Continuing Contract Performance Pending final resolution of a Claim, except as otherwise agreed in writing or as provided in Section 9.7 and Article 13, the Design-Builder shall proceed diligently with performance of the Contract and the Owner shall continue to make payments in accordance with the Design-Build Documents.
Excuse for Nonperformance or Delayed Performance Except with respect to defaults of subcontractors, Contractor/Vendor shall not be in default by reason of any failure in performance of this contract in accordance with its terms (including any failure by Contractor/Vendor to make progress in the prosecution of the work hereunder which endangers such performance) if Contractor/Vendor has notified the Commission or designee within 15 days after the cause of the delay and the failure arises out of causes such as: acts of God; acts of the public enemy; acts of the State and any other governmental entity in its sovereign or contractual capacity; fires; floods; epidemics; quarantine restrictions; strikes or other labor disputes; freight embargoes; or unusually severe weather. If the failure to perform is caused by the failure of a subcontractor to perform or to make progress, and if such failure arises out of causes similar to those set forth above, Contractor/Vendor shall not be deemed to be in default, unless the services to be furnished by the subcontractor were reasonably obtainable from other sources in sufficient time to permit Contractor to meet the contract requirements. Upon request of Contractor, the Commission or designee shall ascertain the facts and extent of such failure, and, if such officer determines that any failure to perform was occasioned by any one or more of the excusable causes, and that, but for the excusable cause, Contractor’s progress and performance would have met the terms of the contract, the delivery schedule shall be revised accordingly, subject to the rights of the State under the clause entitled (in fixed-price contracts, “Termination for Convenience,” in cost-reimbursement contracts, “Termination”). (As used in this Paragraph of this clause, the term “subcontractor” means subcontractor at any tier).
Employee Performance Review When a formal review of an employee’s performance is made, the employee concerned shall be given an opportunity to discuss, sign and make written comments on the review form in question and the employee is to receive a signed copy to indicate that its contents have been read. An employee shall be entitled to a minimum of two (2) work days to review the performance review prior to providing any response to the Employer, verbally or in writing, with respect to the evaluation.
Monitoring of Contract Performance The Contractor shall comply with the monitoring arrangements set out in the Monitoring Requirements Schedule including, but not limited to, providing such data and information as the Contractor may be required to produce under the Contract.
Performance Schedule The Parties will perform their respective responsibilities in accordance with the Performance Schedule. By executing this Agreement, Customer authorizes Motorola to proceed with contract performance.
Reviewing Contract Performance The Contractor shall work with the Authority to establish and maintain an effective and beneficial working relationship to ensure the Contract is delivered to at least the minimum required standard as specified in the Schedule (The Services).
Contract Performance C19.1 The Contractor shall ensure that: C19.1.1 the Goods conform in all respects with the Specification and, where applicable, with any sample or performance demonstration approved by the Authority; C19.1.2 the Goods operate in accordance with the relevant technical specifications and correspond with the requirements of the Specification and any particulars specified in the Contract; C19.1.3 the Goods conform in all respects with all applicable Laws; and C19.1.4 the Goods are free from defects in design, materials and workmanship and are fit and sufficient for all the purposes for which such Goods are ordinarily used and for any particular purpose made known to the Contractor by the Authority.
Suspension of Performance Disbursement Into Court If at any time, there shall exist any dispute between the Company and the Investor(s) with respect to holding or disposition of any portion of the Escrow Funds or any other obligations of Escrow Agent hereunder, or if at any time Escrow Agent is unable to determine, to Escrow Agent's sole satisfaction, the proper disposition of any portion of the Escrow Funds or Escrow Agent's proper actions with respect to its obligations hereunder, or if the parties have not within thirty (30) days of the furnishing by Escrow Agent of a notice of resignation pursuant to Section 9 hereof, appointed a successor Escrow Agent to act hereunder, then Escrow Agent may, in its sole discretion, take either or both of the following actions: a. suspend the performance of any of its obligations (including without limitation any disbursement obligations) under this Escrow Agreement until such dispute or uncertainty shall be resolved to the sole satisfaction of Escrow Agent or until a successor Escrow Agent shall be appointed (as the case may be); provided however, Escrow Agent shall continue to invest the Escrow Funds in accordance with Section 8 hereof; and/or b. petition (by means of an interpleader action or any other appropriate method) any court of competent jurisdiction in any venue convenient to Escrow Agent, for instructions with respect to such dispute or uncertainty, and to the extent required by law, pay into such court, for holding and disposition in accordance with the instructions of such court, all funds held by it in the Escrow Funds, after deduction and payment to Escrow Agent of all fees and expenses (including court costs and attorneys' fees) payable to, incurred by, or expected to be incurred by Escrow Agent in connection with performance of its duties and the exercise of its rights hereunder. c. Escrow Agent shall have no liability to the Company, the Investor(s), or any person with respect to any such suspension of performance or disbursement into court, specifically including any liability or claimed liability that may arise, or be alleged to have arisen, out of or as a result of any delay in the disbursement of funds held in the Escrow Funds or any delay in with respect to any other action required or requested of Escrow Agent.
Interest Rates and Letter of Credit Fee Rates Payments and Calculations (a) Interest Rates. Except as provided in Section 2.13(c) and Section 2.15(a), all Obligations (except for the undrawn portion of the face amount of Letters of Credit) that have been charged to the Loan Account pursuant to the terms hereof shall bear interest at a per annum rate equal to the lesser of (i) the LIBOR Rate plus the Applicable Margin, or (ii) the maximum rate of interest allowed by applicable laws; provided, that following notice to Borrower in accordance with Section 2.15(a) hereof, all Obligations that have been charged to the Loan Account pursuant to the terms hereof shall bear interest at a per annum rate equal, during the duration of the circumstances described in Section 2.15(a), to the lesser of (A) the Base Rate plus the Applicable Margin as calculated pursuant to Section 2.15(a) or (B) the maximum rate of interest allowable by applicable laws.
Performance Delay Time is of the essence in the Vendor’s performance of this Agreement. If at any time it appears to Vendor that it may not meet any of the performance schedules or the scheduled completion date of the services to be performed for any reason, including labor disputes, Vendor shall immediately by verbal means (to be confirmed in writing) notify Customer of the reasons for and the estimated duration of such delay. If requested by Customer, Vendor shall make every effort to avoid or minimize the delay to the maximum extent possible including the expenditure of premium time. Any additional cost caused by these requirements of Customer shall be borne by Vendor, unless the delay in performance arises out of causes beyond the control and without the fault or negligence of Vendor or its subcontractors within the meaning of the Cancellation- Default clause herein. The foregoing requirements are in addition to any of Customer’s other rights and remedies as may be provided by law or this Agreement.
