Compliance with Contractor Employee Jury Service Ordinance Contractor shall comply with the County Ordinance with respect to provision of jury duty pay to employees and have and adhere to a written policy that provides that its employees shall receive from the Contractor, on an annual basis, no less than five days of regular pay for actual jury service in San Mateo County. The policy may provide that employees deposit any fees received for such jury service with the Contractor or that the Contractor deduct from the employees’ regular pay the fees received for jury service.
Operation of Agreement This Agreement will be effective and binding immediately upon its execution, but, anything in this Agreement to the contrary notwithstanding, this Agreement will not be operative unless and until a Change in Control occurs. Upon the occurrence of a Change in Control at any time during the Term, without further action, this Agreement shall become immediately operative.
Maintenance of Properties and Leases Each Loan Party shall, and shall cause each of its Subsidiaries to, maintain in good repair, working order and condition (ordinary wear and tear excepted) in accordance with the general practice of other businesses of similar character and size, all of those properties useful or necessary to its business, and from time to time, such Loan Party will make or cause to be made all appropriate repairs, renewals or replacements thereof.
Suspension of unsafe Construction Works (i) Upon recommendation of the Authority’s Engineer to this effect, the Authority may by notice require the Contractor to suspend forthwith the whole or any part of the Works if, in the reasonable opinion of the Authority’s Engineer, such work threatens the safety of the Users and pedestrians.
(ii) The Contractor shall, pursuant to the notice under Clause 11.17 (i), suspend the Works or any part thereof for such time and in such manner as may be specified by the Authority and thereupon carry out remedial measures to secure the safety of suspended works, the Users and pedestrians. The Contractor may by notice require the Authority’s Engineer to inspect such remedial measures forthwith and make a report to the Authority recommending whether or not the suspension hereunder may be revoked. Upon receiving the recommendations of the Authority’s Engineer, the Authority shall either revoke such suspension or instruct the Contractor to carry out such other and further remedial measures as may be necessary in the reasonable opinion of the Authority, and the procedure set forth in this Clause 11.17 shall be repeated until the suspension hereunder is revoked.
(iii) Subject to the provisions of Clause 21.6, all reasonable costs incurred for maintaining and protecting the Works or part thereof during the period of suspension (the “Preservation Costs”), shall be borne by the Contractor; provided that if the suspension has occurred as a result of any breach of this Agreement by the Authority, the Preservation Costs shall be borne by the Authority.
(iv) If suspension of Works is for reasons not attributable to the Contractor, the Authority’s Engineer shall determine any Time Extension to which the Contractor is reasonably entitled.
Operation of Property (a) Borrower shall not cause or permit Mortgage Borrower to, without Lender’s prior consent: (i) surrender, terminate or cancel (or permit to be surrendered, terminated or canceled) any of the Operating Leases (other than in connection with a sale and release of an Individual Property permitted hereunder), or exercise any remedies under any of the Operating Leases; (ii) reduce or consent to the reduction of (or permit the reduction or the consent to the reduction) of the term of any of the Operating Leases or any Operating Lease Guaranty; (iii) decrease or consent to any decrease (or permit to be decreased or the consent to the decrease) of the amount of any rent or other charges payable under any of the Operating Leases; (iv) Transfer, convey, assign, sell, mortgage, encumber, pledge, hypothecate, grant a security interest in, grant an option or options with respect to, or otherwise dispose of (directly or indirectly, voluntarily or involuntarily, by operation of law or otherwise, whether or not for consideration) the Properties or any collateral for the Mortgage Loan (or permit Operating Company to do so), in each case without the prior written consent of Lender or except as expressly permitted in Section 5.1.20 or Section 5.2.10, or (v) otherwise modify, change, supplement, alter or amend, or waive or release (or permit to be modified, changed, supplemented, altered, amended, waived or released) any of the rights and remedies of Borrower, Mortgage Borrower or any Operating Company under any of the Operating Leases in any material respect or any Operating Lease Guaranty (provided that Lender shall not unreasonably withhold its consent to any modification, change, supplement, alteration, amendment, waiver or release of the Operating Lease as may be reasonably necessary to comply with the requirements of this Agreement or any other Loan Document).
(b) During the continuance of an Event of Default, Borrower shall not exercise (and shall not cause or permit Mortgage Borrower to exercise) any rights, make any decisions, grant any approvals or otherwise take any action under any Operating Lease, Operating Lease Guaranty or any Management Agreement without, in each instance, the prior written consent of Lender, which consent may be withheld in Lender’s sole discretion.
Compliance with Leases (i) Make all payments and otherwise perform all material obligations in respect of all leases of real property to which the Borrower or any of its Subsidiaries is a party, keep such leases in full force and effect and not allow such leases to lapse or be terminated or any rights to renew such leases to be forfeited or cancelled (except, in the case of the Borrower and Subsidiaries of the Borrower only, if in the reasonable business judgment of such Subsidiary it is in its best economic interest not to maintain such lease or prevent such lapse, termination, forfeiture or cancellation and such failure to maintain such lease or prevent such lapse, termination, forfeiture or cancellation is not in respect of a Qualifying Ground Lease or an Operating Lease of an Unencumbered Asset and could not otherwise reasonably be expected to result in a Material Adverse Effect), notify the Administrative Agent of any default by any party with respect to such leases and cooperate with the Administrative Agent in all respects to cure any such default, and cause each of its Subsidiaries to do so.
(ii) With respect to any Qualifying Ground Lease related to any Unencumbered Asset:
(A) pay when due the rent and other amounts due and payable thereunder (subject to applicable cure or grace periods);
(B) timely perform and observe all of the material terms, covenants and conditions required to be performed and observed by it as tenant thereunder (subject to applicable cure or grace periods);
(C) do all things necessary to preserve and keep unimpaired such Qualifying Ground Lease and its rights thereunder;
(D) diligently and continuously enforce the material obligations of the lessor or other obligor thereunder;
(E) deliver to the Administrative Agent all default and other material notices received by it or sent by it under the applicable Qualifying Ground Lease;
(F) upon the Administrative Agent’s reasonable written request and at reasonable intervals, unless an Event of Default shall have occurred and be continuing, in which case, upon written request at any time, provide to the Administrative Agent any information or materials relating to such Qualifying Ground Lease and evidencing the applicable Subsidiary Guarantor’s due observance and performance of its material obligations thereunder;
(G) in connection with the bankruptcy or other insolvency proceedings of any ground lessor or other obligor, ratify the legality, binding effect and enforceability of the applicable Qualifying Ground Lease within the applicable time period therefor in such proceedings, notwithstanding any rejection by such ground lessor or obligor or trustee, custodian or receiver related thereto;
(H) at reasonable times and at reasonable intervals, deliver to the Administrative Agent (or, subject to the requirements of the subject Qualifying Ground Lease, cause the applicable lessor or other obligor to deliver to the Administrative Agent), an estoppel certificate and consent agreement in relation to such Qualifying Ground Lease in form and substance reasonably acceptable to the Administrative Agent, in its discretion, and, in the case of the estoppel certificate, setting forth (i) the name of lessee and lessor under the Qualifying Ground Lease (if applicable); (ii) that such Qualifying Ground Lease is in full force and effect and has not been modified except to the extent the Administrative Agent has received notice of such modification; (iii) that no rental and other payments due thereunder are delinquent as of the date of such estoppel; and (iv) whether such Person knows of any actual or alleged defaults or events of default under the applicable Qualifying Ground Lease; provided, that each Loan Party hereby agrees to execute and deliver to the Administrative Agent, within ten (10) days of any request therefor, such documents, instruments, agreements, assignments or other conveyances reasonably requested by the Administrative Agent in connection with or in furtherance of any of the provisions set forth above or the rights granted to the Administrative Agent in connection therewith.
RIGHT OF ALLOTTEE TO USE COMMON AREAS AND FACILITIES SUBJECT TO PAYMENT OF TOTAL MAINTENANCE CHARGES
Condition of the Contractor’s Property or Equipment The Contractor shall make the Property and/or equipment available to the Judicial Council, pursuant to the terms and conditions set forth in this Agreement. The Contractor shall immediately remedy any problem with the Property’s physical plant or equipment that impairs or diminishes the quality of the Program. The Contractor shall ensure the appropriate hot water, heating, and ventilation is provided at the Property during the Program, inclusive in the prices set forth herein.
Selection of Subcontractors, Procurement of Materials and Leasing of Equipment The contractor shall not discriminate on the grounds of race, color, religion, sex, national origin, age or disability in the selection and retention of subcontractors, including procurement of materials and leases of equipment. The contractor shall take all necessary and reasonable steps to ensure nondiscrimination in the administration of this contract.
a. The contractor shall notify all potential subcontractors and suppliers and lessors of their EEO obligations under this contract.
b. The contractor will use good faith efforts to ensure subcontractor compliance with their EEO obligations.
Litigation; Compliance with Law Except as disclosed, there is no (i) action, suit, claim, proceeding or investigation pending or, to the best of the Company’s knowledge, threatened against or affecting the Company, at law or in equity, or before or by any municipal or other governmental department, commission, board, bureau, agency or instrumentality, domestic or foreign; (ii) arbitration proceeding relating to the Company pending under collective bargaining agreements or otherwise; or (iii) governmental inquiry pending or, to the best of the Company’s knowledge, threatened against or affecting the Company (including, without limitation, any inquiry as to the qualification of the Company to hold or receive any license or permit), and, to the best of the Company’s knowledge, there is no reasonable basis for any of the foregoing. The Company is not in default with respect to any governmental order, writ, judgment, injunction or decree known to or served upon the Company of any court or of any governmental department, commission, board, bureau, agency or instrumentality, domestic or foreign. There is no action or suit by the Company pending or threatened against others. The Company has complied in all respects with all laws, rules, regulations and orders applicable to its businesses, operations, properties, assets, products and services, and the Company has all necessary permits, licenses and other authorizations required to conduct its business as conducted and as proposed to be conducted, except to the extent failure to comply or obtain any such permits, licenses or authorizations will not have a material adverse effect. There is no existing law, rule, regulation or order, and the Company is not aware of any proposed law, rule, regulation or order, which would prohibit or materially restrict the Company from, or otherwise materially and adversely affect the Company in, conducting its business in any jurisdiction in which it is now conducting business or in which it proposes to conduct business.
