Quality Assurance Requirements There are no special Quality Assurance requirements under this Agreement.
Quality Assurance/Quality Control Contractor shall establish and maintain a quality assurance/quality control program which shall include procedures for continuous control of all construction and comprehensive inspection and testing of all items of Work, including any Work performed by Subcontractors, so as to ensure complete conformance to the Contract with respect to materials, workmanship, construction, finish, functional performance, and identification. The program established by Contractor shall comply with any quality assurance/quality control requirements incorporated in the Contract.
EMHS Governance, Safety and Quality Requirements 4.1 Participates in the maintenance of a safe work environment.
4.2 Actively participates in the Peak Performance program.
4.3 Supports the delivery of safe patient care and the consumers’ experience including participation in continuous quality improvement activities in accordance with the requirements of the National Safety and Quality Health Service Standards and other recognised health standards.
4.4 Completes mandatory training (including safety and quality training) as relevant to role.
4.5 Performs duties in accordance with the EMHS Vision and Values, WA Health Code of Conduct, Occupational Safety and Health legislation, the Disability Services Act and the Equal Opportunity Act and Government, WA Health, EMHS and Departmental / Program specific policies and procedures.
SMHS Governance, Safety and Quality Requirements 4.1 Participates in the maintenance of a safe work environment.
4.2 Participates in an annual performance development review.
4.3 Supports the delivery of safe patient care and the consumers’ experience including participation in continuous quality improvement activities in accordance with the requirements of the National Safety and Quality Health Service Standards and other recognised health standards.
4.4 Completes mandatory training (including safety and quality training) as relevant to role.
4.5 Performs duties in accordance with Government, WA Health, South Metropolitan Health Service and Departmental / Program specific policies and procedures.
4.6 Abides by the WA Health Code of Conduct, Occupational Safety and Health legislation, the Disability Services Act and the Equal Opportunity Act.
COUNTY’S QUALITY ASSURANCE PLAN The County or its agent will evaluate the Contractor’s performance under this Contract on not less than an annual basis. Such evaluation will include assessing the Contractor’s compliance with all Contract terms and conditions and performance standards. Contractor deficiencies which the County determines are severe or continuing and that may place performance of the Contract in jeopardy if not corrected will be reported to the Board of Supervisors. The report will include improvement/corrective action measures taken by the County and the Contractor. If improvement does not occur consistent with the corrective action measures, the County may terminate this Contract or impose other penalties as specified in this Contract.
Quality Assurance The parties endorse the underlying principles of the Company’s Quality Management System, which seeks to ensure that its services are provided in a manner which best conforms to the requirements of the contract with its customer. This requires the Company to establish and maintain, implement, train and continuously improve its procedures and processes, and the employees to follow the procedures, document their compliance and participate in the improvement process. In particular, this will require employees to regularly and reliably fill out documentation and checklists to signify that work has been carried out in accordance with the customer’s specific requirements. Where necessary, training will be provided in these activities.
NMHS Governance, Safety and Quality Requirements 2.1 Participates in the maintenance of a safe work environment.
2.2 Participates in an annual performance development review.
2.3 Supports the delivery of safe patient care and the consumers’ experience including participation in continuous quality improvement activities in accordance with the requirements of the National Safety and Quality Health Service Standards and other recognised health standards.
2.4 Completes mandatory training (including safety and quality training) as relevant to role.
2.5 Performs duties in accordance with Government, WA Health, North Metropolitan Health Service and Departmental / Program specific policies and procedures.
2.6 Abides by the WA Health Code of Conduct, Occupational Safety and Health legislation, the Disability Services Act and the Equal Opportunity Act.
Minimum Shipping Requirements for TIPS Sales Vendor shall ship, deliver, or provide ordered goods and services within a commercially reasonable time after acceptance of the order. If a delay in delivery is anticipated, Vendor shall notify the TIPS Member as to why delivery is delayed and provide an updated estimated time for completion. The TIPS Member may cancel the order if the delay is not commercially acceptable or not consistent with the Supplemental Agreement applicable to the order.
Minimum Site Requirements for TIPS Sales (when applicable to TIPS Sale). Cleanup: When performing work on site at a TIPS Member’s property, Vendor shall clean up and remove all debris and rubbish resulting from their work as required or directed by the TIPS Member or as agreed by the parties. Upon completion of work, the premises shall be left in good repair and an orderly, neat, clean and unobstructed condition. Preparation: Vendor shall not begin a project for which a TIPS Member has not prepared the site, unless Vendor does the preparation work at no cost, or until TIPS Member includes the cost of site preparation in the TIPS Sale Site preparation includes, but is not limited to: moving furniture, installing wiring for networks or power, and similar pre‐installation requirements. Registered Sex Offender Restrictions: For work to be performed at schools, Vendor agrees that no employee of Vendor or a subcontractor who has been adjudicated to be a registered sex offender will perform work at any time when students are, or reasonably expected to be, present unless otherwise agreed by the TIPS Member. Vendor agrees that a violation of this condition shall be considered a material breach and may result in the cancellation of the TIPS Sale at the TIPS Member’s discretion. Vendor must identify any additional costs associated with compliance of this term. If no costs are specified, compliance with this term will be provided at no additional charge. Safety Measures: Vendor shall take all reasonable precautions for the safety of employees on the worksite, and shall erect and properly maintain all necessary safeguards for protection of workers and the public. Vendor shall post warning signs against all hazards created by the operation and work in progress. Proper precautions shall be taken pursuant to state law and standard practices to protect workers, general public and existing structures from injury or damage. Smoking: Persons working under Agreement shall adhere to the TIPS Member’s or local smoking statutes, codes, ordinances, and policies.
Quality Assurance Program An employee shall be entitled to leave of absence without loss of earnings from her or his regularly scheduled working hours for the purpose of writing examinations required by the College of Nurses of Ontario arising out of the Quality Assurance Program.
