Order to Stop Work The Procurement Officer, may, by written order to Contractor at any time, and without notice to any surety, require Contractor to stop all or any part of the work called for by this contract. This order shall be for a specified period not exceeding 90 days after the order is delivered to Contractor, unless the parties agree to any further period. Any such order shall be identified specifically as a stop work order issued pursuant to this clause. Upon receipt of such an order, Contractor shall forthwith comply with its terms and take all reasonable steps to minimize the occurrence of costs allocable to the work covered by the order during the period of work stoppage. Before the stop work order expires, or within any further period to which the parties shall have agreed, the Procurement Officer shall either:
Right to Stop Work If Contractor fails to correct any defective Work or repeatedly fails to perform the Work in accordance with the Contract Documents, Owner shall have the right to order Contractor to stop performing the Work, or any portion thereof, until the cause for such order is eliminated.
Project Schedule Construction must begin within 30 days of the date set forth in Appendix A, Page 2, for the start of construction, or this Agreement may become null and void, at the sole discretion of the Director. However, the Recipient may apply to the Director in writing for an extension of the date to initiate construction. The Recipient shall specify the reasons for the delay in the start of construction and provide the Director with a new start of construction date. The Director will review such requests for extensions and may extend the start date, providing that the Project can be completed within a reasonable time frame.
Technical Standards Applicable to a Wind Generating Plant i. Low Voltage Ride-Through (LVRT) Capability A wind generating plant shall be able to remain online during voltage disturbances up to the time periods and associated voltage levels set forth in the standard below. The LVRT standard provides for a transition period standard and a post-transition period standard.
NOTICE TO PROCEED AND SCHEDULE The CONSULTANT shall begin the work to be performed under this Contract only upon receipt of the written notice to proceed from the LPA, and shall deliver the work to the LPA in accordance with the schedule contained in Appendix "C" which is herein attached to and made an integral part of this Contract.
Notice to Proceed - Site Improvements The Recipient shall not commence, or cause to be commenced, any site improvements or other work on the Land until the Director has issued a Notice to Proceed to the Recipient. Such Notice to Proceed will not be issued until the Director is assured that the Recipient has complied with all requirements for the approval of a grant under Revised Code Sections 164.20 through 164.27 and has completed any land acquisition required by the Project. A Notice to Proceed shall be required for all Project prime contractors or direct procurement initiated by the Recipient following execution of this Agreement.
Construction Progress Schedule; Overall Project Schedule The Contractor shall submit for review by the Design Professional and approval by the Owner a Construction Progress Schedule based upon the Design Professional’s Preliminary Design and Construction Schedule and prepared using a CPM (Critical Path Method) process within sixty days after the Effective Date of the Contract, utilizing a full-featured software package in a form satisfactory to the Design Professional and Owner, showing the dates for commencement and completion of the Work required by the Contract Documents, including coordination of mechanical, plumbing, and electrical disciplines, as well as coordination of the various subdivisions of the Work within the Contract. Milestones must be clearly indicated and sequentially organized to identify the critical path of the Project. The Construction Schedule will be developed to represent the CSI specification divisions. It shall have the minimum number of activities required to adequately represent to the Owner the complete scope of Work and define the Project’s (and each Phase’s if phased) critical path and associated activities. The format of the Construction Progress Schedule will have dependencies indicated on a monthly grid identifying milestone dates such as construction start, phase construction, structural top out, dry-in, rough-in completion, metal stud and drywall completion, equipment installation, systems operational, inspections for Material Completion and Occupancy Date, and Final Completion Date. The Contractor shall submit, along with the Construction Progress Schedule, the Submittal Schedule for approval by the Design Professional, correlating the associated approval dates for the documents with the Construction Progress Schedule. Upon recommendation by the Design Professional and approval by the Owner, the Construction Progress Schedule shall become the Overall Project Schedule, which shall be utilized by the Design Professional, Owner and Contractor. The Contractor must provide the Design Professional and the Owner with monthly updates of the Overall Project Schedule indicating completed activities and any changes in sequencing or activity durations, including approved change orders. See also Article 3.3.5.
Optional Xactimate Response Attachment (Part 2)
Why did I get this Notice This is a court-authorized notice of a proposed settlement in a class action lawsuit, XxXxxxx, et al. v. Veriff, Inc., No. 2021L001202, pending in the Circuit Court of DuPage County, Illinois before the Xxx. Xxxxx Xxxxxxx. The Settlement would resolve a lawsuit brought on behalf of persons who allege that Veriff, Inc., collected individuals’ biometrics in Illinois through its identity-verification technology without first providing the individuals with legally-required written disclosures and obtaining written consent. If you received notice of this Settlement, you have been identified as someone who, at some time between November 12, 2016 and [Preliminary Approval], had biometrics collected, captured, purchased, received through trade, possessed, retained or otherwise obtained while in Illinois by Veriff or its technology for the purposes of identity verification, and whose identity was verified. The Court has granted preliminary approval of the Settlement and has conditionally certified the Settlement Class for purposes of settlement only. This notice explains the nature of the class action lawsuit, the terms of the Settlement, and the legal rights and obligations of the Settlement Class Members. Please read the instructions and explanations below so that you can better understand your legal rights. WHAT IS THIS LAWSUIT ABOUT? The Illinois Biometric Information Privacy Act (“BIPA”), 740 ILCS 14/1, et seq., prohibits private companies from capturing, obtaining, storing, transmitting, and/or using the biometric identifiers and/or information, such as scans of face geometry, of another individual for any purpose without first providing them with certain written disclosures and obtaining written consent. This lawsuit alleges that Defendant violated BIPA by collecting or capturing the scans of face geometry of individuals through identity verification technology in Illinois without first providing the requisite disclosures or obtaining the consent required by BIPA. Defendant contests these claims, denies that it collected or possessed facial biometrics or any other information subject to BIPA, and denies that it violated BIPA. WHY IS THIS A CLASS ACTION? A class action is a lawsuit in which an individual called a “Class Representative” brings a single lawsuit on behalf of other people who have similar claims. All of these people together are a “Class” or “Class Members.” Once a Class is certified, a class action Settlement finally approved by the Court resolves the issues for all Settlement Class Members, except for those who exclude themselves from the Settlement Class. WHY IS THERE A SETTLEMENT? To resolve this matter without the expense, delay, and uncertainties of litigation, the Parties have reached a Settlement, which resolves all claims against Defendant and its affiliated entities. The Settlement requires Defendant to pay money to the Settlement Class, as well as pay settlement administration expenses, attorneys’ fees and costs to Class Counsel, and Incentive Awards to each of the Class Representatives, if approved by the Court. The Settlement is not an admission of wrongdoing by Defendant and does not imply that there has been, or would be, any finding that Defendant violated the law. The Court has already preliminarily approved the Settlement. Nevertheless, because the settlement of a class action determines the rights of all members of the class, the Court overseeing this lawsuit must give final approval to the Settlement before it can be effective. The Court has conditionally certified the Settlement Class for settlement purposes only, so that members of the Settlement Class can be given this notice and the opportunity to exclude themselves from the Settlement Class, to voice their support or opposition to final approval of the Settlement, and to submit a Claim Form to receive the relief offered by the Settlement. If the Court does not give final approval to the Settlement, or if it is terminated by the Parties, the Settlement will be void, and the lawsuit will proceed as if there had been no settlement and no certification of the Settlement Class.
Notice to Proceed (NTP Following the JOA and purchase order issuance, the County will issue a Notice to Proceed (NTP) that will provide the construction start date, the Work duration period, and the Substantial Completion date. The Contractor agrees to begin and complete construction within the dates specified on the NTP. The County must approve all extensions of time in writing. The County may also issue an Emergency Notice to Proceed (NTP). In the event the County requires the Contractor to respond to an immediate request for work, a Job Order will be created and an Emergency NTP will be issued. The Contractor will be required to perform the Scope of Work included with the Emergency NTP as directed by the County’s Project Manager or designee. The Detailed Scope of Work, Quotation, Subcontractor Listing, Shop Drawings and required Non Pre-priced backup documentation will be submitted upon completion of the emergency work in accordance with the Ordering Procedures detailed in Section III above.
