Liquidated Damages for Delay In addition to the Contractor bearing the actual cost of correcting any non-compliant work or any other actual damages resulting from Contractor’s breach of this Agreement, the Contractor agrees to pay the Contractor delay damages in the amount of $500.00 per day for every day that the goods and/or services to be provided pursuant to this Agreement have not been timely delivered to the District in compliance with the Scope of Services set forth above, unless the delay has been properly excused by the terms of this Agreement. The parties agree that the District’s actual damages for delay are difficult to estimate and that this $500.00 per day sum is a reasonable pre-estimate of the District’s actual damages for each day of delay and that the is $500.00 per day sum is intended by the parties to be in the nature of liquidated damages, not a penalty. It is not the parties’ intent for this provision to limit either party’s remedies against the other for the breach of this Agreement, except for the District’s money damages for unexcused delays caused by the Contractor.
Additional Remedies Upon the occurrence and during the continuation of an Event of Default, Secured Party shall have the right and power to:
(a) instruct Grantor, at its own expense, to notify any parties obligated on any of the Collateral, including any Account Grantors, to make payment directly to Secured Party of any amounts due or to become due thereunder, or Secured Party may directly notify such obligors of the security interest of Secured Party, and/or of the assignment to Secured Party of the Collateral and direct such obligors to make payment to Secured Party of any amounts due or to become due with respect thereto, and thereafter, collect any such amounts due on the Collateral directly from such Persons obligated thereon;
(b) enforce collection of any of the Collateral, including any Accounts, by suit or otherwise, or make any compromise or settlement with respect to any of the Collateral, or surrender, release or exchange all or any part thereof, or compromise, extend or renew for any period (whether or not longer than the original period) any indebtedness thereunder;
(c) take possession or control of any proceeds and products of any of the Collateral, including the proceeds of insurance thereon;
(d) extend, renew or modify for one or more periods (whether or not longer than the original period) the Obligations or any obligation of any nature of any other obligor with respect to the Obligations;
(e) grant releases, compromises or indulgences with respect to the Obligations, any extension or renewal of any of the Obligations, any security therefor, or to any other obligor with respect to the Obligations;
(f) transfer the whole or any part of Capital Securities which may constitute Collateral into the name of Secured Party or Secured Party's nominee without disclosing, if Secured Party so desires, that such Capital Securities so transferred are subject to the security interest of Secured Party, and any corporation, association, or any of the managers or trustees of any trust issuing any of such Capital Securities, or any transfer agent, shall not be bound to inquire, in the event that Secured Party or such nominee makes any further transfer of such Capital Securities, or any portion thereof, as to whether Secured Party or such nominee has the right to make such further transfer, and shall not be liable for transferring the same;
(g) vote the Collateral;
(h) make an election with respect to the Collateral under Section 1111 of the Bankruptcy Code or take action under Section 364 or any other section of Bankruptcy Code; provided, however, that any such action of Secured Party as set forth herein shall not, in any manner whatsoever, impair or affect the liability of Grantor hereunder, nor prejudice, waive, nor be construed to impair, affect, prejudice or waive Secured Party's rights and remedies at law, in equity or by statute, nor release, discharge, nor be construed to release or discharge, Grantor, any guarantor or other Person liable to Secured Party for the Obligations; and
(i) at any time, and from time to time, accept additions to, releases, reductions, exchanges or substitution of the Collateral, without in any way altering, impairing, diminishing or affecting the provisions of this Security Agreement, the Loan Documents, or any of the other Obligations, or Secured Party's rights hereunder, under the Obligations. Grantor hereby ratifies and confirms whatever Secured Party may do with respect to the Collateral and agrees that Secured Party shall not be liable for any error of judgment or mistakes of fact or law with respect to actions taken in connection with the Collateral other than as a result of intentional misconduct or gross negligence.
Acceleration and Remedies Upon the acceleration of the obligations under the Credit Agreement pursuant to Section 8.1 thereof, the Obligations and, to the extent provided for under the Rate Management Transactions evidencing the same, the Rate Management Obligations, shall immediately become due and payable without presentment, demand, protest or notice of any kind, all of which are hereby expressly waived, and the Agent may, with the concurrence or at the direction of the Required Secured Parties, exercise any or all of the following rights and remedies:
5.2.1 Those rights and remedies provided in this Security Agreement, the Credit Agreement, or any other Loan Document, provided that this Section 5.2.1 shall not be understood to limit any rights or remedies available to the Agent and the Lenders prior to a Default.
5.2.2 Those rights and remedies available to a secured party under the New York UCC (whether or not the New York UCC applies to the affected Collateral) or under any other applicable law (including, without limitation, any law governing the exercise of a bank's right of setoff or bankers' lien) when a debtor is in default under a security agreement.
5.2.3 Without notice except as specifically provided in Section 8.1 or elsewhere herein, sell, lease, assign, grant an option or options to purchase or otherwise dispose of the Collateral or any part thereof in one or more parcels at public or private sale, for cash, on credit or for future delivery, and upon such other terms as the Agent may deem commercially reasonable. The Agent, on behalf of the secured parties, may comply with any applicable state or federal law requirements in connection with a disposition of the Collateral and compliance will not be considered to adversely affect the commercial reasonableness of any sale of the Collateral. If, after the Credit Agreement has terminated by its terms and all of the Obligations have been paid in full, there remain Rate Management Obligations outstanding, the Required Secured Parties may exercise the remedies provided in this Section 5.2 upon the occurrence of any event which would allow or require the termination or acceleration of any Rate Management Obligations pursuant to the terms of the agreement governing any Rate Management Transaction.
Default Rights and Remedies If an Event of Default exists, the Agent shall have the following rights and remedies:
(a) In addition to all other rights and remedies granted to the Agent in this Agreement or in any other Loan Document or by applicable law, the Agent shall have all of the rights and remedies of a secured party under the UCC (whether or not the UCC applies to the affected Collateral). Without limiting the generality of the foregoing, the Agent may (A) without demand or notice to it, collect, receive or take possession of the Collateral or any part thereof and for that purpose the Agent may enter upon any premises on which the Collateral is located and remove the Collateral therefrom or render it inoperable, and/or (B) sell, lease or otherwise dispose of the Collateral, or any part thereof, in one or more parcels at public or private sale or sales, at the Agent's offices or elsewhere, for cash, on credit or for future delivery, and upon such other terms as the Agent may deem commercially reasonable or otherwise as may be permitted by law. The Agent shall have the right at any public sale or sales, and, to the extent permitted by applicable law, at any private sale or sales, to bid (which bid may be, in whole or in part, in the form of cancellation of indebtedness) and become a purchaser of the Collateral or any part thereof free of any right or equity of redemption on the part of the Debtor, which right or equity of redemption is hereby expressly waived and released by the Debtor. Upon the request of the Agent, the Debtor shall assemble the Collateral and make it available to the Agent at anyplace designated by the Agent that is reasonably convenient to it and the Agent. The Debtor agrees that the Agent shall not be obligated to give more than ten (10) days prior written notice of the time and place of any public sale or of the time after which any private sale may take place and that such notice shall constitute reasonable notice of such matters. The Agent shall not be obligated to make any sale of Collateral if it shall determine not to do so, regardless of the fact that notice of sale of Collateral may have been given. The Agent may, without notice or publication, adjourn any public or private sale or cause the same to be adjourned from time to time by announcement at the time and place fixed for sale, and such sale may, without further notice, be made at the time and place to which the same was so adjourned. The Debtor shall be liable for all reasonable expenses of retaking, holding, preparing for sale or the like, and all reasonable attorneys' fees, legal expenses and other costs and expenses incurred by the Agent in connection with the collection of the Obligations and the enforcement of the Agent's rights under this Agreement. The Debtor shall remain liable for any deficiency if the Proceeds of any sale or other disposition of the Collateral applied to the Obligations are insufficient to pay the Obligations in full to the extent provided in the Loan Documents. The Agent may apply the Collateral against the Obligations as provided in the Credit Agreement. The Debtor waives all rights of marshalling, valuation and appraisal in respect of the Collateral. Any cash held by the Agent as Collateral and all cash proceeds received by the Agent in respect of any sale of, collection from or other realization upon all or any part of the Collateral may, in the discretion of the Agent, be held by the Agent as collateral for, and then or at any time thereafter applied in whole or in part by the Agent against, the Obligations in the order permitted by the Credit Agreement. Any surplus of such cash or cash proceeds and interest accrued thereon, if any, held by the Agent and remaining after payment in full of all the Obligations shall be promptly paid over to the Debtor or to whomsoever may be lawfully entitled to receive such surplus; provided that the Agent shall have no obligation to invest or otherwise pay interest on any amounts held by it in connection with or pursuant to this Agreement.
(b) The Agent may cause any or all of the Collateral held by it to be transferred into the name of the Agent or the name or names of the Agent's nominee or nominees.
(c) The Agent may exercise any and all of the rights and remedies of the Debtor under or in respect of the Collateral, including, without limitation, any and all rights of it to demand or otherwise require payment of any amount under, or performance of any provision of, any of the Collateral.
(d) The Agent may collect or receive all money or property at any time payable or receivable on account of or in exchange for any of the Collateral, but shall be under no obligation to do so.
(e) On any sale of the Collateral, the Agent is hereby authorized to comply with any limitation or restriction with which compliance is necessary, in the view of the Agent's counsel, in order to avoid any violation of applicable law or in order to obtain any required approval of the purchaser or purchasers by any applicable Governmental Authority.
Breach of Contract and Liquidated Damages A. Where OGS determines that the Contractor is not in compliance with the requirements of subsection 4.7 of this Contract, and the Contractor refuses to comply with such requirements, or if it is found to have willfully and intentionally failed to comply with the MWBE participation goals set forth in the Contract, the Contractor shall be obligated to pay liquidated damages to OGS.
B. Such liquidated damages shall be calculated as an amount equaling the difference between:
1. All sums identified for payment to MWBEs had the Contractor achieved the contractual MWBE goals; and
2. All sums actually paid to MWBEs for work performed or materials supplied under the Contract.
C. If OGS determines that Contractor is liable for liquidated damages and such identified sums have not been withheld by OGS, Contractor shall pay such liquidated damages to OGS within sixty (60) days after they are assessed. Provided, however, that if the Contractor has filed a complaint with the Director of the Division of Minority and Women’s Business Development pursuant to 5 NYCRR § 142.12, liquidated damages shall be payable only in the event of a determination adverse to the Contractor following the complaint process.
Default Remedies (a) If an Event of Default (other than an insolvency Event of Default) has occurred and is continuing, the Lender, by notice to the Company, may declare the Loan Amount of this Note and all accrued interest thereon to be immediately due and payable, and upon any such declaration, such Loan Amount and accrued interest shall thereupon become due and payable immediately within five (5) business days from the Lender’s written request. In the event the Company fails to pay all outstanding Amounts within this five (5) business day period, the interest rate on the unpaid and outstanding Loan Amount of this Note shall be increased to, and this Note shall bear interest at, a monthly rate equal to one and a half percent (1.5%) or to the maximum rate permitted by law (the "Default Rate") from the expiration of the five (5) business day period until such unpaid and outstanding Loan Amount of this Note is repaid in full. If an insolvency Event of Default has occurred, the Loan Amount of this Note and accrued Interest thereon will become immediately due and payable without any declaration or any act on the part of any Lender. Such declaration of acceleration may be rescinded and past defaults may be waived by the Lender.
(b) No course of dealing or delay or failure on the part of the Lender to exercise any right under this Section shall operate as a waiver of such right or otherwise prejudice the Lender’s rights, powers and remedies. The Company will pay or reimburse the Lender, to the extent permitted by law, for all reasonable costs and expenses, including but not limited to reasonable attorneys’ fees, incurred by the Lender in collecting any sums due on this Note or in otherwise enforcing any of the Lender's rights hereunder.
(c) No right or remedy herein conferred upon the Lender is intended to be exclusive of any other right or remedy contained herein or existing at law, in equity, by statute or otherwise, and every such right or remedy shall be cumulative and shall be in addition to every other such right or remedy contained herein and therein or now or hereafter existing at law, in equity, by statute or otherwise.
Defaults and Remedies Section 6.01.
Withholding for unpaid wages and liquidated damages The FHWA or the contacting agency shall upon its own action or upon written request of an authorized representative of the Department of Labor withhold or cause to be withheld, from any moneys payable on account of work performed by the contractor or subcontractor under any such contract or any other Federal contract with the same prime contractor, or any other federally-assisted contract subject to the Contract Work Hours and Safety Standards Act, which is held by the same prime contractor, such sums as may be determined to be necessary to satisfy any liabilities of such contractor or subcontractor for unpaid wages and liquidated damages as provided in the clause set forth in paragraph (2.) of this section.
Events of Default Rights and Remedies Section 7.1 Events of Default Section 7.2 Rights and Remedies Section 7.3 Certain Notices
Payment of Liquidated Damages If you supply all or some of your milk to a third party during a Month you must, if required by DFMC, immediately pay to DFMC liquidated damages for that Month calculated as follows: $X = W cents x (Y – Z) Where: $X is the amount payable by you to DFMC for the relevant Month. If $X is a negative amount, no amount is payable by you. Y is the average monthly litres you have supplied to DFMC based on the 12 months immediately preceding the relevant Month (or in the event you have not supplied DFMC for 12 months, the average monthly litres you have supplied to DFMC during the period you have supplied DFMC). Z is the number of litres supplied to DFMC by you for the relevant Month.
