Force Majeure Termination - Construction Period Sample Clauses

Force Majeure Termination - Construction Period. Upon a Force Majeure Termination during the Construction Period, the Province shall pay to the Contractor a Termination Payment equal to the lesser of: (a) the Capital Amount less the Progress Payments that the Contractor has received; and (b) the amount actually expended (including any irrevocable commitment to purchase and pay for materials not readily returnable or readily deployable other than on the Project provided arrangements are made satisfactory to the Province acting reasonably, to transfer to the Province ownership of such materials free and clear of any security interests) in furtherance of the design, build and financing of the Project by the Contractor, less the amount of any Progress Payments that the Contractor has received (but without duplication of any Progress Payments the Contractor had become entitled to receive from the Province but had not yet received); less, in either case, all insurance proceeds, if any, legally claimable by the Contractor as a result of events occurring prior to the Force Majeure Termination.
AutoNDA by SimpleDocs
Force Majeure Termination - Construction Period. ‌ Upon a Force Majeure Termination during the Construction Period, the Province shall pay to the Contractor a Termination Payment equal to the lesser of: (a) the Capital Amount less the Progress Payments that the Contractor has received; and (b) the amount actually expended (including any irrevocable commitment to purchase and pay for materials not readily returnable or readily deployable other than on the Project provided arrangements are made, satisfactory to the Province acting reasonably, to transfer to the Province ownership of such materials free and clear of any security interests) in furtherance of the design, build and financing of the Project by the Contractor, less the amount of any Progress Payments that the Contractor has received (but without duplication of any Progress Payments the Contractor had become entitled to receive from the Province but had not yet received), less, in either case, any Adjusted School Capital Payments that the Contractor has received multiplied by a factor of 1.25 (but without duplication of Adjusted School Capital Payments the Contractor has become entitled to receive from the Province but has not yet received), and all insurance proceeds, if any, that would be payable to the Contractor, pursuant to insurance coverages required to be obtained by the Contractor pursuant to Section 11, and as a result of events occurring prior to the Force Majeure Termination and having a bearing on the Termination Payment determined in accordance with this Section 18.7, assuming that the applicable insurance policy was compliant with the requirements of Section 11 and Schedule 11 (Insurance Requirements), that the Contractor had fully complied with all terms of the applicable insurance policy and had made the required disclosures to the insurer, and assuming that the insurer is capable of paying; and less all other insurance proceeds received or to be received by the Contractor as a result of events occurring prior to the Force Majeure Termination and not applied by the Contractor against the loss for which the insurance was obtained.
Force Majeure Termination - Construction Period. Upon a Force Majeure Termination during the Construction Period, the Province shall pay to the Contractor a Termination Payment equal to the lesser of: (a) the Force Majeure Capital Amount; and (b) the amount (to a maximum of the amount of the Project Financing) actually expended in furtherance of the design, build and financing of the Project by the Contractor, less the amount of any Progress Payments that the Contractor has received or become entitled to receive; less, in either case, all insurance proceeds, if any, claimable by the Contractor as a result of events occurring prior to the Force Majeure Termination.
Force Majeure Termination - Construction Period. Upon a Force Majeure Termination during the Construction Period, the Province shall pay to the Contractor a Termination Payment equal to the lesser of: (a) the Force Majeure Capital Amount; and (b) the amount (to a maximum of the amount of the Project Financing) actually expended (including any irrevocable commitment to purchase and pay for materials not readily returnable or readily deployable other than on the Project) in furtherance of the design, build and financing of the Project by the Contractor, less the amount of any Progress Payments that the Contractor has received (but without duplication of any Progress Payments the Contractor has become entitled to receive from the Province but has not yet received); less, in either case, all insurance proceeds, if any, claimable by the Contractor as a result of events occurring prior to the Force Majeure Termination.
Force Majeure Termination - Construction Period. Upon a Force Majeure Termination during the Construction Period, the Province shall pay to the Contractor a Termination Payment equal to the amount which is the sum of: (a) the amount the Contractor is entitled to for work on the Project satisfactorily completed (including work completed but not yet invoiced for) to the date of termination determined in accordance with Section 8 (Payment); (b) breakage costs that are commercially reasonable and consistent with market practice, as determined by the Province, payable to the Contractor’s subcontractors, having regard to customarily negotiated break fees between parties at arm’s length from one another, and subject in every case to a duty on the part of the subcontractor to mitigate its damages and subject to the Contractor’s duty in every instance to take all commercially reasonable measures to mitigate its damages or losses; and (c) fixed expenses of the Contractor, as determined by the Province, that would have been recovered as part of the progress payments after the date of termination, and subject to the Contractor’s duty to take all commercially reasonable measures to mitigate its losses.

Related to Force Majeure Termination - Construction Period

  • Force Majeure Delays In any case where either party hereto is required to do any act (other than the payment of money), delays caused by or resulting from Acts of God or Nature, war, civil commotion, fire, flood or other casualty, labor difficulties, shortages of labor or materials or equipment, government regulations, delay by government or regulatory agencies with respect to approval or permit process, unusually severe weather, or other causes beyond such party’s reasonable control the time during which act shall be completed, shall be deemed to be extended by the period of such delay, whether such time be designated by a fixed date, a fixed time or “a reasonable time.”

  • Termination for continuing Force Majeure Event Either Party may, by written notice to the other, terminate this Framework Agreement if a Force Majeure Event endures for a continuous period of more than one hundred and twenty (120) Working Days.

  • Termination Due to Force Majeure Event If the period of Force Majeure continues or is in the reasonable judgment of the Parties likely to continue beyond a period of 120 (one hundred and twenty) Days, the Parties may mutually decide to terminate this Agreement or continue this Agreement on mutually agreed revised terms. If the Parties are unable to reach an agreement in this regard, the Affected Party shall after the expiry of the said period of 120 (one hundred and twenty ) Days be entitled to terminate the Agreement in which event, the provisions of Articles 16 and 17 shall, to the extent expressly made applicable, apply.

  • Termination due to Force Majeure 13.5.1 If the Force Majeure Event or its effects continue to be present beyond the period as specified in Article 4.5.3, either Party shall have the right to cause termination of the Agreement. In such an event, this Agreement shall terminate on the date of such Termination Notice.

  • Termination Notice for Force Majeure Event If a Force Majeure Event subsists for a period of 180 (one hundred and eighty) days or more within a continuous period of 365 (three hundred and sixty five) days, either Party may in its discretion terminate this Agreement by issuing a Termination Notice to the other Party without being liable in any manner whatsoever, save as provided in this Article 34, and upon issue of such Termination Notice, this Agreement shall, notwithstanding anything to the contrary contained herein, stand terminated forthwith; provided that before issuing such Termination Notice, the Party intending to issue the Termination Notice shall inform the other Party of such intention and grant 15 (fifteen) days time to make a representation, and may after the expiry of such 15 (fifteen) days period, whether or not it is in receipt of such representation, in its sole discretion issue the Termination Notice.

  • Force Majeure If by reason of Force Majeure, either party hereto shall be rendered unable wholly or in part to carry out its obligations under this Agreement through no fault of its own then such party shall give notice and full particulars of Force Majeure in writing to the other party within a reasonable time after occurrence of the event or cause relied upon. Upon delivering such notice, the obligation of the affected party, so far as it is affected by such Force Majeure as described, shall be suspended during the continuance of the inability then claimed but for no longer period, and such party shall endeavor to remove or overcome such inability with all reasonable dispatch. In the event that Vendor’s obligations are suspended by reason of Force Majeure, all TIPS Sales accepted prior to the Force Majeure event shall be the legal responsibility of Vendor and the terms of the TIPS Sale Supplemental Agreement shall control Vendor’s failure to fulfill for a Force Majeure event.

  • Force Majeur In case the Show Facility is damaged or destroyed, or in case of war, government regulations or any other circumstances whatsoever which will make it impossible or impractical for Show Management to permit Exhibitor to occupy the exhibit space described in this Agreement, this Agreement will terminate and Exhibitor will waive any claim for damages for compensation except the pro rata return of the amount paid for space rented, diminished only by a pro rata portion of the amounts expended to produce the Show.

  • Notification of Force Majeure Event 11.5.1 The Affected Party shall give notice to the other Party of any event of Force Majeure as soon as reasonably practicable, but not later than seven (7) days after the date on which such Party knew or should reasonably have known of the commencement of the event of Force Majeure. If an event of Force Majeure results in a breakdown of communications rendering it unreasonable to give notice within the applicable time limit specified herein, then the Party claiming Force Majeure shall give such notice as soon as reasonably practicable after reinstatement of communications, but not later than one (1) day after such reinstatement. Provided that, such notice shall be a pre-condition to the Affected Party’s entitlement to claim relief under this Agreement. Such notice shall include full particulars of the event of Force Majeure, its effects on the Party claiming relief and the remedial measures proposed. The Affected Party shall give the other Party regular reports on the progress of those remedial measures and such other information as the other Party may reasonably request about the Force Majeure. 11.5.2 The Affected Party shall give notice to the other Party of (i) the cessation of the relevant event of Force Majeure; and (ii) the cessation of the effects of such event of Force Majeure on the performance of its rights or obligations/ roles under this Agreement, as soon as practicable after becoming aware of each of these cessations.

  • Termination for Force Majeure 15.5.1. The License Agreement may be terminated for Force Majeure Reasons as specified in Article -14.

  • Force Majeure Event After giving effect to any applicable provision, disruption fallback or remedy specified in, or pursuant to, the relevant Confirmation or elsewhere in this Agreement, by reason of force majeure or act of state occurring after a Transaction is entered into, on any day:— (1) the Office through which such party (which will be the Affected Party) makes and receives payments or deliveries with respect to such Transaction is prevented from performing any absolute or contingent obligation to make a payment or delivery in respect of such Transaction, from receiving a payment or delivery in respect of such Transaction or from complying with any other material provision of this Agreement relating to such Transaction (or would be so prevented if such payment, delivery or compliance were required on that day), or it becomes impossible or impracticable for such Office so to perform, receive or comply (or it would be impossible or impracticable for such Office so to perform, receive or comply if such payment, delivery or compliance were required on that day); or (2) such party or any Credit Support Provider of such party (which will be the Affected Party) is prevented from performing any absolute or contingent obligation to make a payment or delivery which such party or Credit Support Provider has under any Credit Support Document relating to such Transaction, from receiving a payment or delivery under such Credit Support Document or from complying with any other material provision of such Credit Support Document (or would be so prevented if such payment, delivery or compliance were required on that day), or it becomes impossible or impracticable for such party or Credit Support Provider so to perform, receive or comply (or it would be impossible or impracticable for such party or Credit Support Provider so to perform, receive or comply if such payment, delivery or compliance were required on that day), so long as the force majeure or act of state is beyond the control of such Office, such party or such Credit Support Provider, as appropriate, and such Office, party or Credit Support Provider could not, after using all reasonable efforts (which will not require such party or Credit Support Provider to incur a loss, other than immaterial, incidental expenses), overcome such prevention, impossibility or impracticability;

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!