition until Contractor has rectified the situation and is in full compliance with these provisions.
4.15.2 The Contractor at all times shall keep the premises free from accumulation of waste materials or rubbish. At the completion of the Work he shall remove all his waste materials and rubbish from and about. the Project as well as all his tools, construction equipment, machinery and surplus materials and shall leave the premises in a clean and satisfactory condition.
4.15.3 If the Contractor fails to clean up at the completion of the Work, the State may do so as provided in Paragraph 3.4 and the cost thereof shall be charged to the Contractor.
Winding Up (i) Upon the occurrence of a Liquidating Event, the Partnership shall continue solely for the purposes of winding up its affairs in an orderly manner, liquidating its assets, and satisfying the claims of its creditors and Partners.
(ii) No Partner shall take any action that is inconsistent with, or not necessary to or appropriate for, the winding up of the Partnership’s business and affairs.
(iii) The General Partner, or, if there is no remaining General Partner, any Person elected by the Limited Partners holding at least a “majority in interest” (the General Partner or such other Person being referred to herein as the “Liquidator”), shall be responsible for overseeing the winding up and dissolution of the Partnership and shall take full account of the Partnership’s liabilities and property and the Partnership property shall be liquidated as promptly as is consistent with obtaining the fair value thereof, and the proceeds therefrom (which may, to the extent determined by the General Partner, include shares of common stock or other securities of the General Partner) shall be applied and distributed in the following order:
(A) First, to the payment and discharge of all of the Partnership’s debts and liabilities to creditors other than the Partners;
(B) Second, to the payment and discharge of all of the Partnership’s debts and liabilities to the General Partner;
(C) Third, to the payment and discharge of all of the Partnership’s debts and liabilities to the other Partners; and
(D) the balance, if any, shall be distributed to all Partners (including the Special Limited Partner) with positive Capital Accounts in accordance with their respective positive Capital Account balances after giving effect to all allocations in Exhibit B and all prior distributions under Section 5.1.
(iv) The General Partner shall not receive any additional compensation for any services performed pursuant to this Article 13.
(v) Any distributions pursuant to this Section 13.2(a) shall be made by the end of the Partnership’s taxable year in which the liquidation occurs (or, if later, within 90 days after the date of the liquidation).
(i) Notwithstanding the provisions of Section 13.2(a) hereof which require liquidation of the assets of the Partnership, but subject to the order of priorities set forth therein, if prior to or upon dissolution of the Partnership the Liquidator determines that an immediate sale of part or all of the Partnership’s assets would be impractical or would cause undue loss to the Partners (including the Special Limited Partner), the Liquidator may, in its sole and absolute discretion, defer for a reasonable time the liquidation of any asset except those necessary to satisfy liabilities of the Partnership (including to those Partners, including the Special Limited Partner, as creditors) or distribute to the Partners (including the Special Limited Partner), in lieu of cash, as tenants in common and in accordance with the provisions of Section 13.2(a) hereof, undivided interests in such Partnership assets as the Liquidator deems not suitable for liquidation.
(ii) Any such distributions in kind shall be made only if, in the good faith judgment of the Liquidator, such distributions in kind are in the best interests of the Partners (including the Special Limited Partner), and shall be subject to such conditions relating to the disposition and management of such properties as the Liquidator deems reasonable and equitable and to any agreements governing the operation of such properties at such time.
(iii) The Liquidator shall determine the fair market value of any property distributed in kind using such reasonable method of valuation as it may adopt.
(c) In the discretion of the Liquidator, a pro rata portion of the distributions that would otherwise be made to the General Partner, the Limited Partners and the Special Limited Partner pursuant to this Article 13 may be:
(A) distributed to a trust established for the benefit of the General Partner, the Limited Partners and the Special Limited Partner for the purposes of liquidating Partnership assets, collecting amounts owed to the Partnership, and paying any contingent or unforeseen liabilities or obligations of the Partnership or the General Partner arising out of or in connection with the Partnership; the assets of any such trust shall be distributed to the General Partner, the Limited Partners and the Special Limited Partner from time to time, in the reasonable discretion of the Liquidator, in the same proportions as the amount distributed to such trust by the Partnership would otherwise have been distributed to the General Partner, the Limited Partners and the Special Limited Partner pursuant to this Agreement; or
(B) withheld or escrowed to provide a reasonable reserve for Partnership liabilities (contingent or otherwise) and to reflect the unrealized portion of any installment obligations owed to the Partnership, provided that such withheld or escrowed amounts shall be distributed to the General Partner, the Limited Partners and the Special Limited Partner in the manner and order of priority set forth in Section 13.2(a), as soon as practicable.
Furnishings The Premises is: (check one) ☐ - To be furnished with the following items: [ENTER FURNISHINGS] ☐ - Not furnished.
Fixtures The Seller agrees that all fixtures shall be included as part of the sale EXCEPT: _
Furniture, Fixtures and Equipment Sublessee shall have the right to use during the Term the office furnishings and equipment within the Subleased Premises that are identified on Exhibit C attached hereto, as such exhibit may be adjusted by mutual agreement of the parties prior to the Third Floor Premises Delivery Date (the “Furniture”), provided Sublessee may only use the Furniture located in the Second Floor Premises after the Second Floor Commencement Date. The Furniture is provided in its “AS IS, WHERE IS” condition, without representation or warranty whatsoever. Sublessee shall insure the Furniture under the property insurance policy required under the Master Lease, as incorporated herein, and pay all taxes with respect to the Furniture. Sublessee shall maintain the Furniture in good condition and repair, reasonable wear and tear excepted, and shall be responsible for any loss or damage to the same occurring during the Term. Sublessee shall surrender the Furniture to Sublessor upon the termination of this Sublease in the same condition as exists as of the applicable Delivery Date, reasonable wear and tear excepted. Sublessee shall not remove any of the Furniture from the Subleased Premises. Notwithstanding anything to the contrary herein, Sublessee may provide Sublessor with written notice one (1) time not less than forty-five (45) days prior to the Third Floor Premises Delivery Date that lists any items of Furniture that Sublessee does not want to use and Sublessor shall, at no cost to Sublessee, remove such items from the Subleased Premises prior to the Third Floor Premises Delivery Date and such items shall no longer be considered Furniture hereunder. Notwithstanding the foregoing, provided Sublessee is not in default beyond the expiration of any applicable cure or grace period as of the date of the expiration or earlier termination of this Sublease, which condition may be waived by Sublessor in its sole discretion, then upon the expiration or earlier termination of this Sublease, the Furniture shall become the property of Sublessee, and Sublessee shall accept the same in its “AS IS, WHERE IS” condition, without representation or warranty whatsoever except as provided in the Bill of Sale referred to in the following sentence. In the event the Furniture is to become the property of Sublessee upon the expiration or earlier termination of this Sublease pursuant to the terms of the immediately preceding sentence, then Sublessor agrees to execute and deliver to Sublessee a Bill of Sale in the form of Exhibit D attached hereto conveying and transferring to Sublessee the Furniture.
Removal of Tenant’s Property Upon the expiration or earlier termination of this Lease or the termination of Tenant's right of possession of the Premises only, Tenant shall have the right, at its sole cost and expense, for a period of fifteen (15) days thereafter to remove Tenant's Property, Distinctive Property and the Financed Personalty, respectively, from the Premises, provided that Tenant shall pay to Landlord Rent due under Article 3 hereof for the actual number of days which elapse during such fifteen (15) day period until the Tenant's Property, Distinctive Property and the Financed Personalty, as applicable, are removed from the Premises. If and to the extent that Tenant fails to remove any of such property by the expiration of said fifteen (15) day period, Landlord agrees that Tenant Lender, TE Lender and Franchisor each shall have the right for a period of forty (45) days thereafter to remove the same from the Premises, provided, that Tenant shall pay to Landlord Rent due hereunder for the actual number of days which elapse until Tenant Lender, TE Lender or Franchisor remove the same from the Premises during such forty five (45) day period. If and to the extent that any such property remains on the Premises on the sixtieth (60th) day after such termination, the same shall be deemed abandoned, and at Landlord's option shall become the property of Landlord and may be sold or disposed of as Landlord may determine; provided, however, that Landlord shall not use, suffer or permit the use of any Distinctive Property unless the attributes or features thereof associated with Tenant or Franchisor are removed or obliterated. Any and all damage to the Building caused by or resulting from the removal of Tenant's Property, Distinctive Property or Financed Personalty shall promptly be repaired at no cost or expense to Landlord and Tenant shall be liable for such cost and expense unless such repairs are made by Tenant, Franchisor or TE Lender, as the case may be.
Furniture During the Term, at no charge to Subtenant, Subtenant shall be permitted to use the remaining existing modular and office furniture located in the Subleased Premises and described in more particular detail in Exhibit C attached hereto (the “Office Furniture”) as well as all equipment and associated data cabling existing in the Subleased Premises (the Office Furniture together with any equipment and data cabling, being referred to collectively as the “Furniture”). Subtenant shall accept the Furniture in its current condition without any warranty of fitness from Sublandlord (Subtenant expressly acknowledges that no warranty is made by Sublandlord with respect to the condition of any cabling currently located in or serving the Subleased Premises or with respect to the fitness of such cabling for Subtenant’s intend use thereof). For purposes of documenting the current condition of the Office Furniture, Subtenant and Sublandlord shall, within ten (10) days after Sublandlord’s receipt of the Furniture Notice, conduct a joint walk-through of the Subleased Premises in order to inventory items of damage or disrepair. Subtenant shall use the Furniture only for the purposes for which such Furniture is intended and shall be responsible for the proper maintenance, insurance, care and repair of the Furniture, at Subtenant’s sole cost and expense. Subtenant shall not modify, reconfigure or relocate any of the Furniture except with the advance written notice to Sublandlord, and any work of modifying any Furniture (including, without limitation, changing the configuration of, “breaking down” or reassembly of cubicles or other modular furniture) shall be performed at Subtenant’s sole cost. No item of Furniture shall be removed from the Subleased Premises without Sublandlord’s prior written consent.
IDENTITY OF THE PROPERTY 11.1 The Purchaser shall admit the identity of the Property with that described in the Proclamation of Sale and such other documents offered by the Assignee/Bank as the title to the Property by a comparison of the description in the Proclamation of Sale and the aforesaid documents.
11.2 Any error, misstatement, omission or misdescription of the Property in the Proclamation of Sale and the documents referred to in paragraph 11.1 above shall not annul the sale, nor shall any compensation be allowed therefor.
Assessment of capacity For the purpose of establishing the percentage of the rate to be paid to an employee under this Agreement, the productive capacity of the employee will be assessed in accordance with the Supported Wage System and documented in an assessment instrument by either:
(a) the employer and the union in consultation with the employee or, if desired by any of these; or
(b) the employer and an accredited Assessor from a panel agreed by the parties to the Agreement and the employee.