Notice of Potential Claims The Contractor shall not be entitled to additional compensation or to extension of time for (1) any act or failure to act by the County Project Manager or the County, or (2) the happening of any event or occurrence, unless the Contractor has given the County a written Notice of Potential Claim within ten (10) days of the commencement of the act, failure, or event giving rise to the claim, and before final payment by the County. The written Notice of Potential Claim shall set forth the reasons for which the Contractor believes additional compensation or extension of time is due, the nature of the cost involved, and insofar as possible, the amount of the potential claim. Contractor shall keep full and complete daily records of the work performed, labor and material used, and all costs and additional time claimed to be additional.
Notice of Completion; Copy of Record Set of Plans Within fifteen (15) days after completion of construction of the Improvements, Tenant shall cause a Notice of Completion to be recorded in the office of the Recorder of the county in which the Building is located in accordance with Section 8182 of the Civil Code of the State of California or any successor statute, and shall furnish a copy thereof to Landlord upon such recordation. If Tenant fails to do so, Landlord may execute and file the same as Tenant’s agent for such purpose, at Tenant’s sole cost and expense. At the conclusion of construction, (i) Tenant shall cause the Architect and Contractor (A) to update the Approved Working Drawings as necessary to reflect all changes made to the Approved Working Drawings during the course of construction, (B) to certify to the best of their knowledge that the “record-set” of as-built drawings are true and correct, which certification shall survive the expiration or termination of this Lease, and (C) to deliver to Landlord two (2) sets of copies of such record set of drawings within ninety (90) days following issuance of a certificate of occupancy for the Premises, and (ii) Tenant shall deliver to Landlord a copy of all warranties, guaranties, and operating manuals and information relating to the improvements, equipment, and systems in the Premises.
NOTICE OF LABOR DISPUTES (a) If the Contractor has knowledge that any actual or potential labor dispute is delaying or threatens to delay the timely performance of this Contract, the Contractor immediately shall give notice, including all relevant information, to the Authority.
(b) The Contractor agrees to insert the substance of this paragraph, including this subparagraph (b), in any Sub- contract under which a labor dispute may delay the timely performance of this Contract; except that each Subcontract shall provide that in the event its timely performance is delayed or threatened by delay by any actual or potential labor dispute, the Subcontractor shall immediately notify the next higher tier Subcontractor or the Contractor, as the case may be, of all relevant information concerning the dispute.
Notice of Privacy Practices Business Associate shall abide by the limitations of Covered Entity’s Notice of which it has knowledge. Any use or disclosure permitted by this Agreement may be amended by changes to Covered Entity’s Notice; provided, however, that the amended Notice shall not affect permitted uses and disclosures on which Business Associate relied prior to receiving notice of such amended Notice.
Notice of Agreement 1. The Institutions agree to provide a copy of this Agreement, with any amendments, to the Maryland Higher Education Commission.
2. The Institutions agree to provide copies of this Agreement to all relevant individuals and departments of the Institutions, including but not limited to students, academic department chairs participating in the transfer, offices of the president, registrar’s offices, and financial aid offices.
Notice of Arbitration If a Person asserts that there exists a Dispute, then such Person (the “Disputing Person”) will give each other Person involved in such Dispute a written notice setting forth the nature of the asserted Dispute. If all such Persons do not resolve any such asserted Dispute prior to the 10th business day after such notice is given, then any of them may commence arbitration pursuant to this Paragraph 19 by giving each other Person involved in such Dispute a written notice to that effect (an “Arbitration Notice”), setting forth any matters which are required to be set forth therein in accordance with the AAA Rules.
Notice of Disputes Notice of the dispute will be submitted on the form provided in Appendix A and sent to the responding party, in order to provide an opportunity to respond. The Crown shall be provided with a copy.
a) Notice of the dispute shall include the following:
i. Any central provision of the collective agreement alleged to have been violated.
ii. The provision of any statute, regulation, policy, guideline, or directive at issue.
iii. A comprehensive statement of any relevant facts.
iv. The remedy requested.
Notice of Enrollment Notice shall include a list of new employees represented by the Union scheduled to attend the NEO. If practical, the City agrees to provide additional identifying information including, but not limited to, classification and department. Six months from enactment, in the event the City is unable to provide classification and department information in the Notice of Enrollment, the Union can reopen this Agreement for the sole purpose of meeting and conferring over the identifying information provided in this Section II.C.3
Notification of Legal Requests Contractor shall immediately notify City upon receipt of any subpoenas, service of process, litigation holds, discovery requests and other legal requests (“Legal Requests”) related to all data given to Contractor by City in the performance of this Agreement (“City Data” or “Data”), or which in any way might reasonably require access to City’s Data, and in no event later than 24 hours after it receives the request. Contractor shall not respond to Legal Requests related to City without first notifying City other than to notify the requestor that the information sought is potentially covered under a non-disclosure agreement. Contractor shall retain and preserve City Data in accordance with the City’s instruction and requests, including, without limitation, any retention schedules and/or litigation hold orders provided by the City to Contractor, independent of where the City Data is stored.
Notice of Appeal In the event that an employee who has been laid off out of seniority order believes the decision based upon performance and/or qualifications is incorrect, the employee may request that the Association appeal the Sheriff’s determination. If the Association finds there is good reason to believe that the Sheriff has erred in his decision, it may appeal through the process set forth in this Article. Such appeal shall be filed within five (5) working days of delivery of the layoff notice to the employee.
