Condition of the Premises Tenant acknowledges that, except as expressly set forth in this Lease, neither Landlord nor any agent of Landlord has made any representation or warranty with respect to the condition of the Premises, the Building or the Property, or with respect to the suitability of the Premises, the Building or the Property for the conduct of Tenant’s business. Tenant acknowledges that Landlord shall have no obligation to alter, repair or otherwise prepare the Premises for Tenant’s occupancy or to pay for or construct any improvements to the Premises except as otherwise expressly set forth in this Lease or in the Work Letter attached hereto as Exhibit 3.1. Notwithstanding anything to the contrary contained herein, Landlord represents and warrants to Tenant that (a) upon the Commencement Date, the Building and the Premises will be in material compliance with all Applicable Laws (in each case, without regard for any of the Finish Work, Tenant’s particular use (as opposed to the Permitted Use, generally), or the obligations of any other tenants in the Building with respect to their tenant improvements); (b) Landlord has full power and authority to enter into this Lease and has obtained all consents and taken all actions necessary in connection therewith other than to the extent provided in Section 14.6, below; and (c) upon the Commencement Date, the Building systems provided by Landlord and serving the Premises including electrical, HVAC, plumbing and other utility systems shall be in good working order and condition. Subject to the foregoing and Landlord’s obligation to repair latent defects in the Base Building Work as expressly provided in Section 1.1 of Exhibit 3.1, Tenant’s execution of this Lease and taking of possession of the Premises shall conclusively establish that the Premises, the Building and the Property were at such time in good, sanitary and satisfactory condition and repair; provided, nothing in this sentence relieves Landlord of its obligations pursuant to Section 8.1, below.
CONSTRUCTION OF PREMISES Landlord will diligently perform “Landlord’s Work” and Tenant will diligently perform “Tenant’s Work” (if any) as described in the Workletter attached as Exhibit “F” in accordance with the Workletter and the rest of this Lease. Landlord’s Work will be deemed substantially completed even if Landlord has not completed “punch list” or other minor items, as long as (i) Landlord agrees to use reasonable efforts to complete these items within thirty (30) days of signing the punch-list, excluding any items which require special materials or equipment that are unavailable; and (ii) the punch-list items can be completed after Tenant’s occupancy without causing substantial interference with Tenant’s use of the Premises. Tenant’s final punch list will be submitted to Landlord with in fifteen (15) days after Landlord notifies Tenant that Landlord’s Work is substantially completed. Substantial completion of Landlord’s Work will be deemed to have occurred on the earlier of: the date as of which Landlord’s architect certifies in good faith that Landlord’s Work has been substantially completed in substantial conformance with the plans and specifications therefore (or the date as of which such substantial completion would have occurred but for any delays or Tenant’s Work for which Tenant is responsible); or the date that the applicable governmental authorities issue a temporary or final certificate of occupancy for the Premises (or the date as of which such a certificate of occupancy reasonable could have been issued but for any delays or Tenant’s Work for which Tenant is responsible). If and as long as Tenant does not interfere in any way with the construction process (by causing disharmony, scheduling or coordinating difficulties, etc.) Tenant, may, at Tenant’s sole risk and expense, enter the Premises 30 days prior to the substantial completion of Landlord’s Work (“Early Access Period”) for the purposes of installing Tenant’s decorations, movable furniture and business fixtures. The determination of such interference by Landlord shall be conclusive. The Early Access Period shall commence upon Tenant’s receipt of Landlord’s notice of same. For the time period commencing on the date that Landlord’s Work is substantially complete and ending on the date that is ten days after such substantial completion (the “Fixture Period”), Tenant shall have the right to access the Premises for the purposes of installing its furniture, fixtures, audio/visual, security, and other equipment Any access by Tenant prior to the Lease Commencement Date shall be subject to all the terms and conditions of this Lease, except that Tenant shall not be obligated to pay rent during the Fixture Period.
Construction of the Tenant Improvements Landlord shall construct the Tenant Improvements in accordance with this exhibit and the construction contract to be executed by Landlord and its contractor(s). The construction contract for constructing the Tenant Improvements and the contractor(s) to perform the work shall be approved and/or selected, as the case may be, by Landlord at its sole and absolute discretion without the consent of Tenant.
Construction of Tenant Improvements Promptly following approval of the Final TI Working Drawings, Landlord shall apply for and use reasonable efforts to obtain the necessary permits and approvals to allow construction of Landlord’s TI Work. Upon receipt of such permits and approvals, Landlord shall, at Tenant’s expense (subject to the application of the Tenant Improvement Allowance provided in this Workletter, and subject to any other applicable provisions of the Lease or of this Workletter expressly making any specific item of expense or cost the responsibility of Landlord), diligently construct and complete Landlord’s TI Work substantially in accordance with the Approved TI Plans, subject to Unavoidable Delays and Tenant Delays (if any). Such construction shall be performed in a good and workmanlike manner and shall conform to all applicable governmental codes, laws and regulations in force at the time such work is completed. Without limiting the generality of the foregoing, Landlord shall be responsible for compliance of Landlord’s TI Work with the requirements of the Americans with Disabilities Act and all similar or related requirements pertaining to access by persons with disabilities, but nothing in this sentence shall be construed to make Landlord responsible for bearing the cost of any such compliance, to the extent the compliance work is reasonably attributable to or related to the particular nature or design of the Tenant Improvements or is for any other reason expressly made Tenant’s cost or responsibility under any applicable provision of the Lease or of this Workletter. Landlord shall have the right, in its sole discretion, to decide whether and to what extent to use union labor on or in connection with Landlord’s Work, and shall use the TI General Contractor to construct all of Landlord’s TI Work. Landlord and Tenant shall each have a right to approve all subcontractors engaged in connection with the construction of the Tenant Improvements and to review and approve all competitive bids for any elements of the Tenant Improvements, such approval in each instance not to be unreasonably withheld, conditioned or delayed by either party.
TENANT'S USE OF THE PREMISES In consideration of the agreements contained herein, Landlord hereby leases the Premises to Tenant, and Tenant hereby leases the Premises from Landlord, for the Term and upon the terms and conditions hereinafter provided. The Premises are leased subject to, and Tenant agrees not to violate, all present and future covenants, conditions and restrictions of record which affect the Land, all of such documents collectively referred to as the "Restrictions". As an appurtenance to the Premises, Tenant shall have the general and nonexclusive right, together with Landlord and the other tenants of the Project and their respective agents, to use the Common Area subject to the terms and conditions of this Lease. Tenant shall use the Premises solely for the purpose set forth in Tenant's Use Clause as designated in Article 2.n and for no other purpose. Tenant shall not use or occupy the Premises in violation of law or any covenant, condition or restriction affecting the Building or Project or the certificate of occupancy issued for the Building or Project, and shall, upon notice from Landlord, immediately discontinue any use of the Premises which is declared by any governmental authority having jurisdiction to be a violation of law or the certificate of occupancy. Tenant, at Tenant's own cost and expense, shall comply with all laws, ordinances, regulations, rules and/or any directions of any governmental agencies or authorities having jurisdiction which shall by reason of the nature of Tenant's use or occupancy of the Promises, impose any duty upon Tenant or Landlord with respect to the Premises or its use or occupation. A judgment of any court of competent jurisdiction or the admission by Tenant in any action or proceeding against Tenant that Tenant has violated any such laws, ordinances, regulations, rules and/or directions in the use of the Premises shall be deemed to be a conclusive determination of that fact as between Landlord and Tenant. Tenant shall not do or permit to be done anything which will invalidate or increase the cost of any fire, extended coverage or other insurance policy covering the Building or Project and/or property located therein, and shall comply with all rules, orders, regulations, requirements and recommendations of the Board of Fire Insurance underwriters or any other organization performing a similar function. Tenant shall promptly upon demand reimburse Landlord for any additional premium charged for such policy by reason of Tenant's failure to comply with the provisions of this Article. Tenant shall not do or permit anything to be done in or about the Premises which will in any way obstruct or interfere with the rights of other tenants or occupants of the Building or Project, or injure or annoy them, or use or allow the Premises to be used for any improper, immoral, unlawful or objectionable purpose, nor shall Tenant cause, maintain or permit any nuisance in, on or about the Premises. Tenant shall not commit or suffer to be committed any waste in or upon the Premises. Tenant acknowledges that Tenant assumes all responsibility regarding the Occupational Safety Health Act, the legal use and adaptability of the Premises and the compliance thereof with all applicable laws and regulations in effect during the form of this Lease.
Construction of the Project The Corporation hereby represents that it has caused the Project to be completed and acknowledges that it shall not be entitled to any reimbursement for the cost of construction of the Project from the Authority, the Trustee or the Holders of the Bonds, nor shall it be entitled to any diminution or postponement of the payments required to be paid by the Corporation pursuant to this Participation Agreement or the Corporation Obligations. Section 3.04.
LANDLORD'S ACCESS TO PREMISES Landlord reserves and shall at any time upon reasonable notice and in compliance with Tenant’s reasonable security measures have the right to enter the Premises to inspect the same, to supply any service to be provided by Landlord to Tenant hereunder to service and repair HVAC units, water pipes and sprinkler mains, and electrical and telephone risers servicing other parts of the Building, to show said Premises to prospective purchasers or tenants, to alter or repair the Premises or any portion of the Building, and to place “for sale” or “for rent” signs on the Building, all without being deemed guilty of an eviction of Tenant and without abatement of Rent, provided that the business of Tenant shall be interfered with as little as is reasonably practicable. Tenant hereby waives any claim for damages or any inconvenience to or interference with Tenant’s business, any loss of quiet enjoyment of the Premises and any other loss occasioned thereby. For each of the aforesaid purposes, Landlord shall at all times have and retain a key with which to unlock the main door to the Premises but not Tenant’s vaults and safes, and Landlord shall have the right to use any and all means which Landlord may deem proper to open said door in an emergency in order to obtain entry to the Premises, and any entry to the Premises obtained by Landlord by any of said means shall not under any circumstances be construed or deemed to be a forcible or unlawful entry into, or a detainer of the Premises, or any eviction of Tenant from the Premises or any portion thereof. No provision of this Lease shall be construed as obligating Landlord to perform any repairs, alterations or decoration except as otherwise expressly agreed to be performed by Landlord.
The Premises Landlord hereby leases to Tenant and Tenant hereby leases from Landlord the premises set forth in Section 2.2 of the Summary (the “Premises”). The outline of the Premises is set forth in Exhibit A attached hereto, and an outline of the Project is set forth in Exhibit A-1 attached hereto. The parties hereto agree that the lease of the Premises is upon and subject to the terms, covenants and conditions herein set forth, and Tenant covenants as a material part of the consideration for this Lease to keep and perform each and all of such terms, covenants and conditions by it to be kept and performed and that this Lease is made upon the condition of such performance. The parties hereto hereby acknowledge that the purpose of Exhibit A is to show the approximate location of the Premises in the “Building,” as that term is defined in Section 1.1.2, below, only, and such Exhibit is not meant to constitute an agreement, representation or warranty as to the construction of the Premises, the precise area thereof or the specific location of the “Common Areas,” as that term is defined in Section 1.1.3, below, or the elements thereof or of the accessways to the Premises or the “Project,” as that term is defined in Section 1.1.2, below. Except as specifically set forth in this Lease, Tenant shall accept the Premises in its presently existing “as-is” condition and Landlord shall not be obligated to provide or pay for any improvement work or services related to the improvement of the Premises. Tenant also acknowledges that neither Landlord nor any agent of Landlord has made any representation or warranty regarding the condition of the Premises, the Building or the Project or with respect to the suitability of any of the foregoing for the conduct of Tenant’s business, except as specifically set forth in this Lease. However, notwithstanding the foregoing, Landlord agrees that base Building electrical, mechanical, heating, ventilation and air conditioning and plumbing systems located in the Premises shall be in good working order and the roof shall be water tight as of the date Landlord delivers possession of the Premises to Tenant. Except to the extent caused by the acts or omissions of Tenant or any Tenant Parties (as defined in Section 10.13 below) by any alterations or improvements performed by or on behalf of Tenant, if such systems and/or the roof are not in good working order as of the date possession of the Premises is delivered to Tenant and Tenant provides Landlord with notice of the same within ninety (90) days following the date Landlord delivers possession of the Premises to Tenant, Landlord shall be responsible for repairing or restoring the same at Landlord’s sole cost and expense. Subject to any repairs or restoration required by the immediately preceding sentence, the commencement of business operations from the Premises by Tenant shall presumptively establish that the Premises and the Building were at such time in good and sanitary order, condition and repair. For purposes of Section 1938 of the California Civil Code, Landlord hereby discloses to Tenant, and Tenant hereby acknowledges, that the Premises, the Building and the Project have not undergone inspection by a Certified Access Specialist (CASp).
Use of the Premises The Premises shall be used exclusively for the purpose ------------------- of research and development, storage, distribution, offices and marketing of medical devices. Lessee shall not use or permit the Premises, or any part thereof, to be used for any purpose or purposes other than the purpose for which the Premises are hereby leased; and no use shall be made or permitted to be made of the Premises, nor acts done, which will increase the existing rate of insurance upon the building in which the Premises are located, or cause a cancellation of any insurance policy covering said building, or any part thereof, nor shall Lessee sell or permit to be kept, used, or sold, in or about the Premises, any article which may be prohibited by the standard form of fire insurance policies. Lessee shall not commit or suffer to be committed any waste upon the Premises or any public or private nuisance or other act or thing which may disturb the quiet enjoyment of any other tenant in the building in which the premises are located; nor, without limiting the generality of the foregoing, shall Lessee allow the Premises to be used for any improper, immoral, unlawful, or objectionable purpose. Lessee shall not place any harmful liquids in the drainage system of the Premises or of the building of which the Premises form a part. No waste materials or refuse shall be dumped upon or permitted to remain upon any part of the Premises outside of the building proper except in trash containers placed inside exterior enclosures designated for that purpose by Lessor, or inside the building proper where designated by Lessor. No materials, supplies, equipment, finished or semi-finished products, raw materials, or articles of any nature shall be stored upon or permitted to remain on any portion of the Premises outside of the building proper. Lessee shall comply with all the covenants, conditions, and/or restrictions ("C.C. & R.'s") affecting the Premises
Landlord's Improvements All fixtures, improvements or equipment which are installed, constructed on or attached to the Premises or Common Area by Landlord shall be a part of the realty and belong to Landlord.
