MSAA Indicator Technical Specification Document This Agreement shall be interpreted with reference to the MSAA Indicator Technical Specifications document.
Minimum Site Requirements for TIPS Sales (when applicable to TIPS Sale). Cleanup: When performing work on site at a TIPS Member’s property, Vendor shall clean up and remove all debris and rubbish resulting from their work as required or directed by the TIPS Member or as agreed by the parties. Upon completion of work, the premises shall be left in good repair and an orderly, neat, clean and unobstructed condition. Preparation: Vendor shall not begin a project for which a TIPS Member has not prepared the site, unless Vendor does the preparation work at no cost, or until TIPS Member includes the cost of site preparation in the TIPS Sale Site preparation includes, but is not limited to: moving furniture, installing wiring for networks or power, and similar pre‐installation requirements. Registered Sex Offender Restrictions: For work to be performed at schools, Vendor agrees that no employee of Vendor or a subcontractor who has been adjudicated to be a registered sex offender will perform work at any time when students are, or reasonably expected to be, present unless otherwise agreed by the TIPS Member. Vendor agrees that a violation of this condition shall be considered a material breach and may result in the cancellation of the TIPS Sale at the TIPS Member’s discretion. Vendor must identify any additional costs associated with compliance of this term. If no costs are specified, compliance with this term will be provided at no additional charge. Safety Measures: Vendor shall take all reasonable precautions for the safety of employees on the worksite, and shall erect and properly maintain all necessary safeguards for protection of workers and the public. Vendor shall post warning signs against all hazards created by the operation and work in progress. Proper precautions shall be taken pursuant to state law and standard practices to protect workers, general public and existing structures from injury or damage. Smoking: Persons working under Agreement shall adhere to the TIPS Member’s or local smoking statutes, codes, ordinances, and policies.
Agreement Xxx 0000 The Company shall not produce iron ore under this Agreement for transportation in any calendar year in excess of the approved production limit nor shall the total number of the mine workforce exceed the approved mine workforce without the prior consent in principle of the Minister and, subject to that consent, approval of detailed proposals in regard thereto in accordance with this Clause.
Contract Document This Contract is composed of Sections 1 through 9, Exhibits A through F, Attachments 1 through and any exhibits referenced in said attachments, and any documents incorporated by reference, which contain all the terms and conditions agreed upon by the parties.
1.4.1. The definitions found in the Standard Contract Definitions, located at: xxxx://xxx.xxx.xxxxx.xx.xx/admin/contracts/docs/GlossaryofContractTerms.pdf are incorporated into and made a part of this Contract. Additional definitions may be set forth in Exhibit A, Special Provisions.
1.4.2. The PUR 1000 Form (10/06 version) is hereby incorporated into and made a part of this Contract. Sections 1.d., 2-4, 6, 8- 13, 23, 27 and 31 of the PUR 1000 Form are not applicable to this Contract. In the event of any conflict between the PUR 1000 Form and any other terms or conditions of this Contract, such other terms or conditions shall take precedence over the PUR 1000 Form.
1.4.3. The terms of Exhibit A, Special Provisions, supplement or modify the terms of Sections 1 through 9, as provided therein.
1.4.4. In the event of a conflict between the provisions of the documents, the documents shall be interpreted in the following order of precedence:
1.4.4.1. Exhibits A through F;
1.4.4.2. Any documents incorporated into any exhibit by reference;
1.4.4.3. This Standard Integrated Contract;
1.4.4.4. Any documents incorporated into this Contract by reference;
1.4.4.5. Attachments 1 through .
Additional Requirements for Sleeping Rooms The Contractor shall provide departing Attendees a secured area for storing belongings.
TIPS Sales and Supplemental Agreements If awarded, when making a sale under this awarded contract, the terms of the specific TIPS order, including but not limited to: shipping, freight, insurance, delivery, fees, bonding, cost, delivery expectations and location, returns, refunds, terms, conditions, cancellations, defects, order assistance, etc., shall be controlled by the purchase agreement (Purchase Order, Contract, AIA Contract, Invoice, etc.) (“Supplemental Agreement” as used herein) entered into between the TIPS Member Customer and Vendor only. TIPS is not a party to any Supplemental Agreement. All Supplemental Agreements shall include Vendor’s Name, as known to TIPS, and TIPS Contract Name and Number. Vendor accepts and understands that TIPS is not a legal party to TIPS Sales and Vendor is solely responsible for identifying fraud, mistakes, unacceptable terms, or misrepresentations for the specific order prior to accepting. Vendor agrees that any order issued from a customer to Vendor, even when processed through TIPS, constitutes a legal contract between the customer and Vendor only. When Vendor accepts or fulfills an order, even when processed through TIPS, Vendor is representing that Vendor has carefully reviewed the order for legality, authenticity, and accuracy and TIPS shall not be liable or responsible for the same. In the event of a conflict between the terms of this TIPS Vendor Agreement and those contained in any Supplemental Agreement, the provisions set forth herein shall control unless otherwise agreed to and authorized by the Parties in writing within the Supplemental Agreement. The Supplemental Agreement shall dictate the scope of services, the project delivery expectations, the scheduling of projects and milestones, the support requirements, and all other terms applicable to the specific sale(s) between the Vendor and the TIPS Member.
Minimum Customer Support Requirements for TIPS Sales Vendor shall provide timely and commercially reasonable support for TIPS Sales or as agreed to in the applicable Supplemental Agreement.
Minimum Shipping Requirements for TIPS Sales Vendor shall ship, deliver, or provide ordered goods and services within a commercially reasonable time after acceptance of the order. If a delay in delivery is anticipated, Vendor shall notify the TIPS Member as to why delivery is delayed and provide an updated estimated time for completion. The TIPS Member may cancel the order if the delay is not commercially acceptable or not consistent with the Supplemental Agreement applicable to the order.
Custom Products Effective upon creation of Custom Products, Contractor hereby conveys, assigns and transfers to Authorized User the sole and exclusive rights, title and interest in Custom Product(s), whether preliminary, final or otherwise, including all trademark and copyrights. Contractor hereby agrees to take all necessary and appropriate steps to ensure that the Custom Products are protected against unauthorized copying, reproduction and marketing by or through Contractor, its agents, employees, or Subcontractors. Nothing herein shall preclude the Contractor from otherwise using the related or underlying general knowledge, skills, ideas, concepts, techniques and experience developed under a Purchase Order, project definition or work order in the course of Contractor’s business. Authorized User may, by providing written notice thereof to the Contractor, elect in the alternative to take a non-exclusive perpetual license to Custom Products in lieu of Authorized User taking exclusive ownership and title to such Products. In such case, Licensee on behalf of all Authorized Users shall be granted a non-exclusive perpetual license to use, execute, reproduce, display, perform, adapt and distribute Custom Product as necessary to fully effect the general business purpose(s) as stated in paragraph (b)(i)(2), above.
C1 Contract Price In consideration of the Contractor’s performance of its obligations under the Contract, the Authority shall pay the Contract Price in accordance with clause C2 (Payment and VAT).
