Technical Support Services 2.1 The technical support services (the "Services"): Party A agrees to provide to Party B the relevant services requested by Party B, which are specified in Exhibit 1 attached hereto ("Exhibit 1").
Technical Support State Street will provide technical support to assist the Fund in using the System and the Data Access Services. The total amount of technical support provided by State Street shall not exceed 10 resource days per year. State Street shall provide such additional technical support as is expressly set forth in the fee schedule in effect from time to time between the parties (the “Fee Schedule”). Technical support, including during installation and testing, is subject to the fees and other terms set forth in the Fee Schedule.
Uncovering and Correction of Work 12.1 The Contractor shall promptly correct Work rejected by the Owner or failing to conform to the requirements of the Contract Documents, whether observed before or after Substantial Completion and whether or not fabricated, installed or completed, and shall correct any Work found to be not in accordance with the requirements of the Contract Documents within a period of two years from the date of Substantial Completion, or by terms of an applicable special warranty required by the Contract Documents. The provisions of this Article apply to work done by Subcontractors as well as to Work done by direct employees of the Contractor. 12.2 At any time during the progress of the work, or in any case where the nature of the defects shall be such that it is not expedient to have them corrected, the Owner, at their option, shall have the right to deduct such sum, or sums, of money from the amount of the contract as they consider justified to adjust the difference in value between the defective work and that required under contract including any damage to the structure.
Training and Support Licensor shall offer installation support to the Licensee and each of the Members, including assisting with the implementation of any Licensor software. Licensor will provide appropriate training to Licensee and Member staff relating to the use of the Licensed Materials and any Licensor software. Licensor will offer reasonable levels of continuing support to assist Licensee and Members in use of the Licensed Materials, including providing help files and other appropriate user documentation in connection with the use of and access to Licensed Materials. Licensor will, at a minimum, make its personnel available by email, telephone or via the Web, or in person during Licensor’s regular business hours, Monday through Friday, for training and user access support.
Maintenance and Support Services If this Agreement is for IT goods or services, this section applies: Unless otherwise specified in this Agreement: The Contractor shall promptly provide the Court with all Upgrades, including without limitation: (i) all Upgrades generally made available by Contractor to its other customers; (ii) Upgrades as necessary so that the Work complies with the Specifications and Applicable Law (including changes in Applicable Law); (iii) Upgrades as necessary so that the Work operates under new versions or releases of the Court’s operating system or database platform; and (iv) all on-site services necessary for installation of Upgrades. Without limiting any other obligation of Contractor under this Agreement, Contractor represents and warrants that it will maintain services, equipment, software or any other part of the Work so that they operate in accordance with their Specifications and Documentation; and The Contractor shall respond to the Court within four (4) hours after the Court reports a Technical Support Incident (such hours all occurring during Standard M&S Hours) to Contractor. DELIVERY, ACCEPTANCE, AND PAYMENT Delivery. Contractor shall deliver to the Court the Deliverables in accordance with this Agreement, including the Statement of Work. Unless otherwise specified by this Agreement, Contractor will deliver all goods purchased by the Court “Free on Board Destination Freight Prepaid” to the Court at the address and location specified by the Court. Title to all goods purchased by the Court vests in the Court upon payment of the applicable purchase price. Contractor will bear the risk of loss for any Work being delivered until received by the Court at the proper location. All shipments by Contractor or its Subcontractors must include packing sheets identifying: this Agreement number, the Court’s purchase order number, item number, quantity and unit of measure, part number and description of the goods shipped, and appropriate evidence of inspection, if required. Goods for different Agreements shall be listed on separate packing sheets.
Statement of Work The Statement of Work to which Grantee is bound is incorporated into and made a part of this Grant Agreement for all purposes and included as Attachment A.
Manufacturing and Supply (a) Depomed shall supply Product for use in conducting Depomed’s development activities for Product in the Field and in the Territory as set forth in Exhibit D. (b) During the four-year period beginning on the Effective Date (the “Supply Period”), Depomed shall supply and package (or have supplied and packaged) Product pursuant to this Section 4.8. Depomed will use commercially reasonable efforts to enter into a long-term Product supply agreement with [***] days after the Effective Date (the “Depomed Supply Agreement”) that will be freely assignable to Solvay or its Affiliates, successors or assigns at any time. In addition, Depomed and Solvay will negotiate and enter into a Product supply agreement with business terms substantially similar to the Depomed Supply Agreement concurrently with the execution and delivery by Depomed and [***] of the Depomed Supply Agreement (the “Solvay Supply Agreement”, and, together with the Depomed Supply Agreement, the “Supply Agreements”). The Supply Agreements will, together, contain the following provisions (among others mutually agreeable to the Parties): (i) Under the Solvay Supply Agreement, Depomed will agree to supply Solvay with its requirements of finished, packaged Product during the Supply Period; (ii) All manufacturing and records will be performed and maintained in accordance with specifications, cGMP and Applicable Law; (iii) Depomed will provide reasonable assistance to Solvay in the event Solvay wishes to qualify a backup Product manufacturer; (iv) Depomed shall [***]; (v) Solvay will pay Depomed the following amounts in connection with all activities performed by or on behalf of Depomed associated with Product manufacture and supply (other than activities specified on Exhibit D) (A) [***]% of Depomed’s out-of-pocket costs incurred in connection with such manufacture and supply of Product to Solvay, and (B) a labor charge equal to the FTE Charges for all Depomed employees allocated to the manufacture and supply of Product to Solvay, not to exceed FTE Charges for an aggregate of [***] during any given calendar quarter (and Depomed shall provide to Solvay periodic reports detailing the FTE Charges for which Solvay must pay Depomed hereunder);
DEVELOPMENT OR ASSISTANCE IN DEVELOPMENT OF SPECIFICATIONS REQUIREMENTS/ STATEMENTS OF WORK
Online Services Microsoft warrants that each Online Service will perform in accordance with the applicable SLA during Customer’s use. Customer’s remedies for breach of this warranty are described in the SLA.
Services and Support 1.1 In exchange for your continued compliance with this Agreement, and any modification to this Agreement made by Intuit in accordance with Sections A.1.1, you shall have access to the Software/Subscription in accordance with the following provisions: (a) If you purchased a Subscription based license for the Software, which generally means that you will be paying for your use of the Software and Services on a monthly or annual basis, you shall receive as part of your active Subscription, so long as Intuit is receiving the applicable payment from you: (i) access to the features of the Software subscribed to by you; (ii) Updates and Enhancements; (iii) Version Protection, each defined in Section B.1.2 below; and (iv) additional products, services and/or discounts when and if they should be made available to you. If you have purchased a subscription that includes Support you will also be entitled to receive Support Services as defined below. Software licenses obtained through a subscription are eligible for Enhancements during the active subscription period only. The Subscription is cancellable by you in accordance with this Agreement, but you will not be entitled to any refunds if you cancel after the 60-Day Money Back Guarantee period, as defined in Section B.6. If you cancel your Subscription or if we do not receive the payment for your Subscription, or if the Subscription is in any way terminated in accordance with the terms of this Agreement, you will no longer have access to the Software and all related Services defined above upon the expiration of the current Subscription term, but you will retain access to your company data file stored on your device, which can be reinstated to a readable QuickBooks format upon reactivation of your Subscription or with the purchase of a license on the Software. (b) If you purchased your license to the Software under a one-time, upfront payment at retail or directly from Intuit and not under a Subscription, you shall receive: (i) a license to the specific version of the Software product you have selected that, subject to the license grant and restrictions in Section A.1.1, allows you access to the features of the Software; and (ii) Updates and Enhancements to the Software in accordance with the terms of the Termination provisions. Intuit's obligations under this Section B.1.1 are contingent upon you installing all updates and error corrections within thirty (30) days of being notified of their availability by Intuit (or its Representatives). QuickBooks 2015 Software purchased on a separate standalone basis are eligible for enhancements on a when-and-if available basis through May 31, 2018, which is the current support period for QuickBooks 2015.
