Landlord Delays; Notices to Guarantor Sample Clauses

Landlord Delays; Notices to Guarantor. (a) Construction Schedule for Tenant Initial Work. On or before the date which is two (2) weeks after the date when Tenant shall have received the Preliminary Notice, Tenant shall deliver to Landlord a so-called "bar chart" construction schedule for the Tenant Initial Work. Updates of such schedule shall be delivered to Landlord at least monthly thereafter until Tenant has substantially completed the Tenant Initial Work. (b) There shall be a "Landlord Delay" if Tenant shall be actually delayed in commencing or completing the Tenant Initial Work, as a result of any of the following acts or omissions: (1) Landlord's failure to approve or accept (or to disapprove with comments) or its delay in approving or accepting (or disapproving with comments) the Final Working Drawings (or any portions or versions thereof), in accordance with the applicable time limitations set forth in Section 16.14; (2) any additional time required to complete the Tenant Initial Work caused by the failure of Landlord timely to respond to any Tenant requests for Change Orders pursuant to Section 16.5; (3) the failure of Landlord to respond within five (5) Business Days with respect to all issues which could not be addressed due to Landlord's failure to attend the coordination meetings contemplated in Section 16.12, as such issues are set forth in a notice delivered to Landlord promptly after the coordination meeting in question; (4) the performance of work by a contractor, vendor or employee of Landlord which delays completion of the Tenant Initial Work (unless a coordination issue within the ambit of Section 16.13(d), in which event Landlord Delay shall only be incurred if and to the extent Landlord fails to comply with the written decision of an Arbitrator pursuant to Section 34.3); (5) any violation against the Premises or the Building caused by Landlord, which delays Tenant in filing so-called "Directive 14's"; or
Sample 1
AutoNDA by SimpleDocs

Related to Landlord Delays; Notices to Guarantor

  • Notices to Landlord Tenant shall notify Landlord in writing as soon as possible but in no event later than five (5) days after (i) the occurrence of any actual, alleged or threatened Release of any Hazardous Material in, on, under, from, about or in the vicinity of the Premises (whether past or present), regardless of the source or quantity of any such Release, or (ii) Tenant becomes aware of any regulatory actions, inquiries, inspections, investigations, directives, or any cleanup, compliance, enforcement or abatement proceedings (including any threatened or contemplated investigations or proceedings) relating to or potentially affecting the Premises, or (iii) Tenant becomes aware of any claims by any person or entity relating to any Hazardous Materials in, on, under, from, about or in the vicinity of the Premises, whether relating to damage, contribution, cost recovery, compensation, loss or injury. Collectively, the matters set forth in clauses (i), (ii) and (iii) above are hereinafter referred to as “Hazardous Materials Claims”. Tenant shall promptly forward to Landlord copies of all orders, notices, permits, applications and other communications and reports in connection with any Hazardous Materials Claims. Additionally, Tenant shall promptly advise Landlord in writing of Tenant’s discovery of any occurrence or condition on, in, under or about the Premises that could subject Tenant or Landlord to any liability, or restrictions on ownership, occupancy, transferability or use of the Premises under any “Environmental Laws,” as that term is defined below. Tenant shall not enter into any legal proceeding or other action, settlement, consent decree or other compromise with respect to any Hazardous Materials Claims without first notifying Landlord of Tenant’s intention to do so and affording Landlord the opportunity to join and participate, as a party if Landlord so elects, in such proceedings and in no event shall Tenant enter into any agreements which are binding on Landlord or the Premises without Landlord’s prior written consent. Landlord shall have the right to appear at and participate in, any and all legal or other administrative proceedings concerning any Hazardous Materials Claim. For purposes of this Lease, “Environmental Laws” means all applicable present and future laws relating to the protection of human health, safety, wildlife or the environment, including, without limitation, (i) all requirements pertaining to reporting, licensing, permitting, investigation and/or remediation of emissions, discharges, Releases, or threatened Releases of Hazardous Materials, whether solid, liquid, or gaseous in nature, into the air, surface water, groundwater, or land, or relating to the manufacture, processing, distribution, use, treatment, storage, disposal, transport, or handling of Hazardous Materials; and (ii) all requirements pertaining to the health and safety of employees or the public. Environmental Laws include, but are not limited to, the Comprehensive Environmental Response, Compensation and Liability Act of 1980, 42 USC § 9601, et seq., the Hazardous Materials Transportation Authorization Act of 1994, 49 USC § 5101, et seq., the Solid Waste Disposal Act, as amended by the Resource Conservation and Recovery Act of 1976, and Hazardous and Solid Waste Amendments of 1984, 42 USC § 6901, et seq., the Federal Water Pollution Control Act, as amended by the Clean Water Act of 1977, 33 USC § 1251, et seq., the Clean Air Act of 1966, 42 USC § 7401, et seq., the Toxic Substances Control Act of 1976, 15 USC § 2601, et seq., the Safe Drinking Water Act of 1974, 42 USC §§ 300f through 300j, the Occupational Safety and Health Act of 1970, as amended, 29 USC § 651 et seq., the Oil Pollution Act of 1990, 33 USC § 2701 et seq., the Emergency Planning and Community Right-To-Know Act of 1986, 42 USC § 11001 et seq., the National Environmental Policy Act of 1969, 42 USC § 4321 et seq., the Federal Insecticide, Fungicide and Rodenticide Act of 1947, 7 USC § 136 et seq., California Xxxxxxxxx-Xxxxxxx-Xxxxxx Hazardous Substance Account Act, California Health & Safety Code §§ 25300 et seq., Hazardous Materials Release Response Plans and Inventory Act, California Health & Safety Code, §§ 25500 et seq., Underground Storage of Hazardous Substances provisions, California Health & Safety Code, §§ 25280 et seq., California Hazardous Waste Control Law, California Health & Safety Code, §§ 25100 et seq., and any other state or local law counterparts, as amended, as such applicable laws, are in effect as of the Lease Commencement Date, or thereafter adopted, published, or promulgated.

  • Notice to Tenants Seller and Purchaser shall each execute, and Purchaser shall deliver to each tenant immediately after the Closing, a notice regarding the sale in substantially the form of Exhibit D attached hereto, or such other form as may be required by applicable state law. This obligation on the part of Purchaser shall survive the Closing.

  • Notice to Landlord (1) If Tenant shall, on one or more occasions, mortgage Tenant’s Leasehold Estate and if the holder of such Permitted Leasehold Mortgage shall provide Landlord with written notice of such Permitted Leasehold Mortgage together with a true copy of such Permitted Leasehold Mortgage and the name and address of the Permitted Leasehold Mortgagee, Landlord and Tenant agree that, following receipt of such written notice by Landlord, the provisions of this Section 17.1 shall apply in respect to each such Permitted Leasehold Mortgage. (2) In the event of any assignment of a Permitted Leasehold Mortgage or in the event of a change of address of a Permitted Leasehold Mortgagee or of an assignee of such Mortgage, written notice of the new name and address shall be provided to Landlord. (ii) Landlord shall promptly upon receipt of a communication purporting to constitute the notice provided for by subsection (b)(i) above acknowledge by an executed and notarized instrument receipt of such communication as constituting the notice provided for by subsection (b)(i) above and confirming the status of the Permitted Leasehold Mortgagee as such or, in the alternative, notify the Tenant and the Permitted Leasehold Mortgagee of the rejection of such communication as not conforming with the provisions of this Section 17.1 and specify the specific basis of such rejection. (iii) After Landlord has received the notice provided for by subsection (b)(i) above, the Tenant, upon being requested to do so by Landlord, shall with reasonable promptness provide Landlord with copies of the note or other obligation secured by such Permitted Leasehold Mortgage and of any other documents pertinent to the Permitted Leasehold Mortgage as specified by the Landlord. If requested to do so by Landlord, Tenant shall thereafter also provide the Landlord from time to time with a copy of each amendment or other modification or supplement to such instruments. All recorded documents shall be accompanied by the appropriate recording stamp or other certification of the custodian of the relevant recording office as to their authenticity as true and correct copies of official records and all nonrecorded documents shall be accompanied by a certification by Tenant that such documents are true and correct copies of the originals. From time to time upon being requested to do so by Landlord, Tenant shall also notify Landlord of the date and place of recording and other pertinent recording data with respect to such instruments as have been recorded.

  • Notice to Tenant After notice is given to Tenant by Lender that the Landlord is in default under the Note and the Security Instrument and that the rentals under the Lease should be paid to Lender pursuant to the terms of the assignment of leases and rents executed and delivered by Landlord to Lender in connection therewith, Tenant shall thereafter pay to Lender or as directed by the Lender, all rentals and all other monies due or to become due to Landlord under the Lease and Landlord hereby expressly authorizes Tenant to make such payments to Lender and hereby releases and discharges Tenant from any liability to Landlord on account of any such payments.

  • Tenant Delay Except as otherwise provided in the Lease, Delivery of the Premises shall occur when Landlord’s Work has been Substantially Completed, except to the extent that completion of Landlord’s Work shall have been actually delayed by any one or more of the following causes (“Tenant Delay”): (i) Tenant’s Representative was not available to give or receive any Communication or to take any other action required to be taken by Tenant hereunder within a reasonable period of time (not to exceed 2 business days) after written request from Landlord; (ii) Tenant’s request for changes to the Building Shell, whether or not such changes are actually performed; (iii) The construction of any changes to the Building Shell requested by Tenant and agreed upon by Landlord; (iv) Tenant’s request for Change Requests (as defined in Section 4(a) below) whether or not any such Change Requests are actually performed; (v) Construction of any Change Requests; (vi) Tenant’s request for materials, finishes or installations requiring unusually long lead times (provided Landlord will request that the General Contractor inform Tenant of any long lead time items and identify substitutes for such items as soon as reasonably possible); (vii) Tenant’s delay in reviewing, revising or approving plans and specifications beyond the periods set forth herein; (viii) Tenant’s delay in providing any information that is reasonably required to come from Tenant which is critical to the normal progression of the Project within a reasonable period of time after request. Tenant shall provide such information as soon as reasonably possible, but in no event longer than one week after receipt of any request for such information from Landlord; (ix) Tenant’s delay in making payments to Landlord for Excess TI Costs (as defined in Section 5(d) below) for more than 10 business days after such Excess TI Costs are required to be paid to Landlord; or (x) Any other act or omission by Tenant or any Tenant Party (as defined in the Lease), or persons employed by any of such persons that continues for more than 1 business day after Landlord’s notice thereof to Tenant. If Delivery is delayed for any of the foregoing reasons, then Landlord shall cause the TI Architect to certify the date on which the Tenant Improvements would have been Substantially Completed but for such Tenant Delay and such certified date shall be deemed to be the Commencement Date for purposes of Tenant’s obligation to pay Base Rent, Operating Expenses, Excess TI Costs and TI Rent; however, Tenant will not have any obligation to pay any amounts to third parties pursuant to the Lease (and will not occupy the Premises) until the date upon which the Premises is Delivered to Tenant with the Landlord’s Work Substantially Complete. Upon request, Landlord shall advise Tenant of any materials, finishes or installations which are required as part of any Change Request that will result in unusually long lead times.

  • Force Majeure Delays In any case where either party hereto is required to do any act (other than the payment of money), delays caused by or resulting from Acts of God or Nature, war, civil commotion, fire, flood or other casualty, labor difficulties, shortages of labor or materials or equipment, government regulations, delay by government or regulatory agencies with respect to approval or permit process, unusually severe weather, or other causes beyond such party’s reasonable control the time during which act shall be completed, shall be deemed to be extended by the period of such delay, whether such time be designated by a fixed date, a fixed time or “a reasonable time.”

  • Tenant Delays A "Tenant Delay” shall be defined as any delay in the design, permitting or performance of the Base Building Work to the extent that such delay is actually caused by any act or, where there is a duty to act under this Lease, any failure to act by Tenant or Tenant's contractors, architects, engineers, or anyone else engaged by or on behalf of Tenant in connection with the construction of the Tenant Improvement Work as set forth in this Article III (including, without limitation, any delays resulting from the Approved Tenant Finishes under Section 3.l(C) above) and disclosed to Tenant as hereinafter provided. Notwithstanding the foregoing, in no event shall any delays in the completion of the Base Building Work caused by Tenant’s use of non-union labor constitute a Tenant Delay hereunder. Notwithstanding the foregoing, no event shall be deemed a Tenant Delay unless and until Landlord has given Tenant written notice (the "Tenant Delay Notice") advising Tenant: (x) that a Tenant Delay is occurring and setting forth Landlord's good faith estimate as to the likely length of such Tenant Delay; (y) of the basis on which Landlord has determined that a Tenant Delay is occurring; and (z) the actions which Landlord believes that Tenant must take to eliminate such Tenant Delay. No event shall be deemed to be a Tenant Delay unless and until Tenant has failed to rectify the situation causing the Tenant Delay within forty-eight (48) hours after Tenant's receipt of the Tenant Delay Notice (which for the purposes of determining receipt may be delivered by hand to Tenant's Construction Representative, with copies to follow to Tenant at the notice address set forth in Section 1.2 of this Lease within five (5) days thereafter); provided, however, that if Tenant shall fail to eliminate the delay within the aforesaid 48-hour period, then the 48-hour cure period shall be included in the period of time charged to Tenant pursuant to such Tenant Delay Notice (it being understood and agreed that if Tenant shall in fact eliminate the Tenant Delay within the 48-hour cure period, no Tenant Delay shall be deemed to have occurred for the purposes of this Article III). In addition, any delay to the extent caused by (i) Landlord Delay or (ii) subject to the limitations of subsection (D) below, Tenant's Force Majeure (as defined in said subsection (D)) shall not constitute Tenant Delay. Tenant covenants that no Tenant Delay shall delay commencement of the Term or the obligation to pay Annual Fixed Rent or Additional Rent. The Delivery Dates and/or the date of substantial completion of the Base Building Work, as applicable, shall be deemed to have occurred as of the date when such Delivery Dates and/or date of substantial completion of the Base Building Work, as applicable, would have occurred but for any Tenant Delays, as determined by Landlord in the exercise of its good faith business judgment (it being understood and agreed that the foregoing shall not be construed so as to relieve Landlord of its obligation to actually complete the Base Building Work, notwithstanding the fact that substantial completion may have been deemed to have occurred prior to actual completion as the result of Tenant Delays).

  • Notice of Force Majeure Event 14.2.1. As soon as practicable and in any case within 3 days of the date of occurrence of a Force Majeure Event or the date of knowledge thereof, the Party which is rendered wholly or partially unable to perform any of its obligations under this Agreement because of a Force Majeure Event (the “Affected Party”) shall notify the other party of the same, setting out, inter alia, the following in reasonable detail: a) The nature and extent of the Force Majeure Event ; b) The estimated period for which the Force Majeure Event is expected to last; c) The nature of and the extent to which, performance of any of its obligations under this Agreement is affected by the Force Majeure Event; d) The measures which the Affected Party has taken or proposes to take to alleviate/mitigate the impact of the Force Majeure Event and to resume performance of such of its obligations affected thereby; and e) Any other relevant information concerning the Force Majeure Event, and /or the rights and obligations of the Parties under this Agreement.

  • Time of the Essence in This Tenant Work Letter Unless otherwise indicated, all references herein to a “number of days” shall mean and refer to calendar days. If any item requiring approval is timely disapproved by Landlord, the procedure for preparation of the document and approval thereof shall be repeated until the document is approved by Landlord.

  • Notice of Force Majeure If performance is delayed as a result of Force Majeure, the affected party shall provide prompt Notice to the other party and shall be excused from default or delay in performance while such circumstances prevail so long as such party continues to use commercially reasonable efforts to recommence performance as soon as possible.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!