Insurance by the Construction Agent Sample Clauses

Insurance by the Construction Agent. The Construction Agent shall cause to be procured with proceeds of Advances pursuant to, and subject to the terms and conditions of, the Operative Documents and maintain in full force and effect during the Construction Term insurance policies with insurance companies authorized to do business in each jurisdiction in which the Leased Properties under Construction are located with a Best Insurance Reports rating of “A” or better and a financial size category of “VIII” or higher, or that are pre-approved by the Lessor, with limits and coverage provisions as set forth below.
Sample 1
AutoNDA by SimpleDocs
Insurance by the Construction Agent. The Construction Agent shall maintain or cause others to maintain regarding the Property in full force and effect at all times during the Construction Period, insurance policies with (i) responsible insurance companies authorized to do business in Maryland (if so required by law or regulation) with (A) an A.M. Best’s Key Rating Guide rating of A or better and a financial size category of XI or higher, unless otherwise approved by the Lessor and the Agent or (B) an S&P or Mxxxx’x financial strength rating of A or A2, respectively, or higher, unless otherwise approved by the Lessor and the Agent, or (ii) other companies acceptable to the Lessor and the Agent with limits and coverage provisions sufficient to satisfy the requirements set forth below. In addition, the Construction Agent shall from time to time, but at intervals of not less than twelve (12) months each, undertake all actions and due diligence as reasonably necessary to determine whether the insurance coverage maintained by, or caused to be maintained by, the Construction Agent pursuant to this Agreement is in compliance with all of the requirements of this Agreement, including any increases in coverage required as a result of any change in any applicable Laws, and if the Construction Agent determines that such insurance coverage does not meet such requirements, it agrees to promptly cause such coverage to comply with such requirements and to notify the Lessor and the Agent of the steps being taken by the Construction Agent to do so.
Sample 1
Insurance by the Construction Agent. The Construction Agent shall maintain or cause others to maintain in full force and effect at all times prior to the Lease Commencement Date, insurance policies with responsible insurance companies authorized to do business in New Jersey (if so required by law or regulation) with (i) a Best Insurance Reports rating of "A-" or better and an financial size category of "IX" or higher, (ii) or a Standard & Poors financial strength rating of "BBB+" or higher, (iii) or other companies acceptable to the Lessor, with limits and coverage provisions sufficient to satisfy the requirements set forth below.
Sample 1
Insurance by the Construction Agent. The Construction Agent shall procure and maintain in full force and effect for each Construction Property during the Construction Period for such Construction Property insurance policies with insurance companies having a Best Insurance Reports rating of "A-" or better and a financial size category of "IX" or higher at the time of policy issuance with limits and coverage provisions as set forth below. GENERAL LIABILITY INSURANCE. Liability insurance on an occurrence basis against claims filed anywhere in the United States and occurring in anywhere in the United States for the Construction Agent's and Lessor's liability arising out of claims for personal injury (including bodily injury and death) and property damage. Such insurance shall provide coverage for products/completed operations, blanket contractual, broad form property damage, personal injury and independent contractors, with a $10,000,000 minimum limit per occurrence for combined bodily injury and property damage. A maximum deductible or self-insured retention of $25,000 per occurrence shall be allowed with respect to each Property. BUILDER'S RISK INSURANCE. Property damage insurance on an "all risk" basis insuring the Construction Agent the Lessor and the Construction Agent, as their interests may appear, including coverage against loss or damage from the perils of earth movement (including earthquake, landslide, subsidence and volcanic eruption), flood, and boiler and machinery accidents, and not containing any exclusions other than those listed on EXHIBIT B.
Sample 1

Related to Insurance by the Construction Agent

  • Construction Phase - Administration of the Construction Contract INDICATE IN STATEMENT OF WORK “NOT APPLICABLE” IF SECTION IS NOT APPLICABLE 1.1.9.1. The Construction Phase will commence with the award of the Construction Contract to a selected vendor (“Contractor”) and will terminate when final payment is made by the State to the Contractor. In any event, the construction phase will not extend 60 days beyond the substantial completion date unless extended by change order. If such extension occurs, additional costs due to the ARCHITECT/ENGINEER shall be negotiated with the State. 1.1.9.2. The ARCHITECT/ENGINEER shall work with the State during the construction of the Project to provide the administration of the contract between the State and the Contractor in accordance with the terms herein and consistent with the contract between the State and the Contractor, and the extent of his/her duties and responsibilities and the limitations of his/her authority as assigned therein shall not be modified without his/her written consent. 1.1.9.3. The ARCHITECT/ENGINEER shall advise and consult with the State, and all of the State's instructions to the Contractor shall be issued through the ARCHITECT/ENGINEER after authorization by the State. 1.1.9.4. The ARCHITECT/ENGINEER shall, at all times, have access to the work wherever it is in preparation or progress. 1.1.9.5. The ARCHITECT/ENGINEER shall make periodic visits to the Project site, at least biweekly, and shall make such further visits when reasonably requested by the State, as to familiarize himself/herself with the progress and quality of the work performed and as to determine, on the basis of such visits, if such progress and quality are in accordance with the Contract Documents. The ARCHITECT/ENGINEER shall be responsible for project meeting minutes. In addition to this, the ARCHITECT/ENGINEER shall periodically report his/her findings thereon to the State, at such times as in the exercise of his/her professional judgment such findings are appropriate and at least monthly, at the conference provided for in Section 1.1.9.6, and further at such times as the State may reasonably request. The ARCHITECT/ENGINEER shall not be required to make exhaustive or continuous on-site inspections, except as required in the exercise of his/her professional judgment for said reports and, except in particular, to fulfill the commissioning requirements. The ARCHITECT/ENGINEER shall not be responsible for construction means, methods, techniques, sequences or procedures or for safety precautions and programs in connection with the work, and he/she shall not be responsible for the Contractor's failure to carry out the work in accordance with the Contract Documents except as provided for herein specifically between the State and the ARCHITECT/ENGINEER. 1.1.9.6. In preparing the bid documents, to the extent that the ARCHITECT/ENGINEER utilizes sub- consultants for their expertise, such as, but not limited to: Landscape Architects, Civil, Structural, Mechanical, and Electrical Engineers, these consultants, in effect, become an extension of the ARCHITECT/ENGINEER. Where the term ARCHITECT/ENGINEER is used in Section 1.1.9.2 as well as 1.1.9.5, it shall include those sub-consultants when work is being performed in their area of expertise. For example, the Mechanical Engineer would inspect the under slab plumbing before it is backfilled, but then wouldn’t necessarily be needed on site until the rest of the mechanical systems are being installed. The sub-consultant shall also be required to periodically inspect the progress of the “As-builts” and verify that they are up-to-date and verify such to the ARCHITECT/ENGINEER, before the ARCHITECT/ENGINEER issues the certificate of payment for that pay period. 1.1.9.7. Based upon his/her determinations and reports made under Section 1.1.9.5 of this Agreement and upon the Contractor's applications for payment, the ARCHITECT/ENGINEER shall once every month, after an on-site conference between the State, the Contractor and the ARCHITECT/ENGINEER, determine the amount then owing to the Contractor and shall then issue a certificate of payment for the amount agreed upon. The issuance of a Certificate for Payment shall constitute a representation by the ARCHITECT/ENGINEER to the State, based on such ARCHITECT/ENGINEER'S determination and report and the data supplied to him/her by the Contractor (without affecting his/her duties defined in Section 1.1.9.5.), that the work has progressed to the point indicated; that the quality of the work is in accordance with the Contract Documents (subject to the results of any specified subsequent tests required by the Contract Documents, to immaterial and insubstantial deviations from the Contract Documents, which will be corrected prior to completion, and to any further specific qualifications stated in the Certificate for Payment); and that the Contractor is entitled to such payment in the amount certified. Provided, however, the issuance of such certificate will not affect any obligations of the Contractor to the State. By issuing a certificate for payment, the ARCHITECT/ENGINEER shall not be deemed to represent that he/she has made any examination to ascertain how and for what purpose the Contractor has used the monies paid on account of the contract sum. ARCHITECT/ENGINEER shall not accept any part of the work on behalf of the State; ARCHITECT/ENGINEER may only recommend acceptance. Final acceptance is a right reserved solely to the State. 1.1.9.8. The ARCHITECT/ENGINEER shall be, in the first instance, the interpreter of the requirements of all Construction Documents, and shall have all requisite authority relating thereto for the purposes of authorizing the Contractor to proceed or stop with any component of the project after consultation and agreement with the State. The ARCHITECT/ENGINEER shall not be liable to the State for any loss or cost incurred by the State arising from delays in the construction schedule caused by any decision made by the ARCHITECT/ENGINEER in the reasonable exercise of professional judgment either to exercise or not to exercise his/her authority to stop the Work. 1.1.9.9. The ARCHITECT/ENGINEER shall review and respond to shop drawings, samples, and other submissions of the Contractor as in conformance with the design concept and information in the Contract Documents and the designs and plans relating to the project until approved or not requiring re-submission. The ARCHITECT/ENGINEER shall also review the submittal log at construction meetings and report to the State, on a monthly basis, their findings thereon. 1.1.9.10. The ARCHITECT/ENGINEER shall prepare all change orders and supporting data for the State's approval. 1.1.9.11. The ARCHITECT/ENGINEER shall conduct inspections to determine the Dates of Substantial Completion and Final Completion and shall receive written guarantees and related documents assembled by the Contractors and shall issue a final certificate of payment in accordance with Section 1.1.9.6. 1.1.9.12. The ARCHITECT/ENGINEER shall be responsible for system commissioning in accordance with the BGS Design Guidelines and as indicated in the BGS Commissioning Guidelines. Please see the BGS website xxxx://xxx.xxxxxxx.xxx/facilities/forms . The ARCHITECT/ENGINEER shall inspect, and document, each and every system to ensure that it complies with design intent, including but not limited to: system installation, system operation, and seasonal changeover. 1.1.9.13. Except in the manner specifically provided for herein, the ARCHITECT/ENGINEER shall not be responsible to the State for the acts or omissions of the Contractor or any of the Contractor’s agents or employees, or any other person not an employee or agent of the ARCHITECT/ENGINEER performing work on the Project. The ARCHITECT/ENGINEER shall be responsible for and shall pay the amount of any increase in the total Contract Price or the total Change Order(s) Price, which increase results from an error, inconsistency, or omission in the Contract Documents or instructions. 1.1.9.14. ARCHITECT/ENGINEER shall furnish to the State, a complete set of marked-up drawings and specifications showing all the changes to the Construction Documents made by Addenda, Change Orders, Shop Drawings, RFIs and other information received from the Clerk; and General Contractor’s As-built markups. The changes to the drawings are to be created on a separate layer in the DWG set and highlighted in a box, cloud or the like in the PDF set. The specifications are also to differentiate the changes made by highlighting in a box, cloud, etc. and be provided in Microsoft Word. These drawings and specifications shall be supplied within three (3) months of the date of Substantial Completion and before final payment. 1.1.9.15. Architect/Engineer (and design team members as required) shall conduct a one-year warranty inspection of the completed construction project between the eleventh and twelfth month from the date of substantial completion and shall issue a list of defective items needing correction to the Contractor.

  • Law; Construction This Agreement and any claim, counterclaim or dispute of any kind or nature whatsoever arising out of or in any way relating to this Agreement (“Claim”), directly or indirectly, shall be governed by, and construed in accordance with, the internal laws of the State of New York.

  • Review by the Association of Procurement Decisions The Procurement Plan shall set forth those contracts which shall be subject to the Association’s Prior Review. All other contracts shall be subject to Post Review by the Association.

  • Contract Construction 6.27.1 The parties acknowledge that each party and its counsel have reviewed this CONTRACT and that the normal rule of construction to the effect that any ambiguities are to be resolved against the drafting party shall not be employed in the interpretation of this CONTRACT or any amendment or exhibits hereto.

  • Reliance by the State on Representations All payments by the State under this Agreement will be made in reliance upon the accuracy of all representations made by the Party in accordance with this Agreement, including but not limited to bills, invoices, progress reports and other proofs of work.

  • Routine Maintenance, Construction, and Repair The NYISO or Connecting Transmission Owner may interrupt interconnection service or curtail the output of the Small Generating Facility and temporarily disconnect the Small Generating Facility from the New York State Transmission System or Distribution System when necessary for routine maintenance, construction, and repairs on the New York State Transmission System or Distribution System. The NYISO or the Connecting Transmission Owner shall provide the Interconnection Customer with five Business Days notice prior to such interruption. The NYISO and Connecting Transmission Owner shall use Reasonable Efforts to coordinate such reduction or temporary disconnection with the Interconnection Customer.

  • Maintenance of Properties and Insurance (a) The Company shall cause all properties used or held for use in the conduct of its business or the business of any Subsidiary to be maintained and kept in good condition, repair and working order (ordinary wear and tear excepted) and supplied with all necessary equipment and shall cause to be made all necessary repairs, renewals, replacements, betterments and improvements thereof, all as in the judgment of the Company may be necessary so that the business carried on in connection therewith may be properly and advantageously conducted at all times; provided, however, that nothing in this Section shall prevent the Company from discontinuing the operation or maintenance of any such property, or disposing of it, if such discontinuance or disposal is, in the judgment of the Company, desirable in the conduct of its business and not disadvantageous in any material respect to the Holders. (b) The Company shall provide or cause to be provided, for itself and each of its Subsidiaries, insurance (including appropriate self-insurance) against loss or damage of the kinds that, in the reasonable, good faith opinion of the Company, are adequate and appropriate for the conduct of the business of the Company and such Subsidiaries in a prudent manner, with reputable insurers or with the government of the United States or an agency or instrumentality thereof, in such amounts, with such deductibles, and by such methods as shall be customary, in the reasonable, good faith opinion of the Company, for corporations similarly situated in the industry.

  • Maintenance of Properties; Insurance The Borrower will, and will cause each of its Subsidiaries to, (a) keep and maintain all property material to the conduct of its business in good working order and condition, ordinary wear and tear excepted, and (b) maintain, with financially sound and reputable insurance companies, insurance in such amounts and against such risks as are customarily maintained by companies engaged in the same or similar businesses operating in the same or similar locations.

  • Maintenance of Property; Insurance (a) Keep all property useful and necessary in its business in good working order and condition, ordinary wear and tear excepted and (b) maintain with financially sound and reputable insurance companies insurance on all its property in at least such amounts and against at least such risks (but including in any event public liability, product liability and business interruption) as are usually insured against in the same general area by companies engaged in the same or a similar business.

  • Maintenance of Hazard Insurance; Maintenance of Primary Insurance Policies (a) The Master Servicer shall maintain, for each Mortgage Loan, hazard insurance with extended coverage in an amount that is at least equal to the lesser of (i) the maximum insurable value of the improvements securing the Mortgage Loan and (ii) the greater of (y) the outstanding principal balance of the Mortgage Loan and (z) an amount such that the proceeds of the policy are sufficient to prevent the Mortgagor or the mortgagee from becoming a co-insurer. Each policy of standard hazard insurance shall contain, or have an accompanying endorsement that contains, a standard mortgagee clause. Any amounts collected under the policies (other than the amounts to be applied to the restoration or repair of the related Mortgaged Property or amounts released to the Mortgagor in accordance with the Master Servicer's normal servicing procedures) shall be deposited in the Certificate Account. Any cost incurred in maintaining any insurance shall not, for the purpose of calculating monthly distributions to the Certificateholders or remittances to the Trustee for their benefit, be added to the principal balance of the Mortgage Loan, notwithstanding that the Mortgage Loan so permits. Such costs shall be recoverable by the Master Servicer out of late payments by the related Mortgagor or out of Liquidation Proceeds to the extent permitted by Section 3.09. No earthquake or other additional insurance is to be required of any Mortgagor or maintained on property acquired in respect of a Mortgage other than pursuant to any applicable laws and regulations in force that require additional insurance. If the Mortgaged Property is located at the time of origination of the Mortgage Loan in a federally designated special flood hazard area and the area is participating in the national flood insurance program, the Master Servicer shall maintain flood insurance for the Mortgage Loan. The flood insurance shall be in an amount equal to the least of (i) the original principal balance of the related Mortgage Loan, (ii) the replacement value of the improvements that are part of the Mortgaged Property, and (iii) the maximum amount of flood insurance available for the related Mortgaged Property under the national flood insurance program. If the Master Servicer obtains and maintains a blanket policy insuring against hazard losses on all of the Mortgage Loans, it shall have satisfied its obligations in the first sentence of this Section 3.10. The policy may contain a deductible clause on terms substantially equivalent to those commercially available and maintained by comparable servicers. If the policy contains a deductible clause and a policy complying with the first sentence of this Section 3.10 has not been maintained on the related Mortgaged Property, and if a loss that would have been covered by the required policy occurs, the Master Servicer shall deposit in the Certificate Account, without any right of reimbursement, the amount not otherwise payable under the blanket policy because of the deductible clause. In connection with its activities as Master Servicer of the Mortgage Loans, the Master Servicer agrees to present, on behalf of itself, the Depositor, and the Trustee for the benefit of the Certificateholders, claims under any blanket policy. (b) The Master Servicer shall not take any action that would result in non-coverage under any applicable Primary Insurance Policy of any loss that, but for the actions of the Master Servicer, would have been covered thereunder. The Master Servicer shall not cancel or refuse to renew any Primary Insurance Policy that is in effect at the date of the initial issuance of the Certificates and is required to be kept in force hereunder unless the replacement Primary Insurance Policy for the canceled or non-renewed policy is maintained with a Qualified Insurer. The Master Servicer need not maintain any Primary Insurance Policy if maintaining the Primary Insurance Policy is prohibited by applicable law. The Master Servicer agrees, to the extent permitted by applicable law, to effect the timely payment of the premiums on each Primary Insurance Policy, and any costs not otherwise recoverable shall be recoverable by the Master Servicer from the related liquidation proceeds. In connection with its activities as Master Servicer of the Mortgage Loans, the Master Servicer agrees to present, on behalf of itself, the Trustee and the Certificateholders, claims to the insurer under any Primary Insurance Policies and, in this regard, to take any reasonable action in accordance with the Servicing Standard necessary to permit recovery under any Primary Insurance Policies respecting defaulted Mortgage Loans. Any amounts collected by the Master Servicer under any Primary Insurance Policies shall be deposited in the Certificate Account or the Collection Account (as applicable).

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!