Normal time to complete Sample Clauses

Normal time to complete. (1) In gen- eral. The amount of time normally re- quired to complete an item is the item’s reasonably expected production period, as described in § 1.263A–12, deter- mined at the end of the contracting year. Thus, in general, the expected production period for an item begins when a taxpayer incurs at least five percent of the costs that would be allo- cable to the item under § 1.460–5 and ends when the item is ready to be held for sale and all reasonably expected production activities are complete. In the case of components that are assem- bled or reassembled into an item or unit at the customer’s facility by the taxpayer’s employees or agents, the production period ends when the com- ponents are assembled or reassembled into an operable item or unit. To the extent that several distinct activities related to the production of the item are expected to occur simultaneously, the period during which these distinct activities occur is not counted more than once. Furthermore, when deter- mining the normal time to complete an item, a taxpayer is not required to con- sider activities performed or costs in- curred that would not be allocable con- tract costs under section 460 (e.g., inde- pendent research and development ex- penses (as defined in § 1.460–1(b)(9)) and marketing expenses). Moreover, the time normally required to design and manufacture the first unit of an item for which the taxpayer intends to produce multiple units generally does not indicate the normal time to com- plete the item.
Sample 1Sample 2Sample 3See All (8)
AutoNDA by SimpleDocs
Normal time to complete. C enters into a multi-unit contract to produce four units of an item. C does not anticipate pro- ducing any additional units of the item. C expects to perform the research, design, and development that are directly allocable to the particular item and to produce the first unit in the first 24 months. C reasonably ex- pects the production period for each of the three remaining units will be 3 months. This contract is not a contract that involves the manufacture of an item that normally re- quires more than 12 months to complete be-
Sample 1Sample 2Sample 3See All (6)
Normal time to complete. C enters into a multi-unit contract to produce four units of an item. C does not anticipate pro- ducing any additional units of the item. C expects to perform the research, design, and development that are directly allocable to the particular item and to produce the first unit in the first 24 months. C reasonably ex- pects the production period for each of the three remaining units will be 3 months. This contract is not a contract that involves the manufacture of an item that normally re- quires more than 12 months to complete be- cause the normal time to complete the item is 3 months. However, the contract does not satisfy the 90-day safe harbor for unique items because the normal time to complete the first unit of this item exceeds 90 days. Thus, the contract might involve the manu- facture of a unique item depending on the facts and circumstances.
Sample 1Sample 2

Related to Normal time to complete

  • Failure to Complete If Artist becomes ill, dies, or is otherwise unable or unwilling to complete the Project in accordance with the Agreement, any work already done on the Project will be the City’s property. The City will be entitled to withhold any sums not yet paid to Artist, and may use any such sums toward completion of the Project in any manner the City deems appropriate.

  • Extension of time for completion (i) Without prejudice to any other provision of this Agreement for and in respect of extension of time, the Contractor shall be entitled to extension of time in the Project Completion Schedule (the “Time Extension”) to the extent that completion of any Project Milestone is or will be delayed by any of the following, namely: (a) delay in providing the Right of Way of Construction Zone, environmental clearances or approval of railway authorities, specified in Clause 3.1 (iv); (b) Change of Scope (unless an adjustment to the Scheduled Completion Date has been agreed under Article 13); (c) occurrence of a Force Majeure Event; (d) any delay, impediment or prevention caused by or attributable to the Authority, the Authority's personnel or the Authority's other contractors on the Site; and (e) any other cause or delay which entitles the Contractor to Time Extension in accordance with the provisions of this Agreement. (ii) The Contractor shall, no later than 15 (fifteen) business days from the occurrence of an event or circumstance specified in Clause 10.5 (i), inform the Authority’s Engineer by notice in writing, with a copy to the Authority, stating in reasonable detail with supporting particulars, the event or circumstances giving rise to the claim for Time Extension in accordance with the provisions of this Agreement. Provided that the period of 15 (fifteen) business days shall be calculated from the date on which the Contractor became aware, or should have become aware, of the occurrence of such an event or circumstance. Provided further that notwithstanding anything to the contrary contained in this Agreement, Time Extension shall be due and applicable only for the Works which are affected by the aforesaid events or circumstances and shall not in any manner affect the Project Completion Schedule for and in respect of the Works which are not affected hereunder. (iii) On the failure of the Contractor to issue to the Authority’s Engineer a notice in accordance with the provisions of Clause 10.5 (ii) within the time specified therein, the Contractor shall not be entitled to any Time Extension and shall forfeit its right for any such claims in future. For the avoidance of doubt, in the event of failure of the Contractor to issue notice as specified in this clause 10.5 (iii), the Authority shall be discharged from all liability in connection with the claim. (iv) The Authority’s Engineer shall, on receipt of the claim in accordance with the provisions of Clause 10.5 (ii), examine the claim expeditiously within the time frame specified herein. In the event the Authority’s Engineer requires any clarifications to examine the claim, the Authority’s Engineer shall seek the same within 15 (fifteen) days from the date of receiving the claim. The Contractor shall, on receipt of the communication of the Authority’s Engineer requesting for clarification, furnish the same to the Authority’s Engineer within 10 (ten) days thereof. The Authority’s Engineer shall, within a period of 30 (thirty) days from the date of receipt of such clarifications, forward in writing to the Contractor its determination of Time Extension. Provided that when determining each extension of time under this Clause 10.5, the Authority’s Engineer shall review previous determinations and may increase, but shall not decrease, the total Time Extension. (v) If the event or circumstance giving rise to the notice has a continuing effect: (a) a fully detailed claim shall be considered as interim; (b) the Contractor shall, no later than 10 (ten) days after the close of each month, send further interim claims specifying the accumulated delay, the extension of time claimed, and such further particulars as the Authority’s Engineer may reasonably require; and (c) the Contractor shall send a final claim within 30 (thirty) days after the effect of the event or the circumstance ceases. Upon receipt of the claim hereunder, the Authority’s Engineer shall examine the same in accordance with the provisions of Clause 10.5 (iv) within a period of 30 (thirty) days of the receipt thereof

  • General Conditions Applicable to Option to Build If the Interconnection Customer assumes responsibility for the design, procurement and construction of the Participating TO's Interconnection Facilities and Stand Alone Network Upgrades, (1) the Interconnection Customer shall engineer, procure equipment, and construct the Participating TO's Interconnection Facilities and Stand Alone Network Upgrades (or portions thereof) using Good Utility Practice and using standards and specifications provided in advance by the Participating TO; (2) The Interconnection Customer’s engineering, procurement and construction of the Participating TO's Interconnection Facilities and Stand Alone Network Upgrades shall comply with all requirements of law to which the Participating TO would be subject in the engineering, procurement or construction of the Participating TO's Interconnection Facilities and Stand Alone Network Upgrades; (3) the Participating TO shall review, and the Interconnection Customer shall obtain the Participating TO’s approval of, the engineering design, equipment acceptance tests, and the construction of the Participating TO's Interconnection Facilities and Stand Alone Network Upgrades, which approval shall not be unreasonably withheld, and the CAISO may, at its option, review the engineering design, equipment acceptance tests, and the construction of the Participating TO's Interconnection Facilities and Stand Alone Network Upgrades; (4) prior to commencement of construction, the Interconnection Customer shall provide to the Participating TO, with a copy to the CAISO for informational purposes, a schedule for construction of the Participating TO's Interconnection Facilities and Stand Alone Network Upgrades, and shall promptly respond to requests for information from the Participating TO; (5) at any time during construction, the Participating TO shall have the right to gain unrestricted access to the Participating TO's Interconnection Facilities and Stand Alone Network Upgrades and to conduct inspections of the same; (6) at any time during construction, should any phase of the engineering, equipment procurement, or construction of the Participating TO's Interconnection Facilities and Stand Alone Network Upgrades not meet the standards and specifications provided by the Participating TO, the Interconnection Customer shall be obligated to remedy deficiencies in that portion of the Participating TO's Interconnection Facilities and Stand Alone Network Upgrades; (7) the Interconnection Customer shall indemnify the CAISO and Participating TO for claims arising from the Interconnection Customer's construction of the Participating TO's Interconnection Facilities and Stand Alone Network Upgrades under the terms and procedures applicable to Article 18.1

  • Time for Completion The Contractor shall deliver the material and/or services called for in the specifications/proposal and within the delivery time specified and in accordance with the terms of the contract. Work shall be completed within 30 days from the Notice to Proceed issued by the City of Sparks Purchasing Division. The Contractor shall not alter or vary any terms or conditions contained or incorporated herein, including but not limited to, the quantity, price, delivery date or date designated as After Receipt of Order (ARO) or date for commencement or completion of services as mutually agreed upon, unless such alteration or variation is consented to in writing by a duly authorized representative of the City. The City reserves the right to cancel resultant Contract upon ten days written notice in the event the type and quality of the product or work performance is unsatisfactory or in default, subject to Contractor’s right to cure as outlined in termination clause. This is a non-exclusive Contract and the City reserves the right to acquire the material and/or services at its discretion, from other sources during the term of this Contract.

  • TIME OF COMMENCEMENT AND COMPLETION 2.1 The Contractor shall commence the Work upon the date established in the Notice to Proceed. 2.2 The Contractor shall achieve Final Completion, as defined in Section 105.01, Contract Time, Notice of Contract Execution and Notice to Proceed of the Loudoun County Revisions to the 0000 XXXX Xxxx & Bridge Specifications, Division I - General Provisions, within one hundred and eighty (180) calendar days from the date specified in the Notice to Proceed. This time period shall be designated the Contract Time. The Notice to proceed will be issued approximately than thirty (30) days after the execution of this agreement. The Contractor agrees that the time for completion of the Work as described in the Contract Documents shall govern unless specifically amended in writing by the County, and that no claims for early completion are allowed to be presented by the Contractor to the County. 2.3 The County specifies that time is of the essence under this Contract. Time being of the essence, it is essential to the County that Contract work will be completed within the Contract Time. The County and the Contractor agree that damages for failure to complete the work within the Contract Time are not susceptible to exact determination but that $600 per day is in proportion to the actual loss that the County would suffer from such delay. Therefore, the Contractor will pay the County on demand $600 per day for each and every day beyond the one hundred and eighty (180) calendar days, or modified date of completion, that the County determines that work is not complete, as damages caused by such delay and not as a penalty. The County shall be entitled to offset liquidated damages against any sum owed by the County to the Contractor under this Contract. 2.4 The amount of liquidated damages set forth in Articles 2.3 above shall be assessed cumulatively. This provision for liquidated damages does not bar County's right to enforce other rights and remedies against Contractor, which are otherwise legally enforceable, including but not limited to, specific performance or injunctive relief. 2.5 The Contractor hereby waives any defense as to the validity of any liquidated damages stated in this Agreement as they may appear on grounds that such liquidated damages are void as penalties or are not reasonably related to actual damages.

  • TIME OF COMPLETION This project’s start date is scheduled for June 15, 2015 and completion date is July 31, 2015. The Contractor agrees to proceed with the work expeditiously without any delay or cessation, except such as may reasonably be beyond his control, and to employ a force of workmen sufficient so to perform the work covered by this Contract in such manner as to expedite the work of such other Contractors as may be engaged upon the work, as further provided in the Instructions to Bidders, to the end that the work to be performed by the Contractor shall be fully completed on or before the 31st day of July, 2015, subject to such adjustment of said date as may be made in accordance with this Contract. It is specifically agreed that the Contractor shall be bounden for damages, as hereinafter provided, for each and every day's delay which may be due or traceable to the Contract. In case the Contractor shall fail to perform fully the Contract within the agreed time limit, he shall pay to the City of Milwaukee, as liquidated damages for such default, the sum of $250.00 per day for each and every day's delay in completing the performance thereof after such time limit.

  • Date of Completion The Developer must ensure that the Developer’s Works reach Completion on or before the date or milestone referred to in clause 1 of Schedule 3 of this document.

  • Value of Completed Work If the Engineer defaults in the performance of this contract or if the State terminates this contract for fault on the part of the Engineer, the State will give consideration to the following when calculating the value of the completed work: (1) the actual costs incurred (not to exceed the rates set forth in Attachment E, Fee Schedule) by the Engineer in performing the work to the date of default; (2) the amount of work required which was satisfactorily completed to date of default; (3) the value of the work which is usable to the State; (4) the cost to the State of employing another firm to complete the required work; (5) the time required to employ another firm to complete the work; and (6) other factors which affect the value to the State of the work performed.

  • Failure to Comply 8.2.1 If the Developer fails to observe or perform any condition of this Agreement after the Municipality has given the Developer 30 days written notice of the failure or default, then in each such case: (a) The Municipality shall be entitled to apply to any court of competent jurisdiction for injunctive relief including an order prohibiting the Developer from continuing such default and the Developer hereby submits to the jurisdiction of such Court and waives any defence based upon the allegation that damages would be an adequate remedy; (b) The Municipality may enter onto the Lands and perform any of the covenants contained in this Agreement or take such remedial action as is considered necessary to correct a breach of the Agreement, whereupon all reasonable expenses whether arising out of the entry onto the Lands or from the performance of the covenants or remedial action, shall be a first lien on the Lands and be shown on any tax certificate issued under the Assessment Act; (c) The Municipality may by resolution discharge this Agreement whereupon this Agreement shall have no further force or effect and henceforth the development of the Lands shall conform with the provisions of the Land Use By-law; or (d) In addition to the above remedies, the Municipality reserves the right to pursue any other remedy under the Halifax Regional Municipality Charter or Common Law in order to ensure compliance with this Agreement.

  • Non-Compliant Delivery Overshipments and/or early deliveries may be returned at Supplier’s sole expense, or DXC may delay processing the early delivery invoice until the Delivery Date.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!