Claims and Disputes A. Claims by CONTRACTOR shall be made in writing to the COUNTY within two (2) business days after the commencement of the event giving rise to such claim or CONTRACTOR shall be deemed to have waived the claim. All claims shall be priced in accordance with the section in this document entitled “Changes in Work”.
Resolution of Claims and Disputes 4.4.1 The Architect will review Claims and take one or more of the following preliminary actions within ten days of receipt of a Claim: (1) request additional supporting data from the claimant, (2) submit a schedule to the parties indicating when the Architect expects to take action, (3) reject the Claim in whole or in part, stating reasons for rejection, (4) recommend approval of the Claim by the other party or (5) suggest a compromise. The Architect may also, but is not obligated to, notify the surety, if any, of the nature and amount of the Claim.
Complaints and Disputes 28.1. If the Client wishes to report a complaint, he must send an email to the Company with the completed “Complaints Form” found on the Website. The Company will try to resolve it without undue delay and according to the Company’s Complaints Procedure for Clients.
Complaints and Dispute Resolution 16.1 Where a dispute arises in connection with any aspect of this Agreement, the parties acting with good faith, will use all reasonable endeavours to bring any such issue to the attention of the other party in a timely fashion and in any event within 60 days of any such dispute coming to their attention.
Disputes and Claims Failure to file such a protest within the time specified shall constitute agreement on the part of the Contractor with the terms, conditions, amounts and adjustments or non- adjustment to the contract price and/or contract time set forth in the field order.
Resolution of disputes and grievances (a) For the purpose of this clause 14, a dispute includes a grievance.
Mediation of Disputes In the event of any disputes arise between the parties under this Agreement, the parties agree to use the following procedure prior to and as a precondition to either party pursuing any other available remedies, including arbitration or litigation.
GOVERNING LAW AND DISPUTES 12.1 The Parties will make good faith efforts to resolve, in a confidential manner, any dispute which may arise under the Agreement, by escalating it to higher levels of management, prior to resorting to litigation or other legal process.
Resolving Disputes The Company and the customer will use all reasonable endeavours to resolve any dispute between them. If they cannot resolve their dispute between them, they will:-
LAW AND DISPUTES This agreement is governed by Federal law.
