Force Majeure Affecting Subcontractor Sample Clauses

Force Majeure Affecting Subcontractor. If any Subcontractor is entitled under any contract or agreement relating to the Works to relief from force majeure on terms additional to or broader than those specified in this Clause or such additional or broader force majeure events or circumstances shall not excuse the Contractor's non-performance or entitle the Contractor to any relief under this Clause.
Sample 1Sample 2Sample 3See All (14)
AutoNDA by SimpleDocs
Force Majeure Affecting Subcontractor. If any Subcontractor is entitled under any contract or agreement relating to the Works to relief from force majeure on terms additional to or broader than those specified in this clause 19, such additional or broader force majeure events or circumstances shall not excuse the Contractor's non-performance or entitle him to relief under this clause. In the event that delivery to the Contractor of components of the Works provided by any suppliers or Subcontractors is delayed due to Force Majeure affecting the suppliers or Subcontractors respectively for more than two months, and such delay is beyond the control of the Contractor, the Employer may, upon written notice to Contractor, request that the Contractor substitute another entity to provide the components and/or services provided by relevant suppliers or Subcontractors, respectively. The Employer and the Contractor shall discuss such request in good faith with a view to agreeing on the replacement supplier or Subcontractor. The Contract Price shall not change in the event of a replacement of any supplier or Subcontractor save that the Contract Price shall be reduced by the full amount of any reduction in the price of the relevant part of the Works obtained from an alternative supplier or Subcontractor.
Sample 1Sample 2Sample 3See All (10)
Force Majeure Affecting Subcontractor. If any Subcontractor is entitled under any contract or agreement relating to the Works to relief from force majeure on terms additional to or broader than those specified in this clause 19, such additional or broader force majeure events or circumstances shall not excuse the Contractor's non-performance or entitle him to relief under this clause. In the event that delivery to the Contractor of components of the Works provided by any suppliers or Subcontractors is delayed due to Force Majeure affecting the suppliers or Subcontractors respectively for more than two months, and such delay is beyond the control of the Contractor, the Employer may, upon written notice to Contractor, request that the Contractor substitute another entity to provide the components and/or services provided by relevant suppliers or Subcontractors, respectively. The Employer and the Contractor shall discuss such request in good faith with a view to agreeing on the replacement supplier or Subcontractor. The Contract Price shall not change in the event of a replacement of any supplier or Subcontractor save that the Contract Price shall be reduced by the full amount of any reduction in the price of the relevant part of the Works obtained from an alternative supplier or Subcontractor. In such circumstances, any dates in this Contract relating to the delivery of Plant, Materials and/or Equipment shall be modified in accordance with the new delivery dates provided by the new suppliers or Subcontractors provided that the Contractor shall use its best endeavours to agree the earliest delivery date with such new supplier or Subcontractor and that if delivery has not occurred by 30 November 2006, the Employer shall be entitled to terminate this Contract in which case clause 15.5 [Employer's Entitlement to Termination] shall apply. The Employer and the Contractor shall confirm such new dates in writing.
Sample 1Sample 2
Force Majeure Affecting Subcontractor. Amend the title to read “Force Majeure Affecting Subcontractor and supplier”. In the 1st line insert “or supplier” after the word “Subcontractor”
Sample 1
Force Majeure Affecting Subcontractor. 不可抗力影响分包商 If any Subcontractor is entitled under any contract or agreement relating to the Works to relief from force majeure on terms additional to or broader than those specified in this Clause, such additional or broader force majeure events or circumstances shall not excuse the Contractor’s non-performance or entitle him to relief under this Clause. 如果任何分包商根据有关工程的任何合同或协议，有权因较本条规定更多或更广泛范围的不可抗力免除其某些义务，此类更多或更广的不可抗力事件或情况，不应成为承包商不履约的借口，或有权根据本条规定免除其义务。
Sample 1

Related to Force Majeure Affecting Subcontractor

  • Force Majeur In case the Show Facility is damaged or destroyed, or in case of war, government regulations or any other circumstances whatsoever which will make it impossible or impractical for Show Management to permit Exhibitor to occupy the exhibit space described in this Agreement, this Agreement will terminate and Exhibitor will waive any claim for damages for compensation except the pro rata return of the amount paid for space rented, diminished only by a pro rata portion of the amounts expended to produce the Show.

  • Subcontractor Any vendor, subcontractor or other Person that is not responsible for the overall servicing (as “servicing” is commonly understood by participants in the mortgage-backed securities market) of Mortgage Loans but performs one or more discrete functions identified in Item 1122(d) of Regulation AB with respect to Mortgage Loans under the direction or authority of the Servicer or a Subservicer.

  • Force Majeure If by reason of Force Majeure, either party hereto shall be rendered unable wholly or in part to carry out its obligations under this Agreement then such party shall give notice and full particulars of Force Majeure in writing to the other party within a reasonable time after occurrence of the event or cause relied upon, and the obligation of the party giving such notice, so far as it is affected by such Force Majeure, shall be suspended during the continuance of the inability then claimed, except as hereinafter provided, but for no longer period, and such party shall endeavor to remove or overcome such inability with all reasonable dispatch. Choice of Law The Agreement between the Vendor and TIPS/ESC Region 8 and any addenda or other additions resulting from this procurement process, however described, shall be governed by, construed and enforced in accordance with the laws of the State of Texas, regardless of any conflict of laws principles. Venue, Jurisdiction and Service of Process Any Proceeding arising out of or relating to this procurement process or any contract issued by TIPS resulting from or any contemplated transaction shall be brought in a court of competent jurisdiction in Camp County, Texas and each of the parties irrevocably submits to the exclusive jurisdiction of said court in any such proceeding, waives any objection it may now or hereafter have to venue or to convenience of forum, agrees that all claims in respect of the Proceeding shall be heard and determined only in any such court, and agrees not to bring any proceeding arising out of or relating to this procurement process or any contract resulting from or any contemplated transaction in any other court. The parties agree that either or both of them may file a copy of this paragraph with any court as written evidence of the knowing, voluntary and freely bargained for agreement between the parties irrevocably to waive any objections to venue or to convenience of forum. Process in any Proceeding referred to in the first sentence of this Section may be served on any party anywhere in the world. Venue for any dispute resolution process, other than litigation, between TIPS and the Vendor shall be located in Camp or Xxxxx County, Texas.

  • Contractor If COUNTY elects to renegotiate this Agreement due to reduced or terminated 20 funding, CONTRACTOR shall not be obligated to accept the renegotiated terms.

  • Subcontracting 6.1 The Grantee is responsible for the performance of its obligations under this Agreement, including in relation to any tasks undertaken by subcontractors.

  • Subcontractors The Contractor will not subcontract any work under the Contract without prior written consent of the Department. The Contractor is fully responsible for satisfactory completion of all its subcontracted work. The Department supports diversity in its procurements and contracts, and requests that the Contractor offer subcontracting opportunities to certified woman-, veteran-, and minority-owned small businesses. The Contractor may contact the OSD at xxxxxxx@xxx.xxxxxxxxx.xxx for information on certified small business enterprises available for subcontracting opportunities.

  • Force Majeure Event 16.1 If a Force Majeure Event gives rise to a failure or delay in either party performing any obligation under this Agreement (other than any obligation to make a payment), that obligation will be suspended for the duration of the Force Majeure Event.

  • Force Majeure Events a) Neither Party shall be responsible or liable for or deemed in breach hereof because of any delay or failure in the performance of its obligations hereunder (except for obligations to pay money due prior to occurrence of Force Majeure events under this Agreement) or failure to meet milestone dates due to any event or circumstance (a "Force Majeure Event") beyond the reasonable control of the Party experiencing such delay or failure, including the occurrence of any of the following:

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!