Material Project Documents (a) The Company shall at all times (i) perform and observe all of the covenants under the Material Project Documents to which it is a party and take reasonable actions to enforce all of its rights thereunder, other than to the extent the same could not reasonably be expected to have a Material Adverse Effect, (ii) subject to the provisions of clause (b) of this Section 9.8, maintain the System Leases (other than Leases constituting System Leases only pursuant to clause (5) of the definition thereof) in full force and effect, and (iii) maintain the Leases (other than the System Leases referred to in the foregoing clause (ii) of this Section 9.8(a)) to which it or any of its Subsidiaries is a party in full force and effect, except to the extent the same could not reasonably be expected to have a Material Adverse Effect.
(b) If the term of a Lease with the Company or one of its Subsidiaries expires and the Qualified Lessee under such Lease has either ceased operating the related assets or has ceased paying rent as required under the applicable Lease, the Company shall, or shall cause a Subsidiary, as applicable, to enter into a supplement or a new Lease with respect to the related leasehold assets with a Qualified Lessee that provides for rent that, when combined with all other expected revenue, will, in the reasonable judgment of the Company, as of the commencement date of such supplement or new Lease, generate sufficient revenue to satisfy the requirements of Section 9.9 and will not otherwise result in a materially worse position for the Company as compared to the terms of the applicable expired Lease. Each such new Lease shall have a term of at least five years. Notwithstanding the foregoing, if (i) such expired Lease relates to transmission and/or distribution assets that are not generating significant revenue, (ii) the failure to renew such Lease would not constitute a Material Adverse Effect and (iii) the Company reasonably believes it will generate sufficient revenue and hold sufficient assets (without giving effect to the leasehold assets with respect to such Lease) to satisfy the requirements of Section 9.9, then this Section 9.8(b) will not require a supplement or new lease with respect to such leasehold assets.
Environmental Assessment Buyer shall have the right for a period commencing upon execution of this Agreement by both parties and ending on November 28, 2012, to conduct an environmental assessment of the Assets, at Buyer’s sole risk, liability and expense. Seller shall make available to Buyer, during the environmental assessment period described above, Seller’s historical files regarding prior operations on the Assets, and provide Buyer and its representatives with reasonable access to the Assets to conduct the environmental assessment. Buyer shall provide Seller three (3) days prior written notice of a desired date(s) for such assessment and Seller shall have the right to be present during any assessment and, if any testing is conducted pursuant to Seller’s express prior written consent, Seller may require splitting of all samples. Notwithstanding any other provision of this Agreement to the contrary, Buyer shall not have the right to drill any test, monitor or other xxxxx or to extract samples of any air, soil, water or other substance from the Assets without Seller’s express prior written consent. If Buyer proposes a reasonable request to drill a test well or extract a sample pursuant to a systematic and customary procedure for the assessment of the environmental condition of the Assets and Seller refuses to grant its consent to such a well or sampling, then Buyer shall have the right, for a period of seventy-two (72) hours following notification of Seller’s refusal to consent, to deliver written notice to Seller of Buyer’s election to exclude from this transaction the portion of the Assets affected by such proposed test well or sample, and the Purchase Price shall be adjusted accordingly by the Allocated Value of such portion of the Assets so excluded. Under no circumstances whatsoever shall Seller ever be obligated to grant its consent to any such test xxxxx or sampling proposed by Buyer, and Buyer’s sole and exclusive remedy for any refusal by Seller to grant its consent shall be the limited right contained in the preceding sentence to exclude the affected Assets from the transactions contemplated by this Agreement. If Buyer fails to exercise the right to exclude such Assets by written notice to Seller delivered prior to the expiration of the seventy-two hour period described above, then Buyer shall be conclusively deemed to have waived such right and shall be obligated to purchase the affected Assets without conducting such testing or sampling or any adjustment of the Purchase Price unless otherwise provided in this Agreement.
Adverse Effect Any other action, event, or condition of any nature which could result in a material adverse effect on the business, property, or financial condition of Borrower.
MATERIAL SAFETY All manufacturers, importers, suppliers, or distributors of hazardous chemicals doing business in this State must provide a copy of the current Material Safety Data Sheet (MSDS) for any hazardous chemical to their direct purchasers of that chemical.
Environmental Assessments Foreclose on or take a deed or title to any commercial real estate without first conducting a Phase I environmental assessment of the property or foreclose on any commercial real estate if such environmental assessment indicates the presence of a Hazardous Substance in amounts which, if such foreclosure were to occur, would be material.
Project 3.01. The Recipient declares its commitment to the objectives of the Project. To this end, the Recipient shall carry out the Project in accordance with the provisions of Article IV of the General Conditions.
Environmental Site Assessment Perform in accordance with the City Design Manual and other City requirements as designated in writing by the Director.
Capital Projects (a) The selection of all design professionals and contractors for capital projects shall be made by Lessor and Lessor shall provide at its expense all materials and services for capital projects.
(b) Lessee shall cooperate with Lessor with respect to capital projects. Notwithstanding anything in the foregoing which may be construed to the contrary, Lessee shall have no obligation to perform any such capital projects unless Lessee agrees to perform and be responsible for same in accordance with a written agreement therefor between Lessor and Lessee.
Special Projects Involved in a planned endeavour designed and implemented to address a resident, nursing, facility or community health care concern or need. (eg. QI project to improve resident outcomes) (10 – 20 points depending on scope of project)
Construction Progress Schedule A schedule indicating proposed activity sequences and durations, milestone dates for receipt and approval of pertinent information, preparation, submittal, and processing of Shop Drawings and Samples, delivery of materials or equipment requiring long-lead time procurement, and proposed date(s) of Material Completion and Occupancy and Final Completion. The schedule will be developed to represent the sixteen or seventeen CSI Specification Divisions. It shall have a minimum number of activities as required to adequately represent to Owner the complete scope of work and define the Project’s critical path and associated activities. If the Project is to be phased, then each individual Phase should be identified from start through completion of the overall Project and should be individually scheduled and described, including any Owner’s occupancy requirements and showing portions of the Project having occupancy priority. The format of the schedule will have dependencies indicated on a monthly grid identifying milestone dates such as construction start, phase construction, structural top out, dry-in, rough-in completion, metal stud and drywall completion, equipment installation, systems operational, Material Completion and Occupancy Date, final inspection dates, Punchlist, and Final Completion date.
