Notice of Disputes and Objections Sample Clauses

Notice of Disputes and Objections. If Contractor disputes or objects to any requirement, direction, instruction, interpretation, determination, or decision of Owner, Contractor may notify Owner in writing of its dispute or objection and of the amount of any equitable adjustment to the Contract Price or Contract Time to which Contractor claims it will be entitled as a result thereof; provided, however, that Contractor shall, nevertheless, proceed without delay to perform the Work as required, directed, instructed, interpreted, determined, or decided by Owner, without regard to such dispute or objection. Unless Contractor so notifies Owner within two business days after receipt of such requirement, direction, instruction, interpretation, determination, or decision, Contractor shall be conclusively deemed to have waived all such disputes or objections and all claims based thereon.
Sample 1Sample 2Sample 3See All (6)
AutoNDA by SimpleDocs
Notice of Disputes and Objections. If Franchisee disputes or objects to any direction, instruction, determination, or decision of the City, then Franchisee may notify the City in writing of its dispute or objection; provided, however, that Franchisee shall, nevertheless, proceed without delay to perform the Work as directed, instructed, determined, or decided by the City, without regard to such dispute or objection. Unless Franchisee so notifies the City within two business days after receipt of such direction, instruction, determination, or decision, Franchisee shall be deemed to have waived all such disputes or objections and all claims based thereon.
Sample 1

Related to Notice of Disputes and Objections

  • Notice of Disputes Notice of the dispute will be submitted on the form provided in Appendix A and sent to the responding party, in order to provide an opportunity to respond. The Crown shall be provided with a copy. a) Notice of the dispute shall include the following: i. Any central provision of the collective agreement alleged to have been violated. ii. The provision of any statute, regulation, policy, guideline, or directive at issue. iii. A comprehensive statement of any relevant facts. iv. The remedy requested.

  • Notice of Dispute The party wishing to commence the dispute resolution process must give written notice (Notice of Dispute) to the other parties of: (a) The nature of the dispute, (b) The alleged basis of the dispute, and (c) The position which the party issuing the Notice of Dispute believes is correct.

  • Resolution of Disagreements Disputes arising under this Agreement will be resolved informally by discussions between Agency Points of Contact, or other officials designated by each agency.

  • Dispute Notice If there is a dispute between the parties, then either party may give a notice to the other succinctly setting out the details of the dispute and stating that it is a dispute notice given under this clause 17.1.

  • Resolution of Disputes Any dispute or disagreement which may arise under, or as a result of, or in any way related to, the interpretation, construction or application of this Agreement shall be determined by the Committee. Any determination made hereunder shall be final, binding and conclusive on the Grantee and the Company for all purposes.

  • Arbitration Notice BY INITIALING IN THE SPACE BELOW YOU ARE AGREEING TO HAVE ANY DISPUTE ARISING OUT OF THE MATTERS INCLUDED IN THE "ARBITRATION OF DISPUTES" PROVISION DECIDED BY NEUTRAL ARBITRATION AS PROVIDED BY CALIFORNIA LAW AND YOU ARE GIVING UP ANY RIGHTS YOU MIGHT POSSESS TO HAVE THE DISPUTE LITIGATED IN COURT OR JURY TRIAL. BY INITIALING IN THE SPACE BELOW YOU ARE GIVING UP YOUR JUDICIAL RIGHTS TO DISCOVERY AND APPEAL, UNLESS SUCH RIGHTS ARE SPECIFICALLY INCLUDED IN THE "ARBITRATION OF DISPUTES" PROVISION. IF YOU REFUSE TO SUBMIT TO ARBITRATION AFTER AGREEING TO THIS PROVISION, YOU MAY BE COMPELLED TO ARBITRATE UNDER THE AUTHORITY OF THE CALIFORNIA CODE OF CIVIL PROCEDURE. YOUR AGREEMENT TO THIS ARBITRATION PROVISION IS VOLUNTARY.

  • Resolution of Dispute Any dispute regarding this Agreement (including without limitation its validity, interpretation, performance, enforcement, termination and damages) shall be determined in accordance with the laws of the State of California, the United States of America. Any action under this paragraph shall not preclude any party hereto from seeking injunctive or other legal relief to which each party may be entitled.

  • Mediation of Disputes The parties shall endeavor in good faith to settle within 90 days any controversy or claim arising out of or relating to this Agreement or the breach thereof through mediation with JAMS, Endispute or similar organizations. If the controversy or claim is not resolved within 90 days, the parties shall be free to pursue other legal remedies in law or equity.

  • Settlement of Disputes; Arbitration All claims by the Executive for benefits under this Agreement shall be directed to and determined by the Board of Directors of the Company and shall be in writing. Any denial by the Board of Directors of a claim for benefits under this Agreement shall be delivered to the Executive in writing and shall set forth the specific reasons for the denial and the specific provisions of this Agreement relied upon. The Board of Directors shall afford a reasonable opportunity to the Executive for a review of the decision denying a claim. Any further dispute or controversy arising under or in connection with this Agreement shall be settled exclusively by arbitration in Boston, Massachusetts, in accordance with the rules of the American Arbitration Association then in effect. Judgment may be entered on the arbitrator's award in any court having jurisdiction.

  • Resolution of Disputes Choice of Law (a) This Transition Agreement shall be construed and enforced in accordance with the laws of the State of California without regard to the principles of conflicts of law. (b) All suits, actions or proceedings arising out of or relating to this Transition Agreement shall be brought in a state or federal court located in San Francisco County, California, which courts shall be the exclusive forum for all such suits, actions or proceedings. Executive and the Company hereby waive any objection which either of Executive may now or hereafter have to the laying of venue in any such court, including any claim based on the doctrine of forum non conveniens or any similar doctrine, for any such suit, action or proceeding. Executive and the Company each hereby irrevocably consent and submit to the jurisdiction of the federal and state courts located in San Francisco County, California for the purposes of any suit, action or proceeding arising out of relating to this Transition Agreement. If any action is necessary to enforce the terms of this Transition Agreement, the substantially prevailing party will be entitled to reasonable attorneys’ fees, costs and expenses in addition to any other relief to which such prevailing party may be entitled (c) EXECUTIVE AND THE COMPANY EACH HEREBY WAIVE ANY RIGHT TO A TRIAL BY JURY IN ANY SUIT, ACTION OR PROCEEDING ARISING UNDER THIS TRANSITION AGREEMENT OR RELATED IN ANY WAY TO EXECUTIVE’S EMPLOYMENT AND/OR TO THE TERMINATION OF EXECUTIVE’S EMPLOYMENT AND AGREE THAT ANY SUCH SUIT, ACTION OR PROCEEDING SHALL BE TRIED BEFORE A COURT AND NOT BEFORE A JURY.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!