Method of Performance of Work Sample Clauses

Method of Performance of Work. Such work shall be performed either (a) by the employment of the forces and the use of the equipment of the Corporation and by the use of any material on hand or necessary to be purchased by the Corporation, or (b), when consent therefor is given in writing by the Commissioner, by contract in conformity with NYSDOT Reimbursement Procedures. All work within the State Highway right-of-way shall be performed pursuant to a Highway Work Permit issued by the Department. If this method is deemed to be impracticable by the Corporation or Commissioner, then upon written consent of the Commissioner, such other method or combination of methods shall be employed as the Commissioner shall approve. The utility facilities shall be adjusted in accordance with this Agreement, as directed by the State’s Engineer in Charge, without causing delay to the State’s Contractor, and before completion of the State’s contract.
Sample 1Sample 2Sample 3See All (5)
AutoNDA by SimpleDocs
Method of Performance of Work. Such work may be performed (a) by the employment of forces and the use of the equipment of the Municipality and by the use of any material on hand or necessary to be purchased by the Municipality or (b) when consent therefore is stated in writing by the Sponsor, by contract as provided in Section 103 of the General Municipal law, or if this method is deemed to be written consent, by such other method is deemed to be impracticable by the municipality, or Sponsor, then, upon such written consent, by such other method or combination of methods as the Sponsor shall approve. The Utility Facilities shall be adjusted in accordance with this agreement, as directed by the Sponsor=s Engineer in charge, without causing delay to the Sponsor=s Contractor, and before completion of the Sponsor=s highway contract.
Sample 1
Method of Performance of Work. Such work may be performed (a) by the employment of forces and the use of the equipment of the Municipality and by the use of any material on hand or necessary to be purchased by the Municipality or (b) when consent therefor is stated in writing by the State, by contract as provided in Section 103 of the General Municipal law, or if this method is deemed to be impracticable by the Municipality, or Commissioner, then, upon such written consent, by such other method or combination of methods as the Commissioner shall approve. The Utility Facilities shall be adjusted in accordance with this agreement, as directed by the State’s Engineer in Charge, without causing delay to the State’s Contractor, and before completion of the State’s contract.
Sample 1
Method of Performance of Work. Such work shall be performed either (a) by the employment of the forces and the use of the equipment of the Utility Owner and by the use of any material on hand or necessary to be purchased by the Utility Owner, or (b) when consent therefor is given in writing by the Sponsor, by contract in conformity with the "Utility Reimbursement Procedure Manual" PUB 3 (1/87) as revised. All work within the State highway right-of-way shall be performed pursuant to a Highway Work Permit issued by the Department. If this method is deemed to be impracticable by the Utility Owner or Sponsor, then, upon written consent of the Sponsor, such other method or combination of methods shall be employed as approved. The utility Facilities shall be adjusted in accordance with this Agreement, as directed by the Sponsor's Engineer in Charge, without causing delay to the Sponsor's contractor, and before completion of the Sponsor's contract.
Sample 1
Method of Performance of Work. Work done under this agreement shall be performed as hereinafter indicated: Water main to be installed by A Fire hydrant to be installed by A Service connection to be installed by A (A) Private contract to be let by Applicants or performed by Applicants's own forces. (B) Public contract to be let by District or performed by District's own forces.
Sample 1

Related to Method of Performance of Work

  • Method of Performing Services Contractor will determine the method, details, and means of performing the above-described services including measures to protect the safety of the traveling public and Contractor’s employees. County shall not have the right to, and shall not, control the manner or determine the method of accomplishing Contractor’s services.

  • Performance of Work (i) The Borrowers shall complete all Work in a good and workmanlike manner as soon as practicable following the commencement thereof substantially in accordance with the applicable budget approved by Lender in accordance with the terms of this Loan Agreement. The insufficiency of the balance in the applicable Work Reserve shall not relieve the Borrowers from their obligations to perform and complete the related Work as herein provided or to fulfill all other preservation and maintenance covenants in the Loan Documents. (ii) If Lender determines in its reasonable discretion that any Work is not being performed in a workmanlike or timely manner or that any Work has not been completed in a workmanlike manner, Lender shall have the option to withhold disbursement for such unsatisfactory work and so notify the Borrowers with reasonable detail regarding the basis for Lender's dissatisfaction and, after the expiration of forty-five (45) days from the giving of such notice by Lender to the Borrowers of such unsatisfactory work without the cure thereof (or, if such unsatisfactory work is susceptible of a cure but cannot reasonably be cured within said forty-five (45) day period and provided that the Borrowers shall have commenced to cure such unsatisfactory work within said forty-five (45) day period and thereafter diligently and expeditiously proceeds to cure the same, after the expiration of such longer period as is reasonably necessary for the Borrowers in the exercise of due diligence to cure such unsatisfactory work, up to a maximum of an additional sixty (60) days, subject to Force Majeure, without the cure thereof), Lender may proceed under existing contracts or contract with third parties to complete such Work, as the case may be, and apply amounts contained in the applicable Work Reserve toward the labor and materials necessary to complete the same, without providing any additional prior notice to the Borrowers, and exercise any and all other remedies available to Lender upon and during the continuance of an Event of Default hereunder. (iii) In order to facilitate Lender's completion or making of any Work pursuant to Section 6.7(B)(ii) above, the Borrowers grant Lender the right to enter onto each Property during normal business hours after the expiration of the notice specified above and perform, subject to the rights of tenants, any and all work and labor necessary to complete the applicable Work and/or employ watchmen to protect the Property from damage. All sums so expended by Lender shall be deemed to have been advanced under the Loan to the Borrowers and secured by the applicable Mortgage. For this purpose, the Borrowers constitute and appoint Lender their true and lawful attorney-in-fact with full power of substitution to complete or undertake the applicable Work in the name of the Borrowers pursuant to Section 6.7(B)(ii) above. Such power of attorney shall be deemed to be a power coupled with an interest and cannot be revoked. Upon the occurrence and during the continuance of an Event of Default, the Borrowers empower said attorney-in-fact as follows: (i) to use any funds in the applicable Work Reserve for the purpose of making or completing any Work; (ii) to make such additions, changes and corrections to any Work as shall be reasonably necessary or desirable to complete the same; (iii) to employ such contractors, subcontractors, agents, architects and inspectors as shall be required for such purposes; (iv) to pay, settle or compromise all existing bills and claims which are or may become Liens against any Property, or as may be necessary or desirable for the completion of any Work, or for clearance of title; (v) to execute all applications and certificates in the name of the Borrowers which may be required by any of the contract documents; (vi) in its reasonable discretion, to prosecute and defend all actions or proceedings in connection with any Property or the rehabilitation and repair of such Property; and (vii) to do any and every act which the Borrowers might do in their own behalf to fulfill the terms of this Loan Agreement. (iv) Nothing in this Section shall: (i) make Lender responsible for making or completing any Work; (ii) require Lender to expend funds in addition to the amounts on deposit in the applicable Work Reserve to make or complete any Work; (iii) obligate Lender to proceed with any Work; or (iv) obligate Lender to demand from the Borrowers additional sums to make or complete any Work. (v) The Borrowers shall permit Lender and Lender's agents and representatives (including, without limitation, Lender's engineer, architect or inspector) or third parties performing any Work pursuant to this Section 6.7 to enter onto any Property during normal business hours upon reasonable notice (subject to the rights of tenants under their Leases) to inspect the progress of any Work and all materials being used in connection therewith, to examine all plans and shop drawings relating thereto which are or may be kept at any Property, and to complete any Work made pursuant to Section 6.7(B)(ii). The Borrowers shall use commercially reasonable efforts to cause all contractors and subcontractors to cooperate with Lender or Lender's representatives or such other persons described above in connection with inspections described in this Section 6.7(B) or the completion of the Work pursuant to this Section 6.7(B). (vi) All Work and all materials, equipment, fixtures and any other item comprising a part thereof shall be constructed, installed or completed, as applicable, free and clear of all mechanic's, materialman's or other liens (except for the Permitted Encumbrances). (vii) All Work shall comply with all applicable legal requirements of all Governmental Authorities having jurisdiction over the Properties and applicable insurance requirements, including, without limitation, applicable building codes, special use permits, environmental regulations and requirements of insurance underwriters.

  • Performance of Work by City If the Contractor fails to perform the Work in accordance with the schedule referred to in section 2 above, the City may, in its discretion, in order to bring the project closer to the schedule, perform or cause to be performed some or all of the Work, and doing so shall not waive any of the City’s rights and remedies. Before doing so, the City shall give the Contractor notice of its intention. The Contractor shall reimburse the City for additional costs incurred by the City in exercising its right to perform or cause to be performed some or all of the Work pursuant to this section.

  • PERIOD OF PERFORMANCE The period of performance for this contract begins , and ends .

  • Standard of Performance Consultant represents and warrants that it has the qualifications, experience and facilities necessary to properly perform the services required under this Agreement in a thorough, competent and professional manner. Consultant shall at all times faithfully, competently and to the best of its ability, experience and talent, perform all services described herein. In meeting its obligations under this Agreement, Consultant shall employ, at a minimum, generally accepted standards and practices utilized by persons engaged in providing services similar to those required of Consultant under this Agreement.

  • Resumption of Performance During the period that a Force Majeure Event is subsisting, the Affected Party shall, in consultation with the other Parties, make all reasonable efforts to limit or mitigate the effects of such Force Majeure Event on the performance of its obligations under the PPA. The Affected Party shall also make efforts to resume performance of its obligations under this Agreement as soon as possible and upon resumption, shall notify other Parties of the same in writing. The other Parties shall afford all reasonable assistance to the Affected Party in this regard.

  • Acceptance of Employment; Standard of Performance The Subadviser accepts its employment as a discretionary series adviser of the Designated Series and agrees to use its best professional judgment to make investment decisions for the Designated Series in accordance with the provisions of this Agreement and as set forth in Schedule D attached hereto and made a part hereof.

  • Completion of Work The Contractor agrees to complete the work on, or before October 29, 2021.

  • CORRECTION OF WORK 13.2.1 The Contractor shall be responsible for correcting all Work which the Architect has found to be defective or which fails to conform to the Contract Documents whether observed be- fore or after Substantial Completion and whether or not fabricated, installed or completed. The Contractor shall bear all costs of correcting such rejected Work, including compensation for the Architect's and the State’s additional services made necessary thereby. 13.2.2 If, within one year after the Date of Substantial Completion of the Work or designated portion thereof or within one year after acceptance by the State of designated equipment or within such longer period of time as may be prescribed by law or by the terms of any applicable special warranty required by the Contract Documents, any of the Work is found to be defective or not in accordance with the Contract Documents, the Contractor shall correct it promptly after receipt of a written notice from the State to do so unless the State has previously given the Contractor a written acceptance of such condition. This obligation shall survive termination of the Contract. The State shall give such notice promptly after discovery of the condition. 13.2.3 The Contractor shall remove from the site all portions of the Work which are defective or non-conforming and which have not been corrected under Subparagraphs 4.5.1, 13.2.1 and 13.2.4 If the Contractor fails to correct defective or nonconforming Work as provided in Subparagraphs 4.5.1, 13.2.1 and 13.2.2, the State may correct it in accordance with Paragraph 13.2.5 If the Contractor does not proceed with the correction of such defective or non- conforming Work within a reasonable time fixed by written notice from the Architect, the State may remove it and may store the materials or equipment at the expense of the Contractor. If the Contractor does not pay the cost of such removal and storage within ten days thereafter, the State may upon ten additional days written notice sell such Work at auction or at private sale and shall account for the net proceeds thereof, after deducting all the costs that should have been borne by the Contractor, including compensation for the Architect's and the State’s additional services and expenses made necessary thereby. If such proceeds of sale do not cover all costs which the Contractor should have borne, the difference shall be charged to the Contractor and an appropriate Change Order shall be issued. If the payments then or thereafter due the Contractor are not sufficient to cover such amount, the Contractor shall pay the difference to the State. 13.2.6 The Contractor shall bear the cost of making good all work of the State or separate contractors destroyed or damaged by such correction or removal. 13.2.7 Nothing contained in this Paragraph 13.2 shall be construed to establish a period of limitation with respect to any other obligation which the Contractor might have under the

  • REVIEW OF WORK The Consultant shall permit the City, its agents and/or employees to review, at any time, all work performed pursuant to the terms of this Agreement at any stage of the work;

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!