Maintenance and Support Services If this Agreement is for IT goods or services, this section applies: Unless otherwise specified in this Agreement: The Contractor shall promptly provide the Court with all Upgrades, including without limitation: (i) all Upgrades generally made available by Contractor to its other customers; (ii) Upgrades as necessary so that the Work complies with the Specifications and Applicable Law (including changes in Applicable Law); (iii) Upgrades as necessary so that the Work operates under new versions or releases of the Court’s operating system or database platform; and (iv) all on-site services necessary for installation of Upgrades. Without limiting any other obligation of Contractor under this Agreement, Contractor represents and warrants that it will maintain services, equipment, software or any other part of the Work so that they operate in accordance with their Specifications and Documentation; and The Contractor shall respond to the Court within four (4) hours after the Court reports a Technical Support Incident (such hours all occurring during Standard M&S Hours) to Contractor. DELIVERY, ACCEPTANCE, AND PAYMENT Delivery. Contractor shall deliver to the Court the Deliverables in accordance with this Agreement, including the Statement of Work. Unless otherwise specified by this Agreement, Contractor will deliver all goods purchased by the Court “Free on Board Destination Freight Prepaid” to the Court at the address and location specified by the Court. Title to all goods purchased by the Court vests in the Court upon payment of the applicable purchase price. Contractor will bear the risk of loss for any Work being delivered until received by the Court at the proper location. All shipments by Contractor or its Subcontractors must include packing sheets identifying: this Agreement number, the Court’s purchase order number, item number, quantity and unit of measure, part number and description of the goods shipped, and appropriate evidence of inspection, if required. Goods for different Agreements shall be listed on separate packing sheets.
Support Services Rehabilitation, counselling and EAP’s. Support is strictly non- punitive, and can be accessed at anytime (self-identification of the need for help is strongly encouraged).
Support and Maintenance Services Information about Teradici’s support and maintenance for the Licensed Product may be found at xxxxx://xxxx.xxxxxxxx.xxx.
Service Level Agreement 6.1 NCR Voyix will use commercially reasonable efforts to make the Service available to you at or above the Availability Rate set forth at xxxxx://xxx.xxx.xxx/support/aloha-sla. If NCR Voyix does not meet the Availability Rate, you are entitled to request a service-level credit subject to the terms of this Agreement. This credit is calculated as a percentage of the monthly recurring bill (or monthly pro rata share of billing, if billing does not occur monthly) for the Service for the month in which the Availability Rate was not met. The Availability Rate is determined by: (a) dividing the total number of valid outage minutes in a calendar month by the total number of minutes in that month; (b) subtracting that quotient from 1.00; (c) multiplying that difference by 100; and (d) rounding that result to two decimal places in accordance with standard rounding conventions. The number of outage minutes per day for a given service is determined by the lesser of the number of outage minutes.
6.2 Unavailability due to other conditions or caused by factors outside of NCR Voyix’s reasonable control will not be included in the calculation of the Availability Rate. Further, the following are expressly excluded from the calculation of the Availability Rate: (a) service unavailability affecting services or application program interfaces that are not used by you; (b) cases where fail-over to another data center is available but not utilized; (c) transient time-outs, required re-tries, or slower-than-normal response caused by factors outside of NCR Voyix’s reasonable control; (d) Scheduled Downtime, including maintenance and upgrades; (e) force majeure; (f) transmission or communications outages outside the NCR Voyix- controlled environment; (g) store-level down-time caused by factors outside of NCR Voyix’s reasonable control; (h) outages attributable to services, hardware, or software not provided by NCR Voyix, including, but not limited to, issues resulting from inadequate bandwidth or related to third-party software or services;
(i) use of the Service in a manner inconsistent with the documentation for the application program interface or the NCR Voyix Product; (j) your Point of Sale (“POS”) failure or the failure to properly maintain the POS environment, including updating the POS firmware or version of the software running on the POS as recommended by either NCR Voyix, a third-party POS reseller or servicer; and (k) issues related to third party domain name system (“DNS”) errors or failures.
6.3 To obtain a service-level credit, you must submit a claim by contacting NCR Voyix through the website at xxxxx://xxx.xxx.xxx/support/aloha-sla Your failure to provide the claim and other information will disqualify you from receiving a credit. NCR Voyix must receive claims within 60 days from the last day of the impacted month. After that date, claims are considered waived and will be refused. You must be in compliance with the Agreement in order to be eligible for a service-level credit. You may not unilaterally offset for any performance or availability issues any amount owed to NCR Voyix. If multiple Services experience an outage in a given month, the total credit for that month will be the highest credit allowed for any single Service which failed; there is no stacking of credits.
6.4 The remedies set forth in the Section are your sole and exclusive remedies for performance or availability issues affecting the Services, including any failure by NCR Voyix to achieve the Availability Rate.
XXX Hosting 10.1 XXX Hosting is not required for resale in the BellSouth region.
Maintenance Services Subject to Client’s timely payment of the applicable maintenance fees, Accenture will make available the following maintenance services (“Maintenance Services”):
Software Maintenance Subrecipient shall apply security patches and upgrades in a timely manner and keep virus software up-to-date on all systems on which State data may be stored or accessed.
Directory Assistance Service Updates 8.3.3.1 BellSouth shall update end user listings changes daily. These changes include:
8.3.3.1.1 New end user connections
3.3.1.2 End user disconnections
Network Maintenance and Management 38.1 The Parties will work cooperatively to implement this Agreement. The Parties will exchange appropriate information (for example, maintenance contact numbers, network information, information required to comply with law enforcement and other security agencies of the government, escalation processes, etc.) to achieve this desired result.
38.2 Each Party will administer its network to ensure acceptable service levels to all users of its network services. Service levels are generally considered acceptable only when End Users are able to establish connections with little or no delay encountered in the network. Each Party will provide a twenty four (24)-hour contact number for Network Traffic Management issues to the other’s surveillance management center.
38.3 Each Party maintains the right to implement protective network traffic management controls, such as “cancel to”, “call gapping” or seven (7)-digit and ten (10)-digit code gaps, to selectively cancel the completion of traffic over its network, including traffic destined for the other Party’s network, when required to protect the public-switched network from congestion as a result of occurrences such as facility failures, switch congestion or failure or focused overload. Each Party shall immediately notify the other Party of any protective control action planned or executed.
38.4 Where the capability exists, originating or terminating traffic reroutes may be implemented by either Party to temporarily relieve network congestion due to facility failures or abnormal calling patterns. Reroutes shall not be used to circumvent normal trunk servicing. Expansive controls shall be used only when mutually agreed to by the Parties.
38.5 The Parties shall cooperate and share pre-planning information regarding cross-network call-ins expected to generate large or focused temporary increases in call volumes to prevent or mitigate the impact of these events on the public-switched network, including any disruption or loss of service to the other Party’s End Users. Facsimile (FAX) numbers must be exchanged by the Parties to facilitate event notifications for planned mass calling events.
38.6 Neither Party shall use any Interconnection Service provided under this Agreement or any other service related thereto or used in combination therewith in any manner that interferes with or impairs service over any facilities of AT&T-21STATE, its affiliated companies or other connecting telecommunications carriers, prevents any carrier from using its Telecommunications Service, impairs the quality or the privacy of Telecommunications Service to other carriers or to either Party’s End Users, causes hazards to either Party’s personnel or the public, damage to either Party’s or any connecting carrier’s facilities or equipment, including any malfunction of ordering or billing systems or equipment. Upon such occurrence either Party may discontinue or refuse service, but only for so long as the other Party is violating this provision. Upon any such violation, either Party shall provide the other Party notice of the violation at the earliest practicable time.
38.7 AT&T TENNESSEE hereby commits to provide Disaster Recovery to CLEC according to the plan below.
38.7.1 AT&T TENNESSEE Disaster Recovery Plan
38.7.2 In the unlikely event of a disaster occurring that affects AT&T TENNESSEE’s long-term ability to deliver traffic to a CLEC, general procedures have been developed by AT&T TENNESSEE to hasten the recovery process in accordance with the Telecommunications Service Priority (TSP) Program established by the FCC to identify and prioritize telecommunication services that support national security or emergency preparedness (NS/EP) missions. A description of the TSP Program as it may be amended from time to time is available on AT&T TENNESSEE’s Wholesale – Southeast Region Web site. Since each location is different and could be affected by an assortment of potential problems, a detailed recovery plan is impractical. However, in the process of reviewing recovery activities for specific locations, some basic procedures emerge that appear to be common in most cases.
38.7.3 These general procedures should apply to any disaster that affects the delivery of traffic for an extended time period. Each CLEC will be given the same consideration during an outage, and service will be restored as quickly as possible. AT&T TENNESSEE reserves the right to make changes to these procedures as improvements become available or as business conditions dictate.
38.7.4 This plan will cover the basic recovery procedures that would apply to every CLEC.
Service Level Agreements If a Service or a Plan includes a Service Level Agreement (SLA):
(a) we are liable for any remedy or rebate specified by the SLA; and
(b) subject to clauses 40 to 42, and to the express terms of the SLA, our liability for breach of the SLA is limited to such remedy or rebate.
