Requests for Change Orders Sample Clauses

Requests for Change Orders. ‌ 12.6.1 Subject to the terms of the Contract Documents, if Contractor believes that any act, error or omission of Owner constitutes a change in the Work entitling it to additional compensation, it shall within twenty (20) Days after the date on which Contractor discovers, or should have discovered with the exercise of appropriate diligence, the relevant act, error or omission of Owner (provided that the necessity of extra cost and/or time is already determinable, even if such extra cost and/or time has not yet been incurred), submit a Request for Change Order to the Contracting Officer stating the amount of the additional compensation and/or additional time to which it is entitled and the justification for the request. The Contracting Officer shall evaluate the Request for Change Order within a reasonable time and advise Contractor whether Owner will grant in whole, grant in part, or deny the Request for Change Order. Any additional compensation granted shall be recorded in the form of a Change Order. Failure of Contractor to timely submit a Request for Change Order in strict, not substantial, accordance with the requirements of this Section 12.6.1 shall constitute a waiver of and shall forever bar any recovery arising out of the pertinent act, error, or omission of Owner, even if Owner was not prejudiced thereby. 12.6.2 No proposal or claim by Contractor on account of changes to the Work shall be allowed for any costs or delay incurred more than twenty (20) Days before Contractor gives written notice as required.
Sample 1Sample 2See All (4)
AutoNDA by SimpleDocs
Requests for Change Orders. Within ten (10) days of submitting its Notice of Claim, the Construction Manager shall submit to the Owner its Request for Change Order, which shall include a written statement of all details of the claim, including a description of the Work affected, the time extension requested (if any), and the amount sought for the claim. Waiver - The Construction Manager agrees that the Owner shall not be liable for any claim that the Construction Manager fails to submit as a Notice of Claim and Request for Change Order as provided in this paragraph. Any claim not so submitted shall be deemed waived.
Sample 1Sample 2Sample 3
Requests for Change Orders. Subject to the criteria in Sections 9.1(b) and (c) the following occurrences or circumstances shall entitle Contractor or Owner to a change to the Work and/or related obligations hereunder in accordance with the provisions of this Article 9 (each a “Change”): (i) any addition to, deletion from, or modification of the Facility requested by Owner or any Change in the Work that is agreed to by the Parties in writing; (ii) any Change that arises as a result of the issuance of the COL; (iii) an event of Force Majeure; (iv) a Change in Law; [***]; (v) issuance of new ITAAC or revisions to any ITAAC; (vi) encountering conditions at or affecting the Site, Nearby Work Areas or transportation that are inconsistent with the Site, Nearby Work Areas and Transportation Assumptions or that a Reasonably Prudent Contractor would not have discovered or otherwise been aware of prior to the Effective Date; (vii) a request by Owner that Contractor use a Subcontractor other than the one proposed by Contractor, as provided in Section 3.7; (viii) a request by Owner to witness tests or conduct surveillance after-the-fact as provided for in Section 5.9(c), provided that the ten (10) Business Day notification required under Section 5.9(a) has been provided; (ix) uncovering of the Work (unless the Work is found to be deficient) as provided for in Section 5.10; (x) any act, fault, omission, or breach with respect to Owner’s obligations under this Agreement or any delay by Owner, including any delay in giving any required approvals or in performing any of the Owner’s responsibilities or obligations under this Agreement; (xi) a suspension of the Work pursuant to Section 22.1(a); (xii) failure of Owner to issue the Full Notice to Proceed on or before the date required under the Milestone Performance Schedule, unless Contractor has exercised its right to terminate the Agreement as a result of such delay pursuant to Section 22.5; (xiii) an instruction by Owner to Contractor to accelerate the Project Schedule; provided, that for purposes of clarification, the Parties agree that to the extent another provision of this Agreement requires an acceleration and specifies how to allocate responsibility for any affects of such acceleration, this Section 9.1(a)(xiii) shall not be interpreted to override or reallocate the responsibility for the impacts of such acceleration; (xiv) Owner elects to purchase Mandatory Spare Parts or Optional Spare Parts, or Mandatory Spare Parts are unavailable as provid...
Sample 1
Requests for Change Orders. (RFCO) 1. The OR shall ensure that all RFCOs, including any and all requested modifications to the contract documents, are in writing from the GC including supplemental drawings, specifications, supporting documentations and proposed/allowable costs to fully describe the change and why it is justified as a change to the current CDs prior to forwarding the RFCO to the Village. 2. The OR shall review RFCOs, assist in negotiating GC’s proposals, submit recommendations to the Village, and, if they are accepted, prepare change orders that incorporate the approved modifications to the CDs. 3. Prior to forwarding the RFCO to the Village the OR shall include a cover memo evaluating the RFCO. The evaluation shall include a preliminary recommendation as to whether the RFCO is justified given the current CDs and if proposed work, quantities, prices and other data in the GC’s proposal are found to be reasonable and in conformance with the CDs. 4. The OR shall maintain an RFCO log documenting, at a minimum, when a properly submitted RFCO was received, its reference number and title, a very brief description of the request, the requested amount, its current status, and an approved amount (positive or negative/increase or decrease) if applicable. 5. The OR may be requested from time to time to attend a Village Council meeting in support of Village staff to help explain any contract modifications necessary as a result of an RFCOs.
Sample 1
Requests for Change Orders. (i) Any SCA request for a Change Order shall be submitted to Developer in writing. SCA requests for Change Orders shall be subject to Developer’s approval, not to be unreasonably withheld, provided, that it shall not be deemed unreasonable for Developer to withhold its approval for any Change Order which: (A) Intentionally Omitted.
Sample 1
Requests for Change Orders 
Sample 1Sample 2Sample 3See All (9)

Related to Requests for Change Orders

  • Change Orders Any alteration or deviation from the Services mentioned or any other contractual specifications that result in a revision of this Agreement shall be executed and attached to this Agreement as a change order (“Change Order”).

  • REQUESTS FOR FLEXIBLE WORKING ARRANGEMENTS 49.1 Employee may request change in working arrangements s.65 of the Act. Note 1: Section 65 of the Act provides for certain Employees to request a change in their working arrangements because of their circumstances, as set out in s.65(1A).

  • Change Order The Change Order is then submitted to the Project Manager who immediately processes the CO with OPC as required by Bulletin 3.5 and BGS’ Contracting Plan.

  • Requests for Approval If the Administrative Agent requests in writing the consent or approval of a Lender, such Lender shall respond and either approve or disapprove definitively in writing to the Administrative Agent within ten Business Days (or sooner if such notice specifies a shorter period for responses based on Administrative Agent’s good faith determination that circumstances exist warranting its request for an earlier response) after such written request from the Administrative Agent. If the Lender does not so respond, that Lender shall be deemed to have approved the request.

  • REQUESTS FOR PAYMENT Payments shall be made in accordance with Article I.4 of the Special Conditions.

  • Execution of Change Orders Change Orders shall be signed by the Contractor, ordinarily certified by the Design Professional, and approved by the Owner in accordance with the form of Change Order prescribed by the Owner. No request for payment by the Contractor for a Change Order shall be due, nor shall any such request appear on an Application for Payment, until the Change Order is executed by the Owner. In the event of emergency (see Article

  • SCOPE CHANGES The Commissioner reserves the right to require, by written order, changes to the scope of the Contract, by altering, adding to or deducting from the Bid Specifications, such changes to be within the general scope of the Contract. If any such change causes an increase or decrease in the cost of, or the time required for, performance of any part of the work under the Contract, whether or not changed by the order, the Commissioner shall, upon notice from Contractor as hereafter stated, make an equitable adjustment in the Contract price, the delivery schedule or both and shall modify the Contract. The Contractor must assert its right to an adjustment under this clause within thirty days from the date of receipt of the written order. However, if the Commissioner decides that the facts justify it, the Commissioner may provide an adjustment without receipt of a proposal. Failure to agree to any adjustment shall be a dispute under the Disputes clause, provided, however, that nothing in this clause shall excuse the Contractor from proceeding with the Contract as changed.

  • Change Orders and Contract Amendments 33.1 The Procuring Entity may at any time order the Supplier through notice in accordance GCC Clause 8, to make changes within the general scope of the Contract in any one or more of the following: a) drawings, designs, or specifications, where Goods to be furnished under the Contract are to be specifically manufactured for the Procuring Entity; b) the method of shipment or packing; c) the place of delivery; and d) the Related Services to be provided by the Supplier. 33.2 If any such change causes an increase or decrease in the cost of, or the time required for, the Supplier's performance of any provisions under the Contract, an equitable adjustment shall be made in the Contract Price or in the Delivery/Completion Schedule, or both, and the Contract shall accordingly be amended. Any claims by the Supplier for adjustment under this Clause must be asserted within twenty-eight (28) days from the date of the Supplier's receipt of the Procuring Entity's change order. 33.3 Prices to be charged by the Supplier for any Related Services that might be needed but which were not included in the Contract shall be agreed upon in advance by the parties and shall not exceed the prevailing rates charged to other parties by the Supplier for similar services.

  • CHANGE ORDERS AND AMENDMENTS A. Any alterations, additions, or deletions to the terms of this Agreement, which are required by changes in federal or state law or by regulations, are automatically incorporated without written amendment hereto, and shall become effective on the date designated by such law or by regulation. B. To ensure the legal and effective performance of this Agreement, both parties agree that any amendment that affects the performance under this Agreement must be mutually agreed upon and that all such amendments must be in writing. After a period of no less than 30 days subsequent to written notice, unless sooner implementation is required by law, such amendments shall have the effect of qualifying the terms of this Agreement and shall be binding upon the parties as if written herein. C. Customers have the right to issue a change order to any purchase orders issued to the Contractor for the purposes of clarification or inclusion of additional specifications, qualifications, conditions, etc. The change order must be in writing and agreed upon by Contractor and the Customer agency prior to issuance of any Change Order. A copy of the Change Order must be provided by the Contractor to, and acknowledged by, H-GAC.

  • Requests for Loans (a) Borrower shall give to Agent written notice in the form of Exhibit D-1 hereto (or telephonic notice confirmed in writing in the form of Exhibit D-1 hereto) of each Loan (other than a Swing Line Loan) requested hereunder (a “Loan Request”) by 12:00 noon (Cleveland time) on the Business Day prior to the proposed Drawdown Date with respect to Base Rate Loans and three (3) Business Days prior to the proposed Drawdown Date with respect to LIBOR Rate Loans. Each such notice shall specify with respect to the requested Loan the proposed principal amount of such Loan, the Type of Loan, the initial Interest Period (if applicable) for such Loan and the Drawdown Date. Each such notice shall also contain a statement that the conditions to borrowing set forth in §11 hereof have been satisfied. Promptly upon receipt of any such notice, Agent shall notify each of Lenders thereof. Each such Loan Request shall be irrevocable and binding on Borrower and shall obligate Borrower to accept the Loan requested from Lenders on the proposed Drawdown Date. Subject to §2.1(c)(iv), each Loan Request shall be (a) for a Base Rate Loan in a minimum aggregate amount of $1,000,000 or an integral multiple of $100,000 in excess thereof; or (b) for a LIBOR Rate Loan in a minimum aggregate amount of $2,000,000 or an integral multiple of $100,000 in excess thereof; provided, however, that there shall be no more than eight (8) LIBOR Rate Loans outstanding at any one time. (b) Borrower shall give to Agent and Swing Line Lender written notice in the form of Exhibit D-2 hereto (or telephonic notice confirmed in writing in the form of Exhibit D-2 hereto) of each Swing Line Loan requested hereunder (a “Request for Swing Line Loan”) by 1:00 p.m. (Cleveland time) on the Business Day of the proposed borrowing of a Swing Line Loan. On the date of the requested Swing Line Loan and subject to satisfaction of the applicable conditions set xxxxx xx §00 for all borrowings, Swing Line Lender will make the proceeds of such Swing Line Loan available to Borrower in Dollars, in immediately available funds, at the account specified by Borrower in its Request for Swing Line Loan not later than 3:00 p.m. (Cleveland time) on such date. Each such Request for Swing Line Loan shall also contain a statement that the conditions to borrowing set forth in §11 hereof have been satisfied.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!