Notice of Performance Testing or PPA Sample Clauses

Notice of Performance Testing or PPA. Output Tests. Contractor shall give Owner (i) Contractor's schedule for Performance Tests and PPA Output Tests and their projected commencement dates at least thirty (30) days prior thereto, and (ii) at least fourteen (14) days' written notice in advance of the date on which Contractor intends to commence such testing of the Facility under this Agreement. Within five (5) days of receipt of any such notice of testing, Owner shall either (a) instruct Contractor to proceed with such testing, or (b) instruct Contractor to delay such testing if Mechanical Completion has not been achieved by such date. Contractor shall not attempt to cause such testing to be performed if Owner gives notice to Contractor of any aspect of the Project which has not been completed by Contractor, the completion of which is required for the safe operation of all or any part of the Facility during a Performance Test or PPA Output Test in accordance with Applicable Laws, Applicable Permits, Prudent Utility Practices, the Instruction Manual, the Electrical Interconnection Requirements and the PPA Operating Requirements (to the extent applicable to such testing operations). If Owner delays such performance and output testing because of Owner's failure to perform any of its obligations under this Agreement or if the Utility is unable or unwilling to receive the net power output generated during the test in accordance with Prudent Utility Practices, then, to the extent that Contractor was reasonably delayed in the performance of the Services as a direct result thereof, the provisions of Section 5.9 hereof shall apply.
Sample 1Sample 2Sample 3
AutoNDA by SimpleDocs

Related to Notice of Performance Testing or PPA

  • Performance Tests Contractor shall perform Performance Tests in accordance with Section 11.2 of the Agreement and Attachment S.

  • Standard of Performance The Executive will perform his duties under this Agreement with fidelity and loyalty, to the best of his ability, experience and talent and in a manner consistent with his duties and responsibilities.

  • PERIOD OF PERFORMANCE Extend the period of performance by one (1) year from 31 December 2001 to 31 December 2002. The total period of performance now is from 1 March 1996 to 31 December 2002.

  • Time of Performance Except as expressly otherwise herein provided, with respect to all required acts of Tenant, time is of the essence of this Lease.

  • Manner of Performance All Alterations must be performed: (i) in accordance with the approved plans, specifications and working drawings; (ii) in a lien-free and first-class and workmanlike manner; (iii) in compliance with all applicable permits, laws, statutes, ordinances, rules, regulations, orders and rulings now or hereafter in effect and imposed by any governmental agencies and authorities which assert jurisdiction; (iv) in such a manner so as not to interfere with the occupancy of any other tenant in the Building, nor impose any additional expense upon nor delay Landlord in the maintenance and operation of the Building; and (v) at such times, in such manner, and subject to such rules and regulations as Landlord may from time to time reasonably designate.

  • Standards of Performance Executive will at all times faithfully, industriously and to the best of his/her ability, experience and talents perform all of the duties required of and from him/her pursuant to the terms of this Agreement. Executive will devote his/her full business energies and abilities and all of his/her business time to the performance of his/her duties hereunder and will not, without the Company’s prior written consent, render to others any service of any kind (whether or not for compensation) that, in the Company’s sole but reasonable judgment, would interfere with the full performance of his/her duties hereunder. Notwithstanding the foregoing, Executive is permitted to spend reasonable amounts of time to manage his/her personal financial and legal affairs and, with the Company’s consent which will not be unreasonably withheld, to serve on one civic, charitable, not-for-profit, industry or corporate board or advisory committee, provided that such activities, individually and collectively, do not materially interfere with the performance of Executive’s duties hereunder. In no event will Executive engage in any activities that could reasonably create a conflict of interest or the appearance of a conflict of interest. Executive shall be subject to the Company’s policies, procedures and approval practices, as generally in effect from time to time.

  • Excuse of Performance Grantor's and Licensee's performance (other than Licensee's obligation to pay for Products or other fees or monetary obligations in accordance herewith, which shall not be excused) hereunder shall be excused if (but only for so long as) any of the following conditions or events occur and are continuing: Labor conflicts, strikes, lock-outs, fires, explosions, war, civil disturbances, unforeseen military action, governmental action, requisitions or seizures, delays of subcontractors or vendors, unavailability of raw materials or transport facilities, acts of God or nature, or any other condition or event which is beyond the reasonable control of Grantor or Licensee, as the case may be.

  • Suspension of Performance During the period that the performance by one of the parties of its obligations under this Agreement has been suspended by reason of an event of Force Majeure, the other party may likewise suspend the performance of all or part of its obligations hereunder to the extent that such suspension is commercially reasonable.

  • Acceptance of Employment; Standard of Performance The Subadviser accepts its employment as a discretionary series adviser of the Designated Series and agrees to use its best professional judgment to make investment decisions for the Designated Series in accordance with the provisions of this Agreement and as set forth in Schedule D attached hereto and made a part hereof.

  • Prevention of Performance The Custodian will not be responsible for any failure to perform any of its obligations (nor will it be responsible for any unavailability of funds credited to the Cash Account) if such performance is prevented, hindered or delayed by a Force Majeure Event, in such case its obligations will be suspended for so long as the Force Majeure Event continues. “Force Majeure Event” means any event due to any cause beyond the reasonable control of the Custodian, such as restrictions on convertibility or transferability, requisitions, involuntary transfers, unavailability of communications system, sabotage, fire, flood, explosion, acts of God, civil commotion, strikes or industrial action of any kind, riots, insurrection, war or acts of government.

Time is Money Join Law Insider Premium to draft better contracts faster.