No Damages Relief Against City Sample Clauses

No Damages Relief Against City. It is acknowledged by Developer that the City would not have entered into this Agreement if the City were to be liable in damages under or with respect to this Agreement or the application thereof. Consequently, and except for the payment of attorneys’ fees and court costs, the City shall not be liable in damages to Developer and Developer covenants on behalf of itself and its successors in interest not to sue for or claim any damages: (a) for any default under this Agreement; (b) for the regulatory taking, impairment or restriction of any right or interest conveyed or provided hereunder or pursuant hereto; or (c) arising out of or connected with any dispute, controversy or issue regarding the application or interpretation or effect of the provisions of this Agreement. The City and Developer agree that the provisions of this Section 11.3.4 do not apply for damages which: (a) do not arise under this Agreement; (b) are not with respect to any right or interest conveyed or provided under this Agreement or pursuant to this Agreement; or (c) do not arise out of or which are not connected to any dispute, controversy, or issue regarding the application, interpretation, or effect of the provisions of this Agreement or the application of any City rules, regulations, or official policies.
Sample 1Sample 2Sample 3See All (26)
AutoNDA by SimpleDocs
No Damages Relief Against City. The parties acknowledge that the City would not have entered into this Agreement had it been exposed to damage claims from Owner, or Owners successors in interest, assigns, partners, or anyone acting on behalf of the Owner for any breach thereof. As such, the parties agree that in no event shall Owner, or Owners successors in interest, assigns, partners, or anyone acting on behalf of the Owner be entitled to recover damages against City for breach of this Agreement.
Sample 1Sample 2Sample 3See All (12)
No Damages Relief Against City. The parties acknowledge that City would not have entered into this Agreement had it been exposed to damage claims from Developer for any breach thereof. As such, the parties agree that in no event shall Developer be entitled to recover damages against City for breach of this Agreement.
Sample 1
No Damages Relief Against City. Notwithstanding anything else in this Agreement to the contrary, Owner acknowledges that the City would not have entered into this Agreement had it been exposed to damage claims from Owner for any breach hereof. As such, the parties agree that in no event shall Owner be entitled to recover damages of any kind whatsoever against City for breach of this Agreement. SIGNATURE PAGE TO DEVELOPMENT AGREEMENT BY AND BETWEEN CITY OF DESERT HOT SPRINGS AND XXX X. XXXXXXX AND XXXXXX XXXXXXXXX XXXXXXX, TRUSTEES OF THE XXXXXXX FAMILY REVOCABLE LIVING TRUST, AND XXXXXX XXXX-XXXXX (A.K.A, XXXXXX XXXXXXX)
Sample 1
No Damages Relief Against City. The parties acknowledge that the City would not have entered into this Agreement had it been exposed to damage claims from Developer for any breach thereof. As such, notwithstanding any other provision in this Agreement to the contrary, the parties agree that in no event shall Developer be entitled to recover damages against City for breach of this Agreement, and developer hereby waives all claims for damages. 4. Except as specifically amended herein, the terms of the Development Agreement shall remain in full force and effect. 5. Upon execution of this First Amendment, City shall promptly arrange for its recordation as provided in California Government Code Sections 65868 and 65868.5 and Burbank Municipal Code Section 00-0-00000.
Sample 1
No Damages Relief Against City. It is acknowledged by Xxxxx that the City would not have entered into this Agreement if the City were to be liable in damages under or with respect to this Agreement or the application thereof. Consequently, and except for the payment of attorneys’ fees and court costs, the City shall not be liable in damages to any Developer and Xxxxx covenants on behalf of itself and its successors in interest not to sue for or claim any damages:
Sample 1
No Damages Relief Against City. The parties acknowledge that City would not have entered into this Agreement had it been exposed to damage claims from CSE for any breach thereof. As such, the parties agree that in no event shall CSE be entitled to recover damages against City for breach of this Agreement. However, should a court issue a final judgment or other final determination that the City has adopted a tax or assessment, or increase thereof, in violation of Section 4.08 and CSE has paid such tax or assessment, or increase therefore, CSE shall be entitled a refund of such monies it has paid.
Sample 1
AutoNDA by SimpleDocs
No Damages Relief Against City. The Parties acknowledge that the City would not have entered into this Covenant had it been exposed to damage claims from DHS SOLAR for any breach thereof. As such, the Parties agree that in no event shall DHS SOLAR be entitled to recover monetary damages against City for breach of this Covenant.
Sample 1

Related to No Damages Relief Against City

  • No Consequential Damages Other than the Liquidated Damages heretofore described and the indemnity obligations set forth in Article 18.1, in no event shall any Party be liable under any provision of this Agreement for any losses, damages, costs or expenses for any special, indirect, incidental, consequential, or punitive damages, including but not limited to loss of profit or revenue, loss of the use of equipment, cost of capital, cost of temporary equipment or services, whether based in whole or in part in contract, in tort, including negligence, strict liability, or any other theory of liability; provided, however, that damages for which a Party may be liable to another Party under separate agreement will not be considered to be special, indirect, incidental, or consequential damages hereunder.

  • Waiver of Consequential Damages, Etc To the fullest extent permitted by applicable law, the Borrower shall not assert, and hereby waives, any claim against any Indemnitee, on any theory of liability, for special, indirect, consequential or punitive damages (as opposed to direct or actual damages) arising out of, in connection with, or as a result of, this Agreement, any other Loan Document or any agreement or instrument contemplated hereby, the transactions contemplated hereby or thereby, any Loan or Letter of Credit or the use of the proceeds thereof. No Indemnitee referred to in subsection (b) above shall be liable for any damages arising from the use by unintended recipients of any information or other materials distributed to such unintended recipients by such Indemnitee through telecommunications, electronic or other information transmission systems in connection with this Agreement or the other Loan Documents or the transactions contemplated hereby or thereby other than for direct or actual damages resulting from the gross negligence or willful misconduct of such Indemnitee as determined by a final and nonappealable judgment of a court of competent jurisdiction.

  • Damages; Relief Termination of this Agreement shall not preclude either Party from claiming any other damages, compensation or relief that it may be entitled to upon such termination.

  • Disclaimer of Consequential Damages Notwithstanding any provision to the contrary, in no event shall any Party be liable to another Party for any incidental, consequential, special, exemplary or indirect damages, lost business profits or lost data arising out of or in any way related to the Contract Documents.

  • Limitation of Consequential Damages EXCEPT FOR (A) THIRD PARTY CLAIMS THAT ARE SUBJECT TO INDEMNIFICATION UNDER THIS ARTICLE 10, (B) CLAIMS ARISING OUT OF A PARTY’S WILLFUL MISCONDUCT OR FRAUD UNDER THIS AGREEMENT, (C) A PARTY’S BREACH OF ARTICLE 4, (D) NOVARTIS’ BREACH OF SECTION 6.5, OR (E) CLAIMS ARISING OUT OF A PARTY’S BREACH OF ITS CONFIDENTIALITY OBLIGATIONS UNDER THIS AGREEMENT, NEITHER PARTY NOR ANY OF ITS AFFILIATES WILL BE LIABLE TO THE OTHER PARTY TO THIS AGREEMENT OR ITS AFFILIATES FOR ANY INCIDENTAL, CONSEQUENTIAL, SPECIAL, PUNITIVE OR OTHER INDIRECT DAMAGES OR LOST OR IMPUTED PROFITS OR ROYALTIES, LOST DATA OR COST OF PROCUREMENT OF SUBSTITUTE GOODS OR SERVICES, WHETHER LIABILITY IS ASSERTED IN CONTRACT, TORT (INCLUDING NEGLIGENCE AND STRICT PRODUCT LIABILITY), INDEMNITY OR CONTRIBUTION, AND IRRESPECTIVE OF WHETHER THAT PARTY OR ANY REPRESENTATIVE OF THAT PARTY HAS BEEN ADVISED OF, OR OTHERWISE MIGHT HAVE ANTICIPATED THE POSSIBILITY OF, ANY SUCH LOSS OR DAMAGE.

  • Limitation on Consequential Damages NEITHER PARTY WILL HAVE ANY OBLIGATION OR LIABILITY (WHETHER IN CONTRACT, WARRANTY, TORT (INCLUDING NEGLIGENCE) OR OTHERWISE, AND NOTWITHSTANDING ANY FAULT, NEGLIGENCE (WHETHER ACTIVE, PASSIVE OR IMPUTED), REPRESENTATION, STRICT LIABILITY OR PRODUCT LIABILITY), FOR COVER OR FOR ANY INCIDENTAL, INDIRECT, CONSEQUENTIAL, MULTIPLIED, PUNITIVE, SPECIAL, OR EXEMPLARY DAMAGES OR LOSS OF REVENUE, PROFIT, SAVINGS OR BUSINESS ARISING FROM OR OTHERWISE RELATED TO THIS AGREEMENT, EVEN IF A PARTY OR ITS REPRESENTATIVES HAVE BEEN ADVISED OF THE POSSIBILITY OF SUCH DAMAGES. THE PARTIES ACKNOWLEDGE THAT THESE EXCLUSIONS OF POTENTIAL DAMAGES WERE AN ESSENTIAL ELEMENT IN SETTING CONSIDERATION UNDER THIS AGREEMENT.

  • Indemnity Consequential Damages and Insurance 18.1 Indemnity 18.1.1 Indemnified Party 18.1.2 Indemnifying Party 18.1.3 Indemnity Procedures 18.2 Consequential Damages 18.3 Insurance 18.3.1 18.3.2 18.3.3 18.3.4 18.3.5 18.3.6 18.3.7 18.3.8 18.3.9 18.3.10 18.3.11

  • Waiver of Punitive Damages Notwithstanding anything to the contrary contained in this Agreement, the Borrower hereby agrees that it shall not seek from the Lenders or the Administrative Agent punitive, consequential, or indirect damages relating to any such matters under any theory of liability.

  • Waiver of Consequential Damages To the fullest extent permitted by applicable Law, the Borrower shall not assert, and hereby waives, any claim against any Indemnitee, on any theory of liability, for special, indirect, consequential or punitive damages (as opposed to direct or actual damages) arising out of, in connection with, or as a result of, this Agreement, any other Loan Document, the Related Documents or any agreement or instrument contemplated hereby or thereby, the transactions contemplated hereby or thereby, any Term Loan or the use of the proceeds thereof. No Indemnitee referred to in subsection (b) above shall be liable for any damages arising from the use by unintended recipients of any information or other materials distributed by it through telecommunications, electronic or other information transmission systems in connection with this Agreement or the other Loan Documents, the Related Documents or the transactions contemplated hereby or thereby other than for direct or actual damages resulting from the gross negligence or willful misconduct of such Indemnitee as determined by a final and nonappealable judgment of a court of competent jurisdiction.

  • Consequential Damages Waiver NEITHER PARTY SHALL HAVE ANY LIABILITY ARISING OUT OF OR RELATED TO THIS AGREEMENT FOR ANY LOSS OF USE, LOST DATA, LOST PROFITS, FAILURE OF SECURITY MECHANISMS, INTERRUPTION OF BUSINESS, LOSS CAUSED BY THE INTERRUPTION, TERMINATION OR DELAYED OPERATION OF THE INTERNET, THIRD-PARTY TELECOMMUNICATION SERVICES OR THIRD-PARTY SECURITY FEATURES OR SYSTEMS, EXCEPT AS REQUIRED BY LAW. EXCEPT FOR CUSTOMER’S BREACH OF SECTION 1.4 (USE RESTRICTIONS) OR EITHER PARTY’S UNLAWFUL OR WILLFUL MISCONDUCT OR GROSS NEGLIGENCE, NEITHER PARTY SHALL BE LIABLE FOR ANY INDIRECT, SPECIAL, INCIDENTAL, EXEMPLARY, PUNITIVE, RELIANCE, OR CONSEQUENTIAL DAMAGES OF ANY KIND, EVEN IF INFORMED OF THE POSSIBILITY IN ADVANCE, SUFFERED BY ANY PARTY OR ANY PARTY CLAIMING ON BEHALF OF OR THROUGH THE OTHER PARTY, OR ANY OTHER THIRD PARTY RESULTING FROM OR ARISING OUT OF OR RELATED TO THIS AGREEMENT OR THE PERFORMANCE OR BREACH THEREOF.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!