General provisions regarding the construction of the Building and the Leasehold Sample Clauses

General provisions regarding the construction of the Building and the Leasehold. 11.3.1 The parties know that as a result of the decisions of any competent authority and/or the decisions of the Renter and/or anyone on its behalf, changes may be made to the planning and building of the Project and/or Building and/or Leasehold. In such case, it is agreed that the Building and Leasehold shall be built as close as possible to their description in the agreement and its appendices taking into consideration and subject to said changes. 11.3.2 The Renter may at any time, without requiring any consent of the Tenant, make any change or addition in the Project, at its sole discretion, both before the beginning of the term of rent and during and/or after it, including, but not only, additions or reduction of areas, addition of floors, areas or wings to the Commercial Center and/or to Building F and/or to the Building and/or converting closed or open Public Spaces into areas in the exclusive use of various users, changes to openings and passageways, changes to parking lots, to the usages of basements, to the entry openings (for pedestrians and vehicles) of the Commercial Center and/or Building F and/or the Building, to the security room and/or toilets, additions and/or omissions of various building areas, and any other change to the construction or Project Plans, provided that no damage and/or unreasonable interruption is caused to the Leasehold, to the free access to the Leasehold, and to the Public Spaces joined to the Leasehold (hereinafter in this section: “the Changes”). The Tenant shall be prevented from making any contentions and/or claims and/or demands against the Renter and/or anyone on its behalf in connection with performing the Changes, all or some of them, and the Tenant undertakes not to interrupt or object to any Change or addition as aforesaid for any reason, including no such objection to reasonable interruptions caused to it, if any, during the performance of the addition and Change. This is a material term of this agreement.
Sample 1
AutoNDA by SimpleDocs

Related to General provisions regarding the construction of the Building and the Leasehold

  • Construction Phase - Administration of the Construction Contract INDICATE IN STATEMENT OF WORK “NOT APPLICABLE” IF SECTION IS NOT APPLICABLE 1.1.9.1. The Construction Phase will commence with the award of the Construction Contract to a selected vendor (“Contractor”) and will terminate when final payment is made by the State to the Contractor. In any event, the construction phase will not extend 60 days beyond the substantial completion date unless extended by change order. If such extension occurs, additional costs due to the ARCHITECT/ENGINEER shall be negotiated with the State. 1.1.9.2. The ARCHITECT/ENGINEER shall work with the State during the construction of the Project to provide the administration of the contract between the State and the Contractor in accordance with the terms herein and consistent with the contract between the State and the Contractor, and the extent of his/her duties and responsibilities and the limitations of his/her authority as assigned therein shall not be modified without his/her written consent. 1.1.9.3. The ARCHITECT/ENGINEER shall advise and consult with the State, and all of the State's instructions to the Contractor shall be issued through the ARCHITECT/ENGINEER after authorization by the State. 1.1.9.4. The ARCHITECT/ENGINEER shall, at all times, have access to the work wherever it is in preparation or progress. 1.1.9.5. The ARCHITECT/ENGINEER shall make periodic visits to the Project site, at least biweekly, and shall make such further visits when reasonably requested by the State, as to familiarize himself/herself with the progress and quality of the work performed and as to determine, on the basis of such visits, if such progress and quality are in accordance with the Contract Documents. The ARCHITECT/ENGINEER shall be responsible for project meeting minutes. In addition to this, the ARCHITECT/ENGINEER shall periodically report his/her findings thereon to the State, at such times as in the exercise of his/her professional judgment such findings are appropriate and at least monthly, at the conference provided for in Section 1.1.9.6, and further at such times as the State may reasonably request. The ARCHITECT/ENGINEER shall not be required to make exhaustive or continuous on-site inspections, except as required in the exercise of his/her professional judgment for said reports and, except in particular, to fulfill the commissioning requirements. The ARCHITECT/ENGINEER shall not be responsible for construction means, methods, techniques, sequences or procedures or for safety precautions and programs in connection with the work, and he/she shall not be responsible for the Contractor's failure to carry out the work in accordance with the Contract Documents except as provided for herein specifically between the State and the ARCHITECT/ENGINEER. 1.1.9.6. In preparing the bid documents, to the extent that the ARCHITECT/ENGINEER utilizes sub- consultants for their expertise, such as, but not limited to: Landscape Architects, Civil, Structural, Mechanical, and Electrical Engineers, these consultants, in effect, become an extension of the ARCHITECT/ENGINEER. Where the term ARCHITECT/ENGINEER is used in Section 1.1.9.2 as well as 1.1.9.5, it shall include those sub-consultants when work is being performed in their area of expertise. For example, the Mechanical Engineer would inspect the under slab plumbing before it is backfilled, but then wouldn’t necessarily be needed on site until the rest of the mechanical systems are being installed. The sub-consultant shall also be required to periodically inspect the progress of the “As-builts” and verify that they are up-to-date and verify such to the ARCHITECT/ENGINEER, before the ARCHITECT/ENGINEER issues the certificate of payment for that pay period. 1.1.9.7. Based upon his/her determinations and reports made under Section 1.1.9.5 of this Agreement and upon the Contractor's applications for payment, the ARCHITECT/ENGINEER shall once every month, after an on-site conference between the State, the Contractor and the ARCHITECT/ENGINEER, determine the amount then owing to the Contractor and shall then issue a certificate of payment for the amount agreed upon. The issuance of a Certificate for Payment shall constitute a representation by the ARCHITECT/ENGINEER to the State, based on such ARCHITECT/ENGINEER'S determination and report and the data supplied to him/her by the Contractor (without affecting his/her duties defined in Section 1.1.9.5.), that the work has progressed to the point indicated; that the quality of the work is in accordance with the Contract Documents (subject to the results of any specified subsequent tests required by the Contract Documents, to immaterial and insubstantial deviations from the Contract Documents, which will be corrected prior to completion, and to any further specific qualifications stated in the Certificate for Payment); and that the Contractor is entitled to such payment in the amount certified. Provided, however, the issuance of such certificate will not affect any obligations of the Contractor to the State. By issuing a certificate for payment, the ARCHITECT/ENGINEER shall not be deemed to represent that he/she has made any examination to ascertain how and for what purpose the Contractor has used the monies paid on account of the contract sum. ARCHITECT/ENGINEER shall not accept any part of the work on behalf of the State; ARCHITECT/ENGINEER may only recommend acceptance. Final acceptance is a right reserved solely to the State. 1.1.9.8. The ARCHITECT/ENGINEER shall be, in the first instance, the interpreter of the requirements of all Construction Documents, and shall have all requisite authority relating thereto for the purposes of authorizing the Contractor to proceed or stop with any component of the project after consultation and agreement with the State. The ARCHITECT/ENGINEER shall not be liable to the State for any loss or cost incurred by the State arising from delays in the construction schedule caused by any decision made by the ARCHITECT/ENGINEER in the reasonable exercise of professional judgment either to exercise or not to exercise his/her authority to stop the Work. 1.1.9.9. The ARCHITECT/ENGINEER shall review and respond to shop drawings, samples, and other submissions of the Contractor as in conformance with the design concept and information in the Contract Documents and the designs and plans relating to the project until approved or not requiring re-submission. The ARCHITECT/ENGINEER shall also review the submittal log at construction meetings and report to the State, on a monthly basis, their findings thereon. 1.1.9.10. The ARCHITECT/ENGINEER shall prepare all change orders and supporting data for the State's approval. 1.1.9.11. The ARCHITECT/ENGINEER shall conduct inspections to determine the Dates of Substantial Completion and Final Completion and shall receive written guarantees and related documents assembled by the Contractors and shall issue a final certificate of payment in accordance with Section 1.1.9.6. 1.1.9.12. The ARCHITECT/ENGINEER shall be responsible for system commissioning in accordance with the BGS Design Guidelines and as indicated in the BGS Commissioning Guidelines. Please see the BGS website xxxx://xxx.xxxxxxx.xxx/facilities/forms . The ARCHITECT/ENGINEER shall inspect, and document, each and every system to ensure that it complies with design intent, including but not limited to: system installation, system operation, and seasonal changeover. 1.1.9.13. Except in the manner specifically provided for herein, the ARCHITECT/ENGINEER shall not be responsible to the State for the acts or omissions of the Contractor or any of the Contractor’s agents or employees, or any other person not an employee or agent of the ARCHITECT/ENGINEER performing work on the Project. The ARCHITECT/ENGINEER shall be responsible for and shall pay the amount of any increase in the total Contract Price or the total Change Order(s) Price, which increase results from an error, inconsistency, or omission in the Contract Documents or instructions. 1.1.9.14. ARCHITECT/ENGINEER shall furnish to the State, a complete set of marked-up drawings and specifications showing all the changes to the Construction Documents made by Addenda, Change Orders, Shop Drawings, RFIs and other information received from the Clerk; and General Contractor’s As-built markups. The changes to the drawings are to be created on a separate layer in the DWG set and highlighted in a box, cloud or the like in the PDF set. The specifications are also to differentiate the changes made by highlighting in a box, cloud, etc. and be provided in Microsoft Word. These drawings and specifications shall be supplied within three (3) months of the date of Substantial Completion and before final payment. 1.1.9.15. Architect/Engineer (and design team members as required) shall conduct a one-year warranty inspection of the completed construction project between the eleventh and twelfth month from the date of substantial completion and shall issue a list of defective items needing correction to the Contractor.

  • Limitation of Vendor Indemnification and Similar Clauses This is a requirement of the TIPS Contract and is non-negotiable TIPS, a department of Region 8 Education Service Center, a political subdivision, and local government entity of the State of Texas, is prohibited from indemnifying third-parties (pursuant to the Article 3, Section 52 of the Texas Constitution) except as otherwise specifically provided for by law or as ordered by a court of competent jurisdiction. Article 3, Section 52 of the Texas Constitution states that "no debt shall be created by or on behalf of the State … " and the Texas Attorney General has opined that a contractually imposed obligation of indemnity creates a "debt" in the constitutional sense. Tex. Att'y Gen. Op. No. MW-475 (1982). Thus, contract clauses which require TIPS to indemnify Vendor, pay liquidated damages, pay attorney's fees, waive Vendor's liability, or waive any applicable statute of limitations must be deleted or qualified with ''to the extent permitted by the Constitution and Laws of the State of Texas." Does Vendor agree? Yes, I Agree TIPS, a department of Region 8 Education Service Center, a political subdivision, and local government entity of the State of Texas, does not agree to binding arbitration as a remedy to dispute and no such provision shall be permitted in this Agreement with TIPS. Vendor agrees that any claim arising out of or related to this Agreement, except those specifically and expressly waived or negotiated within this Agreement, may be subject to non-binding mediation at the request of either party to be conducted by a mutually agreed upon mediator as prerequisite to the filing of any lawsuit arising out of or related to this Agreement. Mediation shall be held in either Camp or Titus County, Texas. Agreements reached in mediation will be subject to the approval by the Region 8 ESC's Board of Directors, authorized signature of the Parties if approved by the Board of Directors, and, once approved by the Board of Directors and properly signed, shall thereafter be enforceable as provided by the laws of the State of Texas. Does Vendor agree? Yes, Vendor agrees Does Vendor agree? Yes, Vendor agrees Vendor agrees that nothing in this Agreement shall be construed as a waiver of sovereign or government immunity; nor constitute or be construed as a waiver of any of the privileges, rights, defenses, remedies, or immunities available to Region 8 Education Service Center or its TIPS Department. The failure to enforce, or any delay in the enforcement, of any privileges, rights, defenses, remedies, or immunities available to Region 8 Education Service Center or its TIPS Department under this Agreement or under applicable law shall not constitute a waiver of such privileges, rights, defenses, remedies, or immunities or be considered as a basis for estoppel. Does Vendor agree? Yes, Vendor agrees Vendor agrees that TIPS and TIPS Members shall not be liable for interest or late-payment fees on past-due balances at a rate higher than permitted by the laws or regulations of the jurisdiction of the TIPS Member. Funding-Out Clause: Vendor agrees to abide by the applicable laws and regulations, including but not limited to Texas Local Government Code § 271.903, or any other statutory or regulatory limitation of the jurisdiction of any TIPS Member, which requires that contracts approved by TIPS or a TIPS Member are subject to the budgeting and appropriation of currently available funds by the entity or its governing body.

  • Covenants and Conditions; Construction of Agreement All provisions of this Lease to be observed or performed by Lessee are both covenants and conditions. In construing this Lease, all headings and titles are for the convenience of the Parties only and shall not be considered a part of this Lease. Whenever required by the context, the singular shall include the plural and vice versa. This Lease shall not be construed as if prepared by one of the Parties, but rather according to its fair meaning as a whole, as if both Parties had prepared it.

  • Construction of Provisions Although certain provisions of this Agreement contain express language which precludes the Servicer's recovery of, or reimbursement for, expenses incurred hereunder, no inference to the contrary shall be drawn from absence of such, or similar, language in any other provision hereof regarding expenses.

  • CONSTRUCTION AND RENOVATION Construction and renovation projects for a state, local, territorial, or Tribal government’s principal Emergency Operations Center (EOC) as defined by the State Administrative Agency are allowable under the EMPG Program. Written approval must be provided by FEMA prior to the use of any EMPG Program funds for construction or renovation. Requests for EMPG Program funds for construction of an EOC must be accompanied by an EOC Investment Justification (located in the Related Documents tab of the EMPG xxxxxx.xxx posting) to their Regional EMPG Manager for review. Additionally, recipients are required to submit a SF-424C Form and Budget detail citing the project costs. When applying for funds to construct communication towers Sub-Recipients must submit evidence that the Federal Communication Commission’s (FCC) Section 106 review process has been completed and submit all documentation resulting from that review to Grants Program Directorate (GPD) prior to submitting materials for EHP review. Sub-Recipients are also encouraged to have completed as many steps as possible for a successful EHP review in support of their proposal for funding (e.g., coordination with their State Historic Preservation Office to identify potential historic preservation issues and to discuss the potential for project effects, compliance with all state and EHP laws and requirements). Projects for which the Sub-Recipient believes an Environmental Assessment (EA) may be needed, as defined in as defined in DHS Instruction Manual 023-01-001-01, Revision 01, FEMA Directive 108-1 and FEMA Instruction 108-1-1, must also be identified to the FEMA EMPG Regional Program Manager within six months of the award, and completed EHP review materials must be submitted no later than 12 months before the end of the period of performance. EHP review packets should be sent to xxxxxxxxxx@xxxx.xxx. EMPG Program Sub-Recipients using funds for construction projects must comply with the Xxxxx-Xxxxx Act (40 U.S.C. §§ 3141 et seq.). Grant Sub-Recipients must ensure that their contractors or subcontractors for construction projects pay workers no less than the prevailing wages for laborers and mechanics employed on projects of a character similar to the contract work in the civil subdivision of the state in which the work is to be performed. Additional information regarding compliance with the Xxxxx- Xxxxx Act, including Department of Labor (DOL) wage determinations, is available from the following website: xxxxx://xxx.xxx.xxx/whd/govcontracts/dbra.htm In general, Sub-Recipients should consult with their Grant Manager prior to making any investment that does not clearly meet the allowable expense criteria established in this Guidance.

  • LOCATION AND DESCRIPTION OF THE PROPERTY The subject property is a single-storey terraced house bearing the postal address of Xx. 00, Xxxxxx 00/XX0, Xxxxxx Xxxxx Xxxxxxx, 00000 Xxxxxxx Xxxxx, Xxxxxx. The subject property will be sold on an “as is where is basis” and subject to a reserve price of RM310,000.00 (RINGGIT MALAYSIA THREE HUNDRED TEN THOUSAND ONLY) and subject to the Conditions of Sale and by way of an Assignment from the above Assignee/Bank subject to the consent being obtained by the Purchaser from the Developer and other relevant authorities if any, including all terms, conditions, stipulations and covenants which were and may be imposed by the Developer and the relevant authorities. Any arrears of quit rent, assessments and service or maintenance charges which may be lawfully due to any relevant authority or the Developer up to the date of auction sale of the property shall be paid out of the purchase money upon receipt of full purchase price. All other fees, costs and charges relating to the transfer and assignment of the property shall be borne by the successful Purchaser. Online bidders are further subject to the Terms & Conditions on xxx.xxxxxxxxxxxxxxxx.xxx. All intending bidders are required to deposit 10% of the fixed reserve price for the said property by Bank Draft or Cashier’s Order in favour of UOBM for KRISHNAMAL A/P MURLIGIAH & XXXXXXXXXXX A/L XXXXXXX or remit the same through online banking transfer, one (1) working day before auction date. The balance of the purchase money shall be paid by the Purchaser within one hundred and twenty (120) days from the date of auction sale to UNITED OVERSEAS BANK (MALAYSIA) BHD via Real Time Electronics Transfer of Funds and Securities (XXXXXX). For online bidders please refer to the Terms & Conditions on xxx.xxxxxxxxxxxxxxxx.xxx on the manner of payment of the deposit. FOR FURTHER PARTICULARS, please contact M/S HOE & MOIRA, of Xxxxx 000X (Xxxxx), 0xx Xxxxx, Xxxxx Xxxxxx Xxxxxx, Xxxxxxxxxx Xxxx, 00000 Xxxxxx, Xxxxxxxx. (Ref:H&M/MT/Z4P/CB23/16) Tel.: 00-000 0000, Fax: 00-000 0000) the Assignee herein or the undermentioned Auctioneer. Suite C-20-3A, Level 20, Block C, Megan Avenue II, / XXXXX XXXXX BIN XXXXXX 00, Xxxxx Xxx Xxxx Xxxx, 50450 Kuala Lumpur (Licensed Auctioneers) Tel No.: 00-0000 0000 Fax No.: 00-0000 0000 Our Ref: LIAN/UOB1035HM Website: xxx.xxxxxxxxxxxxxxxx.xxx E-mail: xxxx@xxxxxxxxxxxxxxxx.xxx [berkuatkuasa dari 1.11.2022, perniagaan perbankan pengguna (consumer banking business) CITIBANK BERHAD (No. Syarikat: 199401011410 (297089-M) telah dipindahmilik kepada xxx diletakhakkan kepada UOB di bawah Perintah Letakhak bertarikh 12.10.2022 melalui Mahkamah Tinggi Kuala Lumpur Saman Pemula No. WA-24NCC-903-09/2022] Dalam menjalankan xxx xxx kuasa xxxx telah diberikan kepada Pihak Pemegang Serahhak/Bank dibawah Perjanjian Kemudahan, Penyerahanhak xxx Surat Kuasa Wakil kesemuanya Bertarikh 09hb Julai, 2001 diantara Pihak Penyerahhak, Pihak Pelanggan xxx Pihak Pemegang Serahhak/Bank yang diperbuat dalam perkara diatas, adalah dengan ini diisytiharkan bahawa Pihak Pemegang Serahhak/Bank tersebut dengan bantuan Pelelong yang tersebut dibawah.

  • Severability; Construction Whenever possible, each provision of this Agreement shall be interpreted in such manner as to be effective and valid under applicable law, but if any provision of this Agreement shall be prohibited by or invalid under applicable law, such provision shall be ineffective only to the extent of such prohibition or invalidity, without invalidating the remainder of such provisions or the remaining provisions of this Agreement. The parties hereto have participated jointly in the negotiation and drafting of this Agreement. In the event an ambiguity or question of intent or interpretation arises, this Agreement shall be construed as if drafted jointly by the parties hereto, and no presumption or burden of proof shall arise favoring or disfavoring any party by virtue of the authorship of any of the provisions of this Agreement.

  • Additional Provisions Concerning the Collateral (a) To the maximum extent permitted by applicable law, and for the purpose of taking any action that the Collateral Agent may deem necessary or advisable to accomplish the purposes of this Agreement, each Grantor hereby (i) authorizes the Collateral Agent to execute any such agreements, instruments or other documents in such Grantor’s name and to file such agreements, instruments or other documents in such Grantor’s name and in any appropriate filing office, (ii) authorizes the Collateral Agent at any time and from time to time to file, one or more financing or continuation statements, and amendments thereto, relating to the Collateral (including, without limitation, any such financing statements that (A) describe the Collateral as “all assets” or “all personal property” (or words of similar effect) or that describe or identify the Collateral by type or in any other manner as the Collateral Agent may determine regardless of whether any particular asset of such Grantor falls within the scope of Article 9 of the Code or whether any particular asset of such Grantor constitutes part of the Collateral, and (B) contain any other information required by Part 5 of Article 9 of the Code for the sufficiency or filing office acceptance of any financing statement, continuation statement or amendment, including, without limitation, whether such Grantor is an organization, the type of organization and any organizational identification number issued to such Grantor) and (iii) ratifies such authorization to the extent that the Collateral Agent has filed any such financing or continuation statements, or amendments thereto, prior to the date hereof. A photocopy or other reproduction of this Agreement or any financing statement covering the Collateral or any part thereof shall be sufficient as a financing statement where permitted by law. (b) Each Grantor hereby irrevocably appoints the Collateral Agent as its attorney-in-fact and proxy, with full authority in the place and stead of such Grantor and in the name of such Grantor or otherwise, from time to time in the Collateral Agent’s discretion, to take any action and to execute any instrument which the Collateral Agent may deem necessary or advisable to accomplish the purposes of this Agreement, including, without limitation, (i) to obtain and adjust insurance required to be paid to the Collateral Agent pursuant to Section 6(e) hereof, (ii) to ask, demand, collect, sue for, recover, compound, receive and give acquittance and receipts for moneys due and to become due under or in respect of any Collateral, (iii) to receive, endorse, and collect any drafts or other Instruments, Documents and Chattel Paper in connection with clause (i) or (ii) above, (iv) to file any claims or take any action or institute any action, suit or proceedings which the Collateral Agent may deem necessary or desirable for the collection of any Collateral or otherwise to enforce the rights of the Collateral Agent and the Noteholders with respect to any Collateral, (v) to execute assignments, licenses and other documents to enforce the rights of the Collateral Agent and the Noteholders with respect to any Collateral, and (vi) to verify any and all information with respect to any and all Accounts. This power is coupled with an interest and is irrevocable until all of the Obligations are fully performed and Paid in Full. (c) For the purpose of enabling the Collateral Agent to exercise rights and remedies hereunder, at such time as the Collateral Agent shall be lawfully entitled to exercise such rights and remedies, and for no other purpose, each Grantor hereby grants to the Collateral Agent, to the extent assignable, an irrevocable, non-exclusive license (exercisable without payment of royalty or other compensation to any Grantor) to use, assign, license or sublicense any Intellectual Property in which such Grantor now or hereafter has any right, title or interest, wherever the same may be located, including, without limitation, in such license reasonable access to all media in which any of the licensed items may be recorded or stored and to all computer programs used for the compilation or printout thereof. Notwithstanding anything contained herein to the contrary, but subject to the provisions of the Securities Purchase Agreement that limit the right of any Grantor to dispose of its property, and Section 6(g) and Section 6(h) hereof, so long as no Event of Default shall have occurred and be continuing, any Grantor may exploit, use, enjoy, protect, license, sublicense, assign, sell, dispose of or take other actions with respect to the Intellectual Property in the ordinary course of its business and as otherwise expressly permitted by any of the other Transaction Documents. In furtherance of the foregoing, unless an Event of Default shall have occurred and be continuing, the Collateral Agent shall from time to time, upon the request of any Grantor, execute and deliver any instruments, certificates or other documents, in the form so requested, which such Grantor shall have certified are appropriate (in such Grantor’s judgment) to allow it to take any action permitted above (including relinquishment of the license provided pursuant to this clause (c) as to any Intellectual Property). Further, upon the full performance and Payment in Full of all of the Obligations, the Collateral Agent (subject to Section 11(e) hereof) shall release and reassign to any Grantor all of the Collateral Agent’s right, title and interest in and to the Intellectual Property, and the Licenses, all without recourse, representation or warranty whatsoever. The exercise of rights and remedies hereunder by the Collateral Agent shall not terminate the rights of the holders of any licenses or sublicenses theretofore granted by each Grantor in accordance with the second sentence of this clause (c). Each Grantor hereby releases the Collateral Agent from any claims, causes of action and demands at any time arising out of or with respect to any actions taken or omitted to be taken by the Collateral Agent under the powers of attorney granted herein other than actions taken or omitted to be taken through the Collateral Agent’s gross negligence or willful misconduct, as determined by a final judgment of a court of competent jurisdiction no longer subject to appeal. (d) If any Grantor fails to perform any agreement or obligation contained herein, the Collateral Agent may itself perform, or cause performance of, such agreement or obligation, in the name of such Grantor or the Collateral Agent, and the expenses of the Collateral Agent incurred in connection therewith shall be payable by such Grantor pursuant to Section 9 hereof and such obligation shall be secured by the Collateral. (e) The powers conferred on the Collateral Agent hereunder are solely to protect its interest in the Collateral and shall not impose any duty upon it to exercise any such powers. Except for the safe custody of any Collateral in its possession and the accounting for moneys actually received by it hereunder, the Collateral Agent shall have no duty as to any Collateral or as to the taking of any necessary steps to preserve rights against prior parties or any other rights pertaining to any Collateral. (f) Anything herein to the contrary notwithstanding (i) each Grantor shall remain liable under the Licenses and otherwise with respect to any of the Collateral to the extent set forth therein to perform all of its obligations thereunder to the same extent as if this Agreement had not been executed, (ii) the exercise by the Collateral Agent of any of its rights or remedies hereunder shall not release any Grantor from any of its obligations under the Licenses or otherwise in respect of the Collateral, and (iii) the Collateral Agent shall not have any obligation or liability by reason of this Agreement under the Licenses or with respect to any of the other Collateral, nor shall the Collateral Agent be obligated to perform any of the obligations or duties of any Grantor thereunder or to take any action to collect or enforce any claim for payment assigned hereunder. (g) As long as no Event of Default shall have occurred and be continuing and, other than in the case of a Bankruptcy Event of Default, until written notice shall be given to the applicable Grantor: (i) Each Grantor shall have the right, from time to time, to vote and give consents with respect to the Pledged Equity, or any part thereof for all purposes not inconsistent with the provisions of this Agreement, the Securities Purchase Agreement or any other Transaction Document; provided, however, that no vote shall be cast, and no consent shall be given or action taken, which would have the effect of impairing the position or interest of the Collateral Agent in respect of the Pledged Equity or which would authorize, effect or consent to (unless and to the extent expressly permitted by the Securities Purchase Agreement): (A) the dissolution or liquidation, in whole or in part, of a Pledged Entity; (B) the consolidation or merger of a Pledged Entity with any other Person; (C) the sale, disposition or encumbrance of all or substantially all of the assets of a Pledged Entity, except for Liens in favor of the Collateral Agent; (D) any change in the authorized number of shares, the stated capital or the authorized share capital of a Pledged Entity or the issuance of any additional shares of its Capital Stock; or (E) the alteration of the voting rights with respect to the Capital Stock of a Pledged Entity. (i) Each Grantor shall be entitled, from time to time, to collect and receive for its own use all cash dividends and interest paid in respect of the Pledged Equity to the extent not in violation of the Securities Purchase Agreement other than any and all: (A) dividends and interest paid or payable other than in cash in respect of any Pledged Equity, and instruments and other property received, receivable or otherwise distributed in respect of, or in exchange for, any Pledged Equity; (B) dividends and other distributions paid or payable in cash in respect of any Pledged Equity in connection with a partial or total liquidation or dissolution or in connection with a reduction of capital, capital surplus or paid-in capital of a Pledged Entity; and (C) cash paid, payable or otherwise distributed, in respect of principal of, or in redemption of, or in exchange for, any Pledged Equity; provided, however, that until actually paid all rights to such distributions shall remain subject to the Lien created by this Agreement; and (ii) all dividends and interest (other than such cash dividends and interest as are permitted to be paid to any Grantor in accordance with clause (i) above) and all other distributions in respect of any of the Pledged Equity, whenever paid or made, shall be delivered to the Collateral Agent to hold as Pledged Equity and shall, if received by any Grantor, be received in trust for the benefit of the Collateral Agent (for the ratable benefit of the Collateral Agent and the Noteholders), be segregated from the other property or funds of such Grantor, and be forthwith delivered to the Collateral Agent as Pledged Equity in the same form as so received (with any necessary endorsement).

  • Suspension of unsafe Construction Works (i) Upon recommendation of the Authority’s Engineer to this effect, the Authority may by notice require the Contractor to suspend forthwith the whole or any part of the Works if, in the reasonable opinion of the Authority’s Engineer, such work threatens the safety of the Users and pedestrians. (ii) The Contractor shall, pursuant to the notice under Clause 11.17 (i), suspend the Works or any part thereof for such time and in such manner as may be specified by the Authority and thereupon carry out remedial measures to secure the safety of suspended works, the Users and pedestrians. The Contractor may by notice require the Authority’s Engineer to inspect such remedial measures forthwith and make a report to the Authority recommending whether or not the suspension hereunder may be revoked. Upon receiving the recommendations of the Authority’s Engineer, the Authority shall either revoke such suspension or instruct the Contractor to carry out such other and further remedial measures as may be necessary in the reasonable opinion of the Authority, and the procedure set forth in this Clause 11.17 shall be repeated until the suspension hereunder is revoked. (iii) Subject to the provisions of Clause 21.6, all reasonable costs incurred for maintaining and protecting the Works or part thereof during the period of suspension (the “Preservation Costs”), shall be borne by the Contractor; provided that if the suspension has occurred as a result of any breach of this Agreement by the Authority, the Preservation Costs shall be borne by the Authority. (iv) If suspension of Works is for reasons not attributable to the Contractor, the Authority’s Engineer shall determine any Time Extension to which the Contractor is reasonably entitled.

  • Commencement and Completion of Construction Subject to Unavoidable Delays, Developer shall cause construction of the Minimum Improvements to be undertaken and completed: (i) by no later than June 1, 2020; or (ii) by such other date as the parties shall mutually agree upon in writing. Time lost as a result of Unavoidable Delays shall be added to extend this date by a number of days equal to the number of days lost as a result of Unavoidable Delays. All work with respect to the Minimum Improvements shall be in conformity with the Construction Plans approved by the building official or any amendments thereto as may be approved by the building official. Developer agrees that it shall permit designated representatives of the City, upon reasonable notice (which does not have to be written), to enter upon the Development Property during the construction of the Minimum Improvements to inspect such construction and the progress thereof.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!