HIGHWAYS WORKS Sample Clauses

HIGHWAYS WORKS. Not to Commence the Development unless and until the Owners have entered into a Highways Agreement with the Council to undertake the Highways Works; and Not to first Occupy cause or permit to be first Occupied any part of the Development unless and until the Owners have undertaken the Highways Works in accordance with the terms of the Highways Agreement Not to first Occupy cause or permit to be first Occupied any part of the Development unless and until it has paid to the Highways Contribution to the Council

HIGHWAYS WORKS. 2.1 Subject to the conditions set out in the First Schedule hereof Sandwell hereby transfers to Dudley from the commencement of the construction period until substantial completion of the Construction Contract all the functions of the Highway Authority in respect of the Sandwell Highway to enable Dudley to carry out the Highway Works 2.2 The Certified Costs of the Highway Works shall be borne by Dudley following the approval of funding from the DfT at Full Approval stage based on the Works Cost estimate at Schedule Two save for any Certified Costs over and above the grant receivable under the DfT approval which shall be borne by the parties in equal shares 2.3 At all times during the continuance of the Agreement the parties hereto shall in the exercise of their functions observe the conditions set out in the First Schedule hereto 2.4 Dudley in exercising any highway functions hereunder shall be liable in respect of all claims arising out of such exercise and will indemnify and keep Sandwell fully and effectually indemnified in respect of all such claims 2.5 Any claims under the Land Compensation Act 1973 and any costs awarded to claimants together with any expenses thereby incurred shall in the first instance be paid from any remaining funding received from DfT and if no such funding is available shall be shared by Sandwell and Xxxxxx in equal shares.

HIGHWAYS WORKS. The Council hereby covenants that it shall by itself or its contractor carry out the Highway Works hereto and that it will co-ordinate manage and supervise the Highway Works. The Council shall or shall procure that its contractor use its reasonable endeavours to carry out and complete the Highway Works in accordance with the Highways Plan within 18 months from the date of receipt of the Highway Works Contribution provided that this obligation shall not be deemed to be contravened by any unavoidable delay arising from the need to open any part of the Highway Works or any other land in the vicinity of the Highway Works for purposes connected with the provision of services by statutory authorities or statutory undertakers or arising from circumstances relating to the physical nature of the land being developed or of the works which were not reasonably foreseen by both parties at the commencement of the Highway Works and in each case the Council shall notify the Owner in writing of any such delay and shall provide details of the same. Immediately following the completion of this Agreement the Council and the Owners shall use all reasonable endeavours to agree:

HIGHWAYS WORKS